HomeMy WebLinkAbout1989-10-11 COUNTY SANITATION DISTRICTS
OF ORANGE COUNTY, CALIFORNIA
P.O. BOX 0127,FOUNTAIN VALLEY,CALIFORNIA 927294127
job"ELLIS.FOUNTAIN VALLEY.CALIFORNIA 22TOB-7078
(714)962-2411
October 4, 1989
NOTICE OF REGULAR MEETING
DISTRICTS NOS. 1, 2, 3, 5, 6, 7, 11, 13 8 14
WEDNESDAY, OCTOBER 11, 1989 - 7:30 P.M.
10844 Ellis Avenue
Fountain Valley, California
The next regular meeting of the Boards of Directors of County
Sanitation Districts Nos. 1, 2, 3, 5, 6, 7, 11, 13 and 14 of
Orange County, California, will be held at the above hour and
date. e�c
secretary
Tentatively-Scheduled upcoming Meetings:
EXECUTIVE COMMITTEE - Wednesday, October 18th, at S: 30 p.m.
(Hearing on Industrial waste Permit appeal)
EXECUTIVE COMMITTEE - Thursday, October 26th, at 5: 30 p.m.
(NOTE: This is a change from the regular
October meeting date of October 25th to
avoid a conflict with the League of Cities
conference)
CONSERVATION,
y RECLAMATION AND
REUSE COMMITTEE - Wednesday, November 1st, at 5 : 30 p.m.
COUNTY SANITATION DISTRICTS
21 ORANGE COUNTY. CAUFONNIA
1%a4 Ew9 AVENUE
PO 90.e12]
FOUNTAIN VALLEY.CALIFORNIA 92729-91�,MRWO
17141%22aH
JOINT BOARD AND EXECUTIVE COMMITTEE MEETING DATES
Joint Board Meetings Executive Committee Meetings
October Oct 11, 1989
• b
®RE.'
ff
_ .
November Nov 08, 1989 None Scheduled
December Dec 13, 1989 None Scheduled
January Jan 10, 1990 Jan 24, 1990
February Feb 14, 1990 Feb 28, 1990
March Mar 14, 1990 Mar 28, 1990
April Apr 11, 1990 Apr 25, 1990
May May 09 , 1990 May 23 , 1990
June Jun 13, 1990 Jun 27 , 1990
July Jul 11 , 1990 Jul 25, 1990
August Aug 08, 1990 None Scheduled
September Sep 12, 1990 Sep 26, 1990
October Oct 10, 1990 Oct 24, 1990
'- -e _ BOARDS OR DIRECTORS
County Sanitation Districts P.O. Box 8127 a 10844 Ellis Avenue
of Orange County,California Fountain valley,CA 92728-8127
Telephone: (714) 962-2411
JOINT BOARDS
AGENDA
REGULAR MEETING.
OCTOBER 11, 1989 - 7:30 P.M.
In accordance with the requirements of California Government
Code Section 54954.2, this agenda is posted not less than 72
hours prior to the meeting date and time above. All written
materials relating to each agenda item are available for public
inspection in the Office of the Board Secretary.
In the event any matter not listed on this agenda is
proposed to be submitted to the Boards for discussion and/or
action, it will be done in compliance with Section 54954.2, or
as set forth on a supplemental agenda posted not less than 72
hours prior to the meeting date.
(1) Pledge of Allegiance and Invocation
(2) Roll call
( 3) Appointment of Chairmen pro tem, if necessary
(4) Consideration of motion to receive and file minute excerpts
of member agencies relating to appointment of Directors, if
any. (See listing in Board Meeting folders)
(5) Public Comments: All persons wishing to addressthe Boards
an specific agenda items or matters of general interest
should do so at this time. As determined by the Chairman,
speakers may be deferred until the specific item is taken
for discussion and remarks may be limited to five minutes.
(6 ) The Joint Chairman, General Manager and General Counsel
present verbal reports on miscellaneous matters of general
interest to the Directors. These reports are for
information only and require no action by the Directors.
(a) Report of Joint Chairman
(b) Report of General Manager
(c) Report of General Counsel
i s- 3
10/11/89
( 7 ) EACH DISTRICT
ACTION: if no corrections or amendments are made, the
following minutes will be deemed approved as
mailed and be so ordered by the Chairman:
District 1 - September 13, 1989 regular
District 2 - September 13, 1989 regular
District 3 - September 13, 1989 regular
District 5 - September 13, 1989 regular
District 6 - September 13, 1989 regular
District 7 - September 13, 1989 regular
District 11 - September 13, 1989 regular
District 13 - September 13, 1989 regular
District 14 - September 13, 1989 regular
(8) ALL DISTRICTS '
Conssi erafion of roll call vote motion ratifying payment of
claims of the joint and individual Districts as follows:
(Each Director shall be called only once and that vote will
be regarded as the same for each District represented unless
a Director expresses a desire to vote differently for any
District. ) See pages "A" and "R"
9/13/89 9/27/89
ALL DISTRICTS
Jo Operating Fund - $ 460,788.90 $ 990,045.71
Capital Outlay Revolving Fund - 2,502,232.16 439,688.74
Joint Working Capital Fund - 155,213 .48 146,529.26
Self-Funded Insurance Funds - -0- 11,268.85
DISTRICT NO. 1 - 61.68 2,903.71
DISTRICT NO. 2 - 154,941.73 82,550.50
DISTRICT NO. 3 - 5,923.96 59,065.22
DISTRICT NO. 5 - 15,981.28 21,621 .04
DISTRICT NO. 6 - 62,814.13 1,511.94
DISTRICT NO. 7 - 25,762.59 12,362.40
DISTRICT NO. 11 - 74.62 1,758.70
DISTRICT NO. 13 - -0- 126.48
DISTRICT NO. 14 - 43,101.19 1,614.19
DISTRICTS NOS. 5 6 6 JOINT - 12,311.01 7,587.38
DISTRICTS NOS. 6 6 7 JOINT - 2,886.48 36 .28
DISTRICTS NOS. 7 6 14 JOINT - 170.14 3 394.38
$3,442,263. 35 1,782,064.78
-2-
10/11/89
(9 ) CONSENT CALENDAR - ITEMS 9(a) THROUGH 9(x)
All matters placed on the consent calendar are
considered as not requiring discussion or further
explanation and unless any particular item is
requested to be removed from the consent calendar by
a Director, staff member, or member of the public in
attendance, there will be no separate discussion of
these items. All items on the consent calendar will
be enacted by one action approving all motions, and
casting a unanimous ballot for resolutions included
on the consent calendar. All items removed from the
consent calendar shall be considered in the regular
order of business.
Members of the public who wish to remove an item
from the consent calendar shall, upon recognition by
the chair, state their name, address and designate
by letter the item to be removed from the consent
calendar.
The Chairman will determine if any items are to be
deleted from the consent calendar.
Consideration of action to approve all agenda items
appearing on the consent calendar not specifically
removed from same, as follows:
ALL DISTRICTS
(a) Consideration of Resolution No. 89-138, receiving
and filing bid tabulation and recommendation and
awarding contract for Purchase of Chlorine in
Bulk, Specification No. C-025, to Olympic
Chemical Company for the price of $212.70 per ton
plus sales tax, for a one-year period beginning
November 1, 1989, with provision for a one-year
extension (estimated annual cost $1,340,010.00
plus sales tax) . See page "C"
(b) Consideration of Resolution No. 89-139, receiving
and filing bid tabulation and recommendation and
awarding contract for Purchase of Chlorine in
One-Ton Cylinders, Specification No. C-026, to
Continental Chemical Company for the price of
$265.00 per tan plus sales tax, for a one-year
period beginning November 1, 1989, with provision
for a one-year extension (estimated annual cost
$159,000.00 plus sales tax) . See page —
ID-(c) Consideration of motion approving and authorizing
the District 1 Chairman and Secretary to execute
the Consent to Assignment of Real Property Lease
at Plant No. 1, Specification No. L-013, from
Miya Wholesale Nursery, Ltd. to Village Nurseries
L.P. , a California Limited Partnership
-3-
10/11/89
(9) ALL DISTRICTS - (CONSENT CALENDAR Continued)
(d) Consideration of motion approving Change Order
No. 12 to the plans and specifications for
Administration Building Addition, Job No. J-7-4, b.s�
authorizing an addition of $4,530.00 to the
contract with J. R. Roberts Corporation for three
items of additional work including installation
of a low voltage lighting panel, 50 light switch
box extensions for interior partition office
walls, additional ceramic tile in bathrooms
around light switch boxes and towel dispensers
and various plumbing changes in several locations
in the new South wing. See page "E"
(a) Consideration of motion approving Change Order
No. 20 to the plans and specifications for Ocean
Outfall Booster Station "C" at Plant No. 2, Job
No. J-15, authorizing an addition of $17,165.82
to the contract with Advanco Constructors, Inc.
for seven items of additional work including
moving two 120-inch diameter pipe sections to a
remote yard to be sandblasted, painted and then
returned for final placement, installation of
temporary electrical power to heat building
for protection of stored electrical equipment,
installation of a back-up power source for the
wet well bubbler control system in pumping
station, installation of harmonic filters on two
voltage relays, placement of safety handrail
equipment around four roof skylights, placement
of safety plate to close a 12-inch open space
around electrical cable trays and modification of
the computer control system alarm for the
variable frequency drives. See page "F"
(f) Consideration of motion approving Change Order
No. 22 to the plans and specifications for
Headworks No. 2 at Plant No. 1, Job No. P1-20,
and Demolition of Digesters Nos. 1, 2 and 4;
Replacement of Boiler; Piping Cleanouts; and
Grading and Paving at Plant No. 1, Job No. P1-31,
authorizing an addition of $25,662.11 to the
contract with Riewit Pacific Co. for ten items
of additional work including installation of a
digester gas flow meter required by SCAQND,
installation of a concrete landing pad at
existing headworks, addition of new drain line at
Sunflower Pump Station, rerouting three chlorine
solution lines at the splitter box, installation
of an aluminum ladder in lieu of stairway to
access the belt conveyor catwalk, modification of
stile-type stairway, reinforcing covers at piping
trench, installation of a cover over an opening
in discharge channel for odor control, additional
fiberglass grating and aluminum kick plates to
various locations for safety and chlorine gas
leak detector support modifications. See page
-4-
10/11/89
(9) ALL DISTRICTS - (CONSENT CALENDAR Continued)
(g) Consideration of motion approving Change Order
No. 19 to the plans and specifications for Covers
for Primary Basins at Plant No. 1, Job No. P1-25;
Foul Air Scrubber System at Plant No. 1, Job
No. P1-26; Covers for Primary Basins at Plant
No. 2, Job No. P2-32; Foul Air Scrubber System at
Plant No. 2, Job No. P2-33; and Improvements to
Grit Facility "B" , Billings Tunnel and
Distribution Structure "A" , Job No. P2-34,
authorizing an addition of $58,245.54 to the
contract with Advanco Constructors, Inc. for
seven items of additional work including
electrical modifications at rectangular
clarifiers, relocation of existing light
standards at Clarifiers D, E, F and G,
substitution of insulated copper grounding cable
in lieu of bare copper cable at clarifier basins,
installation of Oritex wear surface at each foul
air duct support location, installation of a foul
air connection on the underground primary
effluent line and a new underground effluent
sampling line, repair of 42-inch RCP influent
line to Clarifier I, and modification of
tread-plate hold-down anchors. See page "a"
(h) Consideration of motion approving Change Order
No. 5 to the plans and specifications for
Entrances, Site, Security and Interior Road
Improvements at Plant No. 1, Job No. P1-27,
authorizing an addition of $6,787 .15 to the
contract with Biewit Pacific Co. for five items
of additional work including additional
transformer and electrical wiring at two gate
card readers, installation of District-furnished
multiplexer, repair of landscaping, replacement
of 120-volt relays with 24-volt relays for gate
control circuitry, and traffic sign and striping
modifications. See page "I"
(i) Consideration of motion approving Change Order
No. 5 to the plans and specifications for
Miscellaneous Modifications and Improvements to
Facilities at Plant No. 2, Job No. P2-37,
authorizing an addition of $77,047.00 to the
contract with 2lebarth & Alper for placement of
sloped reinforced fill concrete in Digesters A
and B to improve flow characteristics of sludge
recirculating system, and providing for payment
of contract-specified bonuses for early
completion of certain major elements of the
project. See page "J"
V/ -5-
10/11/89
( 9) ALL DISTRICTS - (CONSENT CALENDAR Continued)
(j ) Consideration of Resolution No. 89-140, accepting
Cleaning of Digesters 7 and 8 at Plant No. 1, Job
No. P1-35-1-1, as complete, authorizing execution
of a Notice of Completion and approving Final
Closeout Agreement. See page "K"
(k) Consideration of motion authorizing the Selection
Committee to negotiate Addendum No. 2 to the
Professional Services Agreement with John Carollo
Engineers for design of Digesters Nos. 11-16,
Sludge and Gas Handling Facilities at Reclamation
Plant No. 1, Job No. P1-34, (subsequently divided
into Job Nos. P1-34-1 and P1-34-2) to provide for
additional construction support services and for
separation of Job No. P1-34-1 into two separate
construction projects, Gas Handling Facilities at
Reclamation Plant No. 1, Job No. P1-34-1, and
Construction of Digesters Nos. 11-16 at
Reclamation Plant No. 1, Job No. P1-34-3.
(1) Consideration of motion authorizing the Selection
Committee to solicit proposals and negotiate a
Professional Services Agreement with EMA, Inc.
for design of Replacement of Computerized
Monitoring System at Plant No. 2, Job No. P2-44.
(m) Consideration of motion authorizing the Selection
Committee to solicit proposals and negotiate a
Professional Services Agreement to conduct a
study of user categories for establishing rates
for Districts' one-time connection fees and
annual use fees.
(n) Consideration of Resolution No. 89-141 , approving
Addendum No. 1 to Agreement with Arthur Young &
Company for the functional design and
redevelopment of the Districts' supplemental user
fee data processing programs to interface with
the County Assessor' s and County Auditor's data
base management systems, including training
services and oversight necessary to implement the
new programs, providing for an expanded scope of
work to include additional program modifications
requested by the County Assessor to facilitate
data transfers, for an additional amount not to
exceed $37 ,180. 00, increasing the total
authorized compensation from $161,882.00 to an
amount not to exceed $199,062 .00 (said increase
to be deducted from County Assessor's charge to
the Districts for data base information and
processing) . See page "L"
-6-
10/11/89
(9) ALL DISTRICTS (CONSENT CALENDAR Continued)
.. (o) Consideration of motion authorizing staff to
issue a purchase order to Containerized Chemical
Disposal, Inc. for disposal of classified
materials and wastes under the County of Orange
Cooperative Agreement, pursuant to the
requirements of the Resource Conservation and
Recovery Act, for the period October 12, 1989 to
May 31, 1990, renewable for two years contingent
upon negotiations with the County of Orange (Cost
through 5/31/90 estimated not to exceed
$100,000.00) .
DISTRICT 2
(p) Consideration of motion approving Change Order
No. 1 to the plans and specifications for Portion
of Euclid Interceptor Sewer, between Edinger
Avenue and Lampoon Avenue, Contract No. 2-26-2,
and South Anaheim Relief Sewer, on Ball Road
between Euclid Street and Walnut Street, Contract
No. 2-27, authorizing an addition of $98,532.00
to the contract with W. H. Ebert Corp. for an
additional 1,610 tons of asphalt paving on Ball
Road. See page "M"
(q) Consideration of motion authorizing the staff and
General Counsel to negotiate and prepare an
agreement with the City of Anaheim relative to a
cooperative project in connection with
construction of Portion of Euclid Interceptor
Sewer, between Broadway and Orangethorpe Avenue,
Contract No. 2-26-3, and the City of Anaheim
Euclid Street Maintenance Project between
La Palma Avenue and the 91 Freeway, providing for
City costs to be reimbursed to the District.
(r) Consideration of motion to receive and file
petition from Gene Wilson, at al. requesting
annexation of 2.102 acres of territory to the
District in the vicinity of Country Hill Road and
Vista Del Sol in the City of Anaheim; and
consideration of Resolution No. 89-144-2,
authorizing initiation of proceedings to annex
said territory to the District, proposed
Annexation No. 70 - Wilson Annexation to County
Sanitation District No. 2. See pages "N" and
DISTRICT 3
(s) Consideration of motion authorizing the Selection
Committee to solicit a proposal and negotiate a
Professional Services Agreement with NBS/Lowry
..i Engineers for design and construction services
�.J required re Lampoon Interceptor Sewer, Contract
No. 3-24-2, and Orange-Western Subtrunk Relief
Sewer, Contract No. 3-25.
-7-
10/11/89
(15) ALL DISTRICTS
C osed Session: During the course of conducting the
sineu� ss set forth on this agenda as a regular
meeting of the Boards, the Chairman may convene the
Boards in closed session to consider matters of
pending or potential litigation, or personnel
matters, pursuant to Government Code Sections 54956.9
or 54957.6.
Reports relating to (a) purchase and sale of real
property; (b) matters of pending or potential
litigation; (c) employee compensation; or which are
exempt from public disclosure under the California
Public Records Act, may be reviewed by the Boards
during a permitted closed session and are not
available for public inspection. At such time as
final actions are taken by the Directors on any of
these subjects, the minutes will reflect all required
disclosures of information.
(a) Convene in closed session, if necessary
(b) Reconvene in regular session
(c) Consideration of action, if any, on matters considered
in closed session.
(16) ALL DISTRICTS
Ot e�i r u—siness and communications or supplemental agenda
items, if any
(17 ) DISTRICT 1
Ot�T)u-s-iness and communications or supplemental agenda
items, if any
(18) DISTRICT 1
Consideration of motion to adjourn
(19 ) DISTRICT 2
O r usiness and communications or supplemental agenda
items; if any
(20) DISTRICT 2
Consideration of motion to adjourn
(21) DISTRICT 3
OEHer-Fu-s-iness and communications or supplemental agenda
items, if any
(22) DISTRICT 3
Conssi eration of motion to adjourn
(23) DISTRICT 5
ot�-er-business and communications or supplemental agenda
items, if any
-14-
10/11/89
(14) DISTRICTS 1,2,3,5,6,7,11 & 13 (Continued from page 12)
(g) DISTRICT 6
ConSicTe—ration of the following actions relative to
proposed Ordinance No. 615, An Ordinance of the Board of
Directors of County Sanitation District No. 6 of Orange
County, California, Amending Ordinance No. 614
Establishing Wastewater Discharge Regulations for Use of
District Sewerage Facilities:
(1) Consideration of motion to read Ordinance
No. 615 by title only and waive reading of said
entire ordinance (must be adopted by unanimous
vote of Directors present) .
(2) Consideration of roll call vote motion adopting
Ordinance No. 615.
(h) DISTRICT 7
Cons Teration of the following actions relative to
proposed Ordinance No. 723, An Ordinance of the Board of
Directors of Cot:nty Sanitation District No. 7 of Orange
County, California, Amending Ordinance No. 722
Establishing Wastewater Discharge Regulations for Use of
District Sewerage Facilities:
(1) Consideration of motion to read ordinance
No. 723 by title only and waive reading of said
entire ordinance (must be adopted by unanimous
vote of Directors present) .
(2) Consideration of roll call vote motion adopting
Ordinance No. 723.
(i) DISTRICT 11
Consideration of the following actions relative to
proposed Ordinance No. 1111, An Ordinance of the Board
of Directors of County Sanitation District No. 11 of
Orange County, California, Amending Ordinance No. 1110
Establishing Wastewater Discharge Regulations for Use of
District Sewerage Facilities:
(1) Consideration of motion to read Ordinance
No. 1111 by title only and waive reading of said
entire ordinance (must be adopted by unanimous
vote of Directors present) .
(2) Consideration of roll call vote motion adopting
Ordinance No. 1111 .
(j ) DISTRICT 13
ConsideraElon of the following actions relative to
proposed Ordinance No. 1306, An Ordinance of the Board of
Directors of County Sanitation District No. 13 of Orange
County, California, Amending Ordinance No. 1305
Establishing Wastewater Discharge Regulations for Use of
District Sewerage Facilities:
(1) Consideration of motion to read Ordinance
No. 1306 by title only and waive reading of said
entire ordinance (must be adopted by unanimous
vote of Directors present) .
(2) Consideration of roll call vote motion adopting
Ordinance No. 1306.
-13-
10/11/89
(15) ALL DISTRICTS
Closed Session: During the course of conducting the
�ussiness et forth on this agenda as a regular
meeting of the Boards, the Chairman may convene the
Boards in closed session to consider matters of
pending or potential litigation, or personnel
matters, pursuant to Government Code Sections 54956.9
or 54957 .6 .
Reports relating to (a) purchase and sale of real
property; (b) matters of pending or potential
litigation; (c) employee compensation; or which are
exempt from public disclosure under the California
Public Records Act, may be reviewed by the Boards
during a permitted closed session and are not
available for public inspection. At such time as
final actions are taken by the Directors on any of
these subjects, the minutes will reflect all required
disclosures of information.
(a) Convene in closed session, if necessary
(b) Reconvene in regular session
(c) Consideration of action, if any, on matters considered
in closed session.
(16 ) ALL DISTRICTS
0 er usiness and communications or supplemental agenda
items, if any
(17) DISTRICT 1
Ornusiness and communications or supplemental agenda
items, if any
(18) DISTRICT 1
ConsiTe—ration of motion to adjourn
(19) DISTRICT 2
Ofier-Susiness and communications or supplemental agenda
items; if any
(20) DISTRICT 2
Consi eration of motion to adjourn
(21 ) DISTRICT 3
Ot er usiness and communications or supplemental agenda
items, if any
(22) DISTRICT 3
Consi oration of motion to adjourn
(23) DISTRICT 5
0 er usiness and communications or supplemental agenda
items, if any
-14-
10/11/89
(24) DISTRICT 5
Consideration of motion to adjourn
(25) DISTRICT 11
Offer Yusiness and communications or supplemental agenda
items, if any
(26) DISTRICT 11
Condon of motion to adjourn
(27 ) DISTRICT 13
Other business and communications or supplemental agenda
items, if any
(28) DISTRICT 13
Consideration of motion to adjourn
(29) DISTRICTS 6 7 & 14
Consi eration of he following actions relative Supplement
No. 1 to Environmental Impact Report for Proposed Formation
of County Sanitation District No. 14 and Proposed
Reorganization No. 79 Involving Reorganization of Districts
Nos. 7 and 13 re Baker-Gisler Interceptor, Contracts
Nos. 14-1-1A and 14-1-1B, and Baker Force Mains, Contract
No. 14-1-2, required to assess the impacts resulting from the
final designed alignment of said projects:
(a) verbal staff report
(b) Consideration of motion to receive and file Initial
Study and Environmental Impact Assessment, which
assesses the impacts of the changed alignment of said
sewers necessitating the use of public and private
easements and increasing the size of pipe from 72 inches
to 90 inches, finding that additional documentation and
preparation of Supplement No. 1 to said EIR is necessary
to satisfy CEQA requirements. See pages "Y" and
'.z,.
(c) Consideration of motion declaring intent to prepare and
circulate for public review Notice of Preparation of
Supplement No. 1 to said EIR, in compliance with CEQA
regulations.
( 30) DISTRICT 6
Ott business and communications or supplemental agenda
items, if any
( 31 ) DISTRICT 6
Consideration of motion to adjourn
-15-
10/11/89 `
( 32) DISTRICT 7
Ot Es-
t business and communications or supplemental agenda
items, if any
(33) DISTRICT 7
Consideration of motion to adjourn
(34) DISTRICT 14
Other business and communications or supplemental agenda
items, if any
(35) DISTRICT 14
Consideration of motion to adjourn
-16-
MANAGER'S AGENDA REPORT
County Sanitation Districts P.O. Box 8127•10844 EIIISAvenue
of Orange County, California Fountain Valley,CA 92728.8127
Telephone;(714)962-2411
JOINT BOARDS
Meeting Date
October 11, 1989 at 7:30 p.m.
The following is a brief explanation of the more important, non-routine
items which appear on the enclosed agenda and which are not otherwise
self-explanatory. Warrant lists are enclosed with the agenda material
summarizing the bills paid since the last Joint Board meeting.
ALL DISTRICTS
9(a): AWARD PURCHASE OF CHLORINE IN BULK, SPECIFICATION NO. C-025.
Aunnually, the Districts use six to seven thousand tons of bulk chlorine
for odor control in a system consisting of one centralized 25-ton tank and
associated distribution equipment at Plant No. 1; and two centralized 25-tan
tanks and related distribution piping and equipment at Plant No. 2. (The
Districts also use approximately 600 tons of chlorine purchased annually in
one-tan cylinders, under separate contract, as backup for the bulk stations and
for remote areas of the plants with lower usage rates. See following agenda
Item.)
Our bulk chlorine usage has stabilized at about 6,300 tons per year for
odor mitigation. The estimated usage represents a 700 ton reduction from the
current contract period due to the installation of the primary basin covers and
air scrubbers.
On September 5, sealed bids were received for supplying bulk chlorine for
a one-year period beginning November 1, 1989, with option to renew for one
additional year. Two bids were received. The low bidder was Olympic Chemical
Company at $212.70 per ton, plus sales tax. This represents a $33.20 (18.5%)
per ton price increase over the 1988-89 contract price. It is worth noting that
the chlorine market has been unstable over the past few years. The price per
ton to 1988-89 was $179.50 per ton and during the 1987-88 contract year it was
$209.40.
Staff recommends award of a contract to Olympic Chemical Company for
Purchase of Chlorine in Bulk for the unit price of $212.70 per ton, plus sales
tax, for a one-year period, with option for a one-year extension under mutually
..i agreeable terms. Estimated annual cost for the new contract, based on 6,300
tons, is $1,340,010.00, plus sales tax.
October 11, 1989
9(b): AWARD PURCHASE OF CHLORINE IN ONE-TON CYLINDERS, SPECIFICATION NO. C-026.
One-ton chlorine cylinders are used for odor control in remote areas of
the plants with low usage rates. They are also used as backup in case of
emergency shutdowns of the bulk chlorine system.
On September 5, four bids were received to furnish and deliver chlorine
in one-ton cylinders for a one-year period beginning November 1, 1989. The bids
varied from a high of $375.00 to a low of $265.00 per ton, exclusive of sales
tax, submitted by Continental Chemical Company. The bid price is $20.50 (3.8%)
per ton lower than the expiring contract.
Staff recommends that award of the Purchase of Chlorine in One-ton
Cylinders for a one-year contract period be made to Continental Chemical Company
for a unit price of $265.00 per ton, plus sales tax, with option for a one-year
extension under mutually agreeable terms. The annual quantity of chlorine to be
purchased in one-ton cylinders based on a projected usage of 600 tons,
represents an estimated cost of $159,000.00, plus sales tax.
9(c): APPROVE DISTRICT CONSENT TO ASSIGNMENT OF LEASE, SPECIFICATION NO. L-013.
The Districts lease a 50' x 3,900' parcel over its Plant No. 1 outfall
right-of-way adjacent to the Santa Ana River to Miya Wholesale Nursery to grow
ornamental landscape plants. The annual revenue is nominal but the Districts
are able to avoid maintenance costs on the right-of-way.
Miya Wholesale Nurseries sold their business to Village Nurseries and has
requested Districts consent to the assignment of lease. Village Nurseries has
accepted the lease in its entirety without modification. The Districts, consent
should be granted.
9(d): APPROVE CHANGE ORDER NO. 12 TO ADMINISTRATION BUILDING ADDITION JOB
J- -4.
Job No. J-7-4, Administration Building Addition, includes the
construction of a new administration building addition and remodeling of the
existing administration building, addition of two new parking areas and
associated work at a cost of $3,549,000.00. Change Order No. 12 adds $4,530.00
to the contract with J. R. Roberts Corporation.
Item 1 directs the contractor to furnish and install a low voltage
lighting panel in the new South Wing to facilitate independent operation of
lighting and fan circuits in the bathrooms, and 50 light switch box extensions
for interior partition office walls. These changes add $2,851.00. Item 2
provides for installation of additional ceramic tile in the new South Wing
bathrooms to finish around the light switch boxes and towel dispensers where
they protrude above the tile wainscot. These changes add a cost of $664.00.
Item 3 directs the contractor to make several changes to the plumbing in the new
South Wing. The changes were requested by staff and included adding vending
machine water valves, rerouting a sink drain line vent to avoid electrical
boxes, and relocation of water lines under air handling units that conflicted
with new roof trusses. This change resulted in an additional cost of $1,015.00
to the contract.
-2-
October 11, 1989
The above-described changes are considered by staff to be corrections
which would have been included in the original design If known prior to its
completion. None of the items are for replaced work.
Staff recommends approval of Change Order No. 12 adding $4,530.00 to the
contract with J. R. Roberts Corporation. There is no time extension associated
with this change order.
9(e): APPROVAL OF CHANGE ORDER NO. 20 TO OCEAN OUTFALL BOOSTER STATION "C" AT
PLANT NO. 2, JOB N -1 .
The new $28.5 million master-planned Ocean Outfall Booster Station "C" at
Plant No. 2, Jab No. J-15, is being built under several contracts. It includes
five pumps, each capable of pumping 120 mgd to the outfall . The capacity of the
station is 480 mgd with four pumps operating (the fifth pump is a standby, spare
pump). This project is nearly complete and is now in the testing/start-up
phase. Change Order No. 20 adds $17,165.82 to the contract.
Item 1, at a cost of $6,473.00, provides for the unloading of two
sections of the 120-inch diameter pipe and hauling to a remote area of the plant
for sandblasting and spray painting, and relocating the pipe for final
placement. This was done to avoid any damage to operating outfall pumping
equipment. Item 2 provides for installation of temporary power needed for
heating equipment to protect stored electrical equipment, at a cost of
$1,835.82. Item 3 is for a back-up power source, not provided in the contract
specifications, for the bubbler panels used to control pump station wet well
depths in the event of computer system failure, at a cost of $1,802.00. Item 4
is the installation of two filters required due to harmonic distortions in
electrical circuits of newly installed equipment, at a cost of $1,696.00.
Item 5 is for placement of a permanent, movable handrail around the four roof
skylights as a safety measure, at a cost of $1,806.00. Item 6 is for closing
two open holes in the main level floor created because the penetrating
electrical cable trays are smaller than the opening, at a cost of $928.00.
Item 7 provides for connecting an alarm for the air conditioning system to the
computer control system which is vital for maintaining proper operating
environment for variable frequency drive units, at a cost of $2,625.00.
The above-described changes are considered by staff to be corrections
which would have been included in the original design if known prior to its
completion. None of the items are for replaced work.
Staff recommends approval of Change Order No. 20 adding $17,165.82 to the
contract with Advanco Constructors, Inc. There is no time extension associated
with this change order.
9(f) : APPROVAL OF CHANGE ORDER NO. 22 TO HEADWORKS NO. 2 AT PLANT N0. 1
B N . P1-2 ; AND DEMOLITION DICE TER- NO 1, 2 AND 4; REPLACEMENT
F BOILER; PIPIN LEANOUT-; AND GRADING AN PAVIN AT PLANT NU. 2,
JOB NO. P1-31.
Job No. P1-20, Headworks No. 2 at Plant No. 1, and Job No. P1-31,
Demolition of Digesters Nos. 1, 2 and 4; Replacement of Boiler, Piping
Cleanouts; and Grading and Paving at Plant No. 1, includes the construction of a
-3-
October 11, 1989
new 140 million gallon per day influent pumping plant and preliminary treatment
facilities at a cost of $31,458,000.00. Change Order No. 22 adds $25,662.11 to
the contract.
Item 1, in the amount of $1,198.70 for Job No. PI-31, is the installation
of a digester gas flow meter at the boiler digester gas supply piping. This
flow meter, required by the South Coast Air Quality Management District, was
purchased separately by the Districts and installed by the contractor.
For Job No. P1-20, Item 1 is the addition of a walkway landing pad
between the splitter box catwalk and the existing headworks roof to resolve a
conflict between elevations, and was added at a cost of $477.86. Item 2, in the
amount of $1,956.29, is the addition of a drain line at the Sunflower Pump
Station. The new drain line is needed to drain a trench of future periodic
washdown water and was not provided for in the contract. Item 3, in the amount
of $7,726.32, is for a change in the chlorine solution piping at the splitter
box. Three chlorine solution lines are in conflict with the installation of a
stop plate at the splitter box roof. The 6-inch diameter chlorine solution
piping will be rerouted outside the parapet wall to avoid this conflict.
Item 4, in the amount of $2,670.61, is for the substitution of an access ladder
at the belt conveyor catwalk for the contract-specified stairway which was found
to be in conflict with the electrical conduit and the roll-up door at the south
side of the barscreen building. (The price includes a credit for deleting
installation of the stairway.)
Item S. in the amount of $689.47, is the modification of a stile-type
stairway at Tunnel No. 1 which was fabricated 48 inches in width per the
contract drawings but conflicted with the clear tunnel opening between the
vertical pipe supports. Item 6, in the amount of $474.02, is the modification
of a cover at the piping trench between the Sunflower Pump Station and Tunnel
No. 1 due to the need for additional reinforcement for vehicle crossing (N-20
loading) on all piping trench covers. Item 7, in the amount of $3,519.29, is
the addition of a cover plate at the Sunflower Pump Station. The cover, over an
opening in the discharge channel , is required to maintain odor control in the
area. It was not shown in the contract drawings. Item 8, for $5,949.55, is for
modifications at the foul air scrubbing area control panels for safety. The
needed fiberglass grating and aluminum kick plates were not included in the
contract drawings. Item 9, in the amount of $1,000.00, is for modifications to
the chlorine gas leak detector supports at the Chlorine Building area. The
detectors are mounted outside of the Chlorine Building and need support
modifications due to the addition of weather-proof housings an each of the
detectors. The housings increased the weight of the originally specified
detector units thus requiring the support change.
Most of the above-described which would have been included in the
original design if discovered or known in design. Items 3, 4 and 5 include
design errors which contributed to the cost.
Staff recommends approval of Change Order No. 22 for a net addition of
$25,662.11 to the contract with Kiewit Pacific Co. There is no time extension
associated with this change order.
v
-4-
October 11, 1989
9(g) : APPROVE CHANGE ORDER NO. 19 TO COVERS FOR PRIMARY BASINS AT PLANT NO. 1,
JOB NO. P1-25; FOUL AIR SCRUBBER SYSTEM AT PLANT NO. 1, JOB NO. P1- 6;
...y COVERS FOR PRIMARY BASINS AT PLANT NO. 2, JOB N0. P2-32• FOUL AIR
SCRUBBER SYSTEMS AT PLANT N0. 2'
JOB NO. P2- 3• AND IMPROVEMENTS TO GRIT
FACILITY "B", BIL INGS TUNNEL ND DISTRIBUTION bIKULIUKh "A", JOB NU.
P2- 4.
In September 1987 the Directors awarded a contract for construction of
odor control facilities at Treatment Plants Nos. 1 and 2, Jobs No. P1-25, PS-26,
P2-32, P2-33, and P2-34, which provides for domes over all primary clarifier
basins, as well as associated work. The malodorous air will be collected and
deodorized. This $20 million project is nearly complete and is in the testing
and start-up phase. Change Order No. 19 provides for seven items of
miscellaneous changes and adds $58,245.54 to the contract.
Item 1, in the amount of $6,860.00, provides for the removal of a portion
of existing conduits, wiring and equipment that interfered with the installation
of the new flat covers at Primary Clarifiers "A", "B", and "C". New conduits,
wiring and existing electrical equipment were reinstalled after the new covers
were in place. Item 2, in the amount of $4,609.00, provides for the relocation
of existing lighting standards that were located on the center access bridges of
Clarifiers "D", "E", "F", and "G" and interfered with the installation of the
new dome covers at the clarifiers. Item 3, in the amount of $2,215.33, provides
for the substitution of insulated grounding cable and grounding lugs at all
clarifier basins, to lieu of bare copper cable and attaching lugs, to minimize
corrosion.
Item 4, in the amount of $21,899.41, provides for the installation of
Oritex wear surface at each support for overhead FRP ductwork to eliminate
erosion of the ductwork caused by expansion and contraction from the elements of
weather. Item 5, in the amount of $14,722.44, provides for the installation of
a 24-inch foul air vent on the underground primary effluent system at Plant
No. 2 to withdraw odorous gases from that system and provides for the
installation of a new 1-inch underground sampling line at Junction Box "A" to be
used for effluent sampling under a future contract. Item 6, in the amount of
$1,500.00, provides for the repair of the 42-inch RCP influent line to Clarifier
"I" that was shown incorrectly on "as-built" drawings and damaged by the
contractor during pile driving operations. Item 7, in the amount of $6,439.36,
changes the hold down anchors for new tread plates in Headworks "C" from
protruding stud bolts to flat head screw anchors to eliminate a tripping hazard.
The above-described changes are considered by staff to be corrections
which would have been included in the original design if known prior to its
completion. None of the items are for replaced work.
Staff recommends approval of Change Order No. 19 for an addition of
$58,245.54 to the contract with Advanco Constructors, Inc. There is no time
extension associated with this work.
9(h): APPROVAL OF CHANGE ORDER NO. 5 TO ENTRANCES, SITE SECURITY AND INTERIOR
ROAD IMPROVEMENTS PLANT NO. 1, JOB NO. P1-27.
Job No. P1-27, Entrances, Site, Security and Interior Road Improvements
at Plant No. 1 includes a new front entrance opposite the southbound 405 freeway
.,� off/on ramps and a new Wastehauler Dump Station. Change Order No. 4 consists of
five items of work for a net addition of $6,787.15.
-5-
October 11, 1989
Item 1, for $1,353.29, is for additional transformers and electrical
wiring at the two card readers associated with Entrance Gates No. 1 and No. 5.
The 9-volt power source required for proper card reader operation was omitted
from the contract drawings. Item 2, in the amount of $2,353.55, is for the
installation of a Districts-furnished multiplexer to allow for communications
between the present card readers, future card readers and the card-key
controller. This item was required to enhance proper operation of the entrance
gates and to provide capacity for expansion of controls on the entire gate
system. Item 3, for $1,552.93, is for replacement to the Wastehauler Building
landscaped area. During installation of the Districts-furnished trees to the
referenced area, damage occurred to the landscaping and repairs were required.
Item 4, in the amount of $772.40, is for the replacement of the
contract-specified 120-volt relays with 24-volt relays. This change was
required due to excessive voltage drop. Item 5, for $754.98, involves
modification of CALTRANS signs within the plant to conform with Districts'
In-plant standard sign heights. Also, the Ellis Avenue westerly left turn
pocket was re-striped to allow for a one-week delay in the closing of the
existing main entrance.
The above-described changes are considered by staff to be corrections
which would have been included in the original design if known prior to its
completion.
Staff recommends approval of Change Order No. 5 for an addition of
$6,787.15 to the contract with Kiewit Pacific Co. There is no time extension
associated with this change order.
9(1): APPROVAL OF CHANGE ORDER NO. 5 TO MISCELLANEOUS MODIFICATIONS AND
IMPROVEMENTS TO FACILITIES AT TREATMENT PLANT NO. 2. JOB NO. P - 7.
This project includes 38 non-related items of rehabilitation and repair
work at Plant No. 2. Major items Include replacement of the domes on Digesters
A and B, built in the early 19501s; replacement of two influent pumps at
Headworks C; the installation of replacement barscreens at Headworks C;
replacement of grit augers; screening conveyors; chlorine system piping and
waste activated sludge pumps; new primary influent flow meters; and waste
activated sludge bypass piping. Change Order No. 5 adds $77,047.00 for one
item of additional work, plus payment of a bonus for early completion of
digester work.
Item 1, in the amount of $55,047.00, provides for the placement of sloped
fill concrete in Digesters A and B which will improve the flow characteristics
of sludge recirculation and reduce the amount of periodic maintenance work.
Item 2, in the amount of $22,000.00, is a bonus payment to the contractor for
early completion of the work at Digesters A and B.
Staff recommends approval of Change Order No. 5 adding $77,047.00 to the
contract with Ziebarth and Alper. There is no time extension associated with
this change order.
9(j): ACCEPTANCE OF CLEANING OF DIGESTERS 7 AND 8 AT PLANT NO. 1 JOB NO.
P1- -1-1, AS COMPLETE.
Dorado Enterprises has fulfilled all contractual obligation within the
specified contract time for Cleaning of Digesters 7 and 8 at Plant No. 1.
-6-
October 11, 1989
Staff recommends adoption of the resolution attached to the agenda
material authorizing acceptance of the work as complete, execution of the Final
Closeout Agreement and filing of the Notice of Completion as required. The
final project cost is $171,000.00
9(k): AUTHORIZE SELECTION COMMITTEE TO NEGOTIATE ADDENDUM NO. 2 TO PROFESSIONAL
SERVICES AGREEMENT MITH 0 N AROLLO ENGINEERS RE DIGESTERS NOS. 11-I6
AND GAS HANDLING FACILITIES AT RECLAMATION PLANT NO. 1, JOB NO. P1- 4.
In February 1988, the Directors awarded a professional services agreement
to John Carollo Engineers for the design of digesters, gas handling facilities
and sludge handling facilities at Reclamation Plant No. 1. Subsequently, under
Addendum No. 1, the job was divided into two contracts; Job No. P1-34-1 for
digesters and gas handling facilities, and Job No. P1-34-2 for sludge handling
facilities. Several developments have occurred which require that work be
performed by the engineer which is beyond the scope of the original agreement
and Addendum No. 1, including revisions to the plans and specifications;
additional design services to include two more sludge cake storage silos for
increased system reliability, and modifications to the design to coordinate with
other projects; and extra construction services.
Based on the Financial Plan included in the recently-approved Action
Plan, staff recommends separating Digesters Nos. 11-16 and Gas Handling
Facilities at Reclamation Plant No. 1, Job No. P1-34-1 into two separate jobs,
Gas Handling Facilities at Reclamation Plant No. 1, Job No. P1-34-1, and
Digesters Nos. 11-16 at Reclamation Plant No. 1, Job No. P1-34-3. This will
allow better phasing of the projects consistent with budgeting and cash flow
expectations for the massive new master-planned construction program set forth
in 02020 VISION".
Changing the project from one set of plans and specifications to two sets
requires extra engineering work. Additional design services are also required
to increase the number of sludge cake storage silos to provide the system
reliability required by the Districts.
This year's budget authorized additional staff engineering positions to
assume some of the rising construction management effort associated with our
extensive construction of master-planned facilities. However, we are having
difficulty recruiting qualified engineers. It is, therefore, necessary to also
request additional construction support from Carollo. Specifically, staff is
requesting that Carollo attend weekly construction meetings for all three
contracts, provide support in evaluating plan changes received from the various
contractors once the projects are under construction, review equipment
submittals, additional speciality inspection services, and assistance in
coordinating the work with other construction projects.
Staff is therefore recommending that the Selection Committee be authorized
to negotiate Addendum No. 2 for the additional engineering services set forth
above. Following the Selection Committee negotiations, the proposed addendum
will be presented to the Boards for consideration.
`/ -7-
October 11, 1989
9(1): AUTHORIZING THE SELECTION COMMITTEE TO NEGOTIATE A PROFESSIONAL
SERVICES AGREEMENT WITH EMA, INC. FOR PREPARATION OF PLANS AND
PE I I A IONS FOR REPLACEMENT OF COMPUTERIZED MONITORING SYSTEM AT PLANT
NO, 2, J B NO. P2-44.
The Master Plan as approved by the Boards of Directors in July 1989,
determined the need for implementation of a new computerized distributed control
system at Plant No. 2. The existing data acquisition system at Plant 2,
Installed in 1976, is becoming more expensive to maintain and less reliable
since parts are no longer manufactured. Repair parts must be located on the
used equipment market or in a third party's inventory. Control Data Corp.
training or staffing is no longer available for repairs or maintenance.
Design for the Plant 1 Control Center Instrumentation, Job No. J-23-2, is
underway by EMA, Inc. EMA, Inc. has demonstrated an excellent ability to
document facilities as currently configured, integrate a data acquisition system
into the existing Plant 1 facilities, and specify systems which satisfy Master
Plan requirements. Advantages of using EMA, Inc. for parallel design of the
data acquisition system at Plant 2 are commonality of equipment and operation,
consistency of personnel training for similar systems, and staffing flexibility
between plants. In addition, design cost savings should be realized since EMA
already is performing similar work, is familiar with Districts' needs and can
thus reduce the "learning curve" time.
Staff therefore recommends that the Selection Committee be authorized
to negotiate an agreement with EMA, Inc. for the design of Replacement of
Computerized Monitoring System at Plant No. 2, Job No. P2-44. Following the
Selection Committee's negotiations, the agreement will be presented to the
Boards for consideration.
9(m) : AUTHORIZE SELECTION COMMITTEE TO SOLICIT PROPOSALS AND NEGOTIATE A
PROFESSIONAL SERVICES AGREEMENT RE USER AND CONNECTION FEE TU Y.
The Districts' "2020 VISION" Action Plan projects that connection fees
from new development will finance approximately one-half of the Districts'
capital requirements over the next 30 years and the balance will be funded by
borrowing in the debt market.
Our allocation of property taxes pursuant to Proposition 13 now finances
approximately 58 percent of our annual operation and maintenance costs.
Supplemental use fees finance the major portion of the balance of the operation
and maintenance costs. Because property tax revenues are limited by
Proposition 13, future increases in operations and maintenance costs will , for
the most part, be funded by increasing use fees. Use fees will also be the
primary source of funds for debt service and retirement.
The present connection fee structure provides two categories--residential
and commercial . Use fees are categorized into single family dwellings, multiple
family dwellings and non-residential buildings. Because of changing conditions
and requirements, and our increasing reliance on fees for financing future
activities, staff is recommending that a consultant be engaged to study the
various user categories to determine the appropriate schedule of fees and user
classes to ensure that the charges for each property are as equitable as we can �,
make them. The study would not only determine the categories but also conduct
-8-
October 11, 1989
flow measurements in the field to determine typical flows from various types of
properties. The study would also review our industrial waste user fee
calculation procedures.
Once the Selection Committee has negotiated an agreement it will be
submitted to the Boards for consideration.
9(n): APPROVING ADDENDUM NO. 1 TO AGREEMENT WITH ARTHUR YOUNG AND COMPANY.
The Orange County Assessor's Office has provided data processing support
for the various Sanitation Districts' supplemental use fee programs for the past
several years. This support has been required to calculate the annual
supplemental use fee for each parcel based upon number of residential units, or
square footage for non-residential properties, and to prepare a billing tape for
the County Auditor to include the charge on the property tax bills. The
Districts pay the Assessor for the cost of providing this service.
Because of recent changes to the Assessor's data base and computer
system, in January 1989 the Directors authorized an agreement with Arthur Young
and Co. to develop and implement required new computer programs to determine and
to assess annual supplemental use fees. This work was completed within the
authorized budget and the fees will be collected on the 1989-90 tax bills.
Discussions with the Assessor's staff during the development process made
it clear to them that some changes and enhancements would be required within
their software to facilitate data transfers to other agencies such as the
Sanitation Districts. Accordingly, the Assessor's staff has asked the Districts
to have Arthur Young make those improvements while they are working with the
system. This is a prudent approach as the Districts' programs will also require
modification as a result of the improvements to the Assessor's programs.
Staff is therefore requesting approval of Addendum No. 1 to the agreement
with Arthur Young to accomplish the work requested by the County Assessor for an
amount not to exceed $37,180.00. This will increase the agreement for services
with Arthur Young from $161,882.00 to $199,062.00. All costs incurred to modify
the Assessor's programs will be deducted from the Assessor's billing for the
property tax database information.
9(o): DISPOSAL OF CLASSIFIED MATERIALS/WASTE UNDER COUNTY OF ORANGE COOPERATIVE
AGREEMENT.
As part of our regular wastewater treatment plant operating and
maintenance activities we use materials and generate certain wastes that are
subject to regulation under the Resource Conservation and Recovery Act (RCRA).
These materials and wastes require special handling pursuant to an operations
plan required of the Districts by RCRA.
The staff has completed the following steps in compliance with these
requirements:
1. Identified types and quantities of classified materials/waste
generated within each department.
2. Constructed a central collection and storage facility for these
materials at Plant No. 1.
-9-
October 11, 1989
3. Provided for the regular collection and storage of materials for
disposal from the two treatment plants and other Districts' facilities.
To dispose of this classified waste in the most economical manner, the
staff is recommending that the Districts join in an existing County of Orange
Cooperative Agreement for disposal of the classified materials/waste. The
County has entered into an agreement with Containerized Chemical Disposal , Inc.
to provide for these disposal services for itself and participating cities and
other agencies in the County. We are required to dispose of the wastes on a
quarterly basis and the estimated annual cost is not expected to exceed
$100,000.00 based on approximately 22 tons of waste.
It is recommended that a purchase order be authorized to Containerized
Chemical Disposal , Inc. for disposal of the Districts' classified waste now
stored on site, and for disposal of waste generated between now and May 31,
1990, the expiration date of the County's contract. The County has the option
to renew the contract for two years, however, the Districts could withdraw from
the Joint participation agreement at any time if it is deemed desirable to do
SO.
DISTRICT 2
9(p) : APPROVE CHANGE ORDER NO. 1 TO THE PLANS AND SPECIFICATIONS FOR PORTION OF
HE EUCLID INTERCEPTOR E E BETWEEN EDINGER AVENUE AND LAMP
MMIKALI N ANO bUU1h ANAH IM RELIEF EWER N BALL R AD B TW EN
U L D R A D ALN TR E NTRA T NO. -27.
This project is the construction of vitrified clay and reinforced
concrete gravity sewer relief lines. The contracts, a Portion of the Euclid
Interceptor Sewer, between Edinger Avenue and Lampson Avenue, Contract No.
2-26-2, and the South Anaheim Relief Sewer, on Ball Road between Euclid Street
and Walnut Street, Contract No. 2-27, were awarded to W. H. Ebert Corporation of
San Jose in March 1989, in the amount of $9,242,538.00, and are located within
the Cities of Anaheim, Garden Grove, Santa Ana and Fountain Valley.
Change Order No. 1, in the amount of $98,532.00, is for additional
asphalt paving in Ball Road between Euclid Street and Walnut Street (Contract
No. 2-27). The contract documents indicated that 800 tons of asphalt would be
required on Ball Road. However, an additional 1610 tons were actually needed to
replace the asphalt removed for the construction of the new vitrified clay pipe
because the consulting design engineer made a quantity mistake in calculation.
The original bid price for the work was $92.00 per ton of asphalt. But, because
of the large overrun, staff negotiated a price of $61.20 per ton for the
additional asphalt paving. The reduced unit price saves $49,588.00.
Staff recommends approval of Change Order No. 1 adding $98,532.00 to the
contract with W. H. Ebert Corporation. There is no time extension associated
with the work.
9(q): AUTHORIZING REIMBURSEMENT AGREEMENT WITH THE CITY OF ANAHEIM FOR
INCLUSION - NDED IMPROVEMENTS TO EU LID STREET TO BE INCLUDED IN
PORTION EUCLID INTERCEPTOR SEWER, CONTRACT NO.
The Directors have previously authorized design of the new Euclid
Interceptor by phases between the Fountain Valley reclamation plant and
-10-
October 11, 1989
Orangethorpe Avenue in the City of Fullerton. Contract No. 2-26-3, Portion of
Euclid Interceptor Sewer between Broadway and Orangethorpe Avenue, is now under
design by Willdan Associates. Another portion of the Euclid Interceptor,
immediately south of Contract No. 2-26-3, is now under construction by the City
of Anaheim pursuant to a cooperative agreement between the District and Anaheim.
Anaheim is administering the project which includes the construction of city
storm drain and street improvements.
The City of Anaheim has requested that the District include in Contract
No. 2-26-3 the construction of street improvement items to Euclid Street
between La Palma Avenue and the 91 Freeway, the northerly city boundary. The
District will administer the city-designed project and be reimbursed for
construction and inspection costs under the proposed cost-sharing agreement.
The action appearing on the agenda is to authorize preparation of an
agreement with the City of Anaheim for the joint construction of Portion of
Euclid Interceptor Sewer, between Broadway and Orangethorpe Avenue, Contract
No. 2-26-3, and City of Anaheim Euclid Street Maintenance Project between La
Palma Avenue and the 91 Freeway, to be executed by the Chairman in a farm
approved by General Counsel.
9(r): INITIATING ANNEXATION NO. 70 - WILSON ANNEXATION TO COUNTY SANITATION
DISTRICT NO. 2.
The District has received a request from Walter Posey, Gene Wilson and
V. A. Bauerlein to annex 2.102 acres of territory in the vicinity of Country
Hill Road and Vista Del Sol in the City of Anaheim. There are currently two
single family residences under construction on this parcel . The City of Anaheim
is the local sewering entity. The annexation would be in accordance with the
terms of the negotiated agreement with the County of Orange re AB 8 tax
exchanges for annexing properties.
Staff recommends approval of the resolution included with the agenda
material initiating proceedings for said Annexation No. 70.
DISTRICT 3
9(s): AUTHORIZING SELECTION COMMITTEE TO SOLICIT A PROPOSAL AND NEGOTIATE A
PROFESSIONAL SERVICES AGREEMENT WITH NBS LOWRY ENGINEERS FOR DESIGN AND
CONSTRUCTION SERVICES RELATIVE TO LAMPSON INTERCEPTOR SEWER, CONTRACT NO.
-24-2 AND ORANGE-WESTERN SUBTRUNK RELIEF SEWER, CONTRACT NO. 3-25.
Proposed is the preparation of updated plans and specifications for the
construction of the Lampson Interceptor Sewer, Contract No. 3-24-2, and the
Orange-Western Subtrunk Relief Sewer, Contract No. 3-25. The plans and
specifications for portions of bath projects were originally prepared in 1983;
however, the projects were not constructed pending further review of drainage
and development plans. That review has now been completed as part of the
recently-adopted 1989 Master Plan.
The 1983 plans were prepared by Lowry & Associates. Staff is proposing
that the Selection Committee be authorized to negotiate with the successor of
that firm, NBS/Lowry Engineers, for the updates in accordance with the 1989
Master Plan.
-11-
October 11, 1989
The Lampson Interceptor Sewer was proposed to extend from the Knott
Interceptor in Lampson Avenue to Western Avenue; it is now proposed to extend an
additional 1.000 feet easterly to Santa Rosalie Street.
The Orange-Western Subtrunk Relief Sewer is proposed to extend from the
Knott Interceptor easterly in Crescent Avenue to intercept the existing
Orange-Western Subtrunk Sewer in Western Avenue. A 21-inch sewer was envisioned
in 1983; the 1989 Master Plan proposes a 27-inch sewer.
Since NBS/Lowry prepared the original plans, the updates and the
extensions could most logically be accomplished by the same firm. The staff is,
therefore, recommending that the Selection Committee be authorized to solicit a
proposal and negotiate a professional services agreement to provide the
necessary design and construction services. Following the Selection Committee's
negotiations, the agreement will be presented to the Board for consideration.
9(t) : ACCEPTANCE OF MANHOLE ADJUSTMENTS AND STREET REPAIRS ON KNOTT INTERCEPTOR
EWER, CONTRA O. -34R, AS COMPLETE.
Mladen Buntich Construction Company has fulfilled all contractual
obligation within the specified time for construction of Manhole Adjustments and
Street Repairs on Knott Interceptor Sewer, Contract No. 3-34R.
Staff recommends adoption of the resolution attached to the agenda
material authorizing acceptance of the work as complete, execution of the Final
Closeout Agreement and filing of the Notice of Completion as required. The
final project cost is $369,010.00
9(u): RECEIVE FILE AND REFER TO GENERAL COUNSEL, SUMMONS AND COMPLAINT RE
ESTMINSTER S HOOL DISTRICT V . ALL PERSONS INTERESTED IN AMENDMENT 3 T
THE REDEVELOPMENT PLAN FOR THE WESTMIN TER MMERCIAL REDEVELOPMENT
PR JE NO. 1.
The District has been served with a copy of the Summons and Complaint in
the above-referenced matter wherein the School District is challenging the
Redevelopment Agency of the City of Westminster over the allocation of the tax
increment within the project agency's area. The General Counsel 's office has
contacted the attorney representing the School District and received an open
extension of time in which to file an answer or other responsive pleading in the
case. The effect of this stipulation wherein we do not participate in the
lawsuit is basically to allow the School District and the Redevelopment Agency
to negotiate their own settlement. The General Counsel advises it does not
appear probable that we will ever be involved in this litigation, if
negotiations are successful. In the event the negotiations should totally fail
and the litigation becomes more intense, we will be notified by attorneys for
the plaintiffs, at which time Mr. Woodruff would review it in more detail and
present an analysis, report and recommendation.
The litigation, however, should be received and filed and the matter be
referred to the General Counsel to represent the interests of the District, as
necessary.
-12-
October 11, 1989
DISTRICTS 5 AND 6
�./ 9(v): AWARD CONTRACT FOR REHABILITATION OF BALBOA TRUNK SEWER BETWEEN 32ND
STREET AND CORONADO STREET. CONTRACT N0. 5-27-1 AND INVESTIGATION F
PACIFIC COAST HIGHWAY GRAVITY SEWER, CONTRACT Nut 5-37-2.
Contract No. 5-27-1
The Balboa Trunk Sewer, constructed in 1943, includes approximately
12,700 feet of 15-inch to 24-inch vitrified clay pipe and about 40 manholes.
In June 1987, Robert Bein, William Frost and Associates (RBF), was awarded a
contract to prepare plans and specifications for the rehabilitation of Balboa
Trunk Sewer, between Lido Pump Station and "A" Street Pump Station, Contract
No. 5-27. The first phase of the rehabilitation, Contract No. 5-27, included
chemical sealing of leaking joints and cracks in the sewer which showed severe
seawater infiltration into the line, and the rehabilitation of existing
manholes. It was awarded to Coastline Construction Company in May 1988 and the
project was completed in December 1988 at a cost of $88,200.00. Since this was
a relatively new (and inexpensive) repair method, only portions of the line were
included (although all manholes were repaired) in order to allow an evaluation
of the new process. Our assessment of the repair process is that the original
work was successful .
Contract No. 5-27-1 is the second phase and will consist of sealing the
remaining leaking joints. No manhole repair work will be performed under
Contract No. 5-27-1. The Engineer's estimate of the work is $76,000.00.
Contract No. 5-37-2
County Sanitation Districts 5 and 6 jointly own and operate both pressure
force main and gravity collection systems within Pacific Coast Highway. In
recent years the dual force main system has been completely rehabilitated. The
gravity system, extending from Bitter Point Pump Station (59th Street) easterly
to Dover Drive, collects sewage from lower-lying areas and conveys it to either
the Rocky Point (at the Balboa Bay Club) or Bitter Point Pump Stations where the
sewage is pumped into the force main system for delivery to Plant 2 in
Huntington Beach.
While the force mains were under rehabilitation, the gravity sewer,
constructed in 1936, was exposed at several locations and found to need repair
but a full television inspection of the pipe is needed. The recently-completed
Master Plan sets forth a gravity sewer upsizing and rehabilitation and/or
replacement schedule for future years.
Specifications for Investigation of Pacific Coast Highway Gravity Sewer,
Contract No. 5-37-2, between Dover Drive and Bitter Point Pump Station have been
prepared by Robert Bein, William Frost and Associates (RBF). The video-taped
inspection will determine the condition of the line and locate leaks, cracks and
dips, and verify manhole conditions. The Engineer's estimate for this work is
$54,000.00.
Bid and Award of Joint Project for Contracts 5-27-1 and 5-37-2
Because contractors that perform chemical grouting services also do TV
v inspection, Contract No. 5-27-1 was combined for bidding purposes with Contract
No. 5-37-2.
-13-
October 11, 1989
On September 19, 1989 one bid, submitted by National Plant Services, Inc.
in the amount of $108,321.40, was received for Rehabilitation of Balboa Trunk
Sewer between 32nd Street and Coronado Street, Contract No. 5-27-1 and
Investigation of Pacific Coast Highway Gravity Sewer, Contract No. 5-37-2. A
bid tabulation including the subtotals for Contracts Nos. 5-27-1 and 5-37-2 is
attached to the agenda.
Staff has contacted other firms that took out plans and specifications on
this project but declined to bid and determined that the traffic control
requirements discouraged them from bidding. Staff has worked with the low
bidder on other projects and has been satisfied with their work. Because we are
aware of their capabilities, and the low bid is below the Engineer's estimate of
$130,000.00, it is recommended that the contract be awarded to National Plant
Services, Inc. , the sole bidder, for their bid amount of $108,321.40.
DISTRICT 7
9(w): APPROVAL OF PLANS AND SPECIFICATIONS FOR ABANDONMENT OF LANE ROAD PUMP
STATION, CONTRACT NO. 7-11-1 AND ABANDONMENT OF CASTLEROCK AND DOW
AVENUE PUMP STATIONS AND MODIFICATIONS TO MACARTHUR PUMP STATION,
CONTRACT NO. 7-117 .
In April 1988, the Directors approved a professional services agreement
with Boyle Engineering Corporation for design and construction services required
for the Modification and/or Abandonment of Five District No. 7 Pump Stations,
Contract No. 7-11. Subsequently, the work covered under the original Contract
No. 7-11 has been divided into three separate contracts for the five items of
work, resulting in the following construction projects:
Contract No. 7-11-1, Abandonment of Lane Road Pump Station.
Contract No. 7-11-2, Relocation of Michelson Pump Station.
Contract No. 7-11-3, Abandonment of Castierock and Dow Avenue Pump
Station and Modifications to MacArthur Pump Station.
Originally built in 1967, the Lane Road Sewage Lift Station pumped
sewage from the 21-inch Main Street Subtrunk Sewer to the Gisler-Red Hill Trunk
Sewer. Expansion of the commercial/industrial area east of the Orange County
Airport in District No. 7 and formation of District No. 14 has resulted in
construction of the Main Street Pump Station and the Von Kansan and Main Street
Trunk Sewers which intercept the 21-inch Main Street Subtrunk Sewer, thereby
eliminating the need for the Lane Road Pump Station.
In April 1989, the Directors authorized the General Manager to negotiate
and execute an agreement with the City of Irvine for the abandonment of the
Lane Road Pump Station, Contract 7-11-1, in conjunction with the City's Main
Street improvements. However, the City has now decided to postpone their
project for an indefinite period of time. Staff believes that the interests of
the District would be best served by proceeding with Contract No. 7-11-1 and
combining it with Contract No. 7-11-3 into a single contract. The City of
Irvine concurs with the District's plan of action and will proceed with their
Main Street improvement project at a later date.
-14-
October 11, 1989
The Castlerock Pump Station is a small pump station serving a drainage
area containing twenty-nine residences in the unincorporated area of Cowan
Heights in the northeasterly portion of District No. 7 known as the Rocking
Horse Ridge Estates. The area served by the pump station drains naturally to
the northeast where development has since occurred within the City of Orange.
The remoteness of the site limits the District's ability to handle equipment or
other failures which can lead to sewage spills. A gravity sewer has been
designed to connect to a City of Orange sewer located in Strawberry Ridge to
allow abandonment of the Castlerock Pump Station.
The Dow Avenue Pump Station, located in Dow Avenue in the industrial area
of the City of Tustin, serves a tributary area of 316 acres and conveys the flow
along a 7,680-foot force main to the Red Hill Interceptor at Moulton Parkway.
The construction of the recently-completed IRWD Harvard Avenue Trunk Sewer in
Myford Road by IRWD will allow abandonment of the Dow Avenue Pump Station by
replacing the force main with a gravity sewer to drain directly to the new IRWD
sewer in Harvard.
The MacArthur Pump Station, located three-quarters of a mile south of the
Orange County Airport in MacArthur Boulevard, serves approximately 400 acres of
commercial/industrial property in the City of Newport Beach. The pump station
discharges into one-half mile of force main which is intercepted by the Von
Karman Trunk Sewer at Birch Street. The existing pump station lacks both
adequate capacity and standby capability. The proposed modification calls for
piping changes and an increase in the pumping capacity of the station.
Staff recommends approval of the plans and specifications for Abandonment
of Lane Road Pump Station, Contract No. 7-11-1 and Abandonment of Castlerock
and Dow Avenue Pump Stations and Modifications to MacArthur Pump Station,
Contract No. 7-11-3 and authorizing the General Manager to establish the date of
receipt of bids. A tentative bid date of November 21, 1989 is scheduled. The
Engineer's estimate of Contract No. 7-11-1 is $70,000 and $1,600,000 for
Contract No. 7-11-3.
9(x): APPROVING ACQUISITION OF EASEMENT FROM ALLEN D. GAGE FOR ABANDONMENT OF
Z` TLR K PUMP
� U 3AT, C N� IKAW NU. /--11-3.
Acquisition of permanent and temporary easements are necessary for the
proposed gravity sewer which will allow abandonment of the Castlerock Pump
Station as part of Contract No. 7-11-3 as described above under Agenda Item
9(w).
Staff has met with the property owner of Lot 26, Tract No. 11284, Allen
D. Gage, who has agreed to execute Grant of Easement documents subject to
certain conditions relative to limiting construction activities and restoration
of existing landscaping. The conditions will be included in the detailed
specifications of Contract No. 7-11-3.
Staff believes that it is in the Districts' best interest to settle this
matter for the owner's offer of $3,000 as compensation for inconvenience during
construction and disturbance of the landscape improvements located within the
construction area.
The recommended action is to approve and authorize acceptance of a Grant
of Easement from Allen D. Gage relative to abandonment of Castlerock Pump
.Station as part of Contract No. 7-I1-3 in the amount of $3,000.00.
-15-
October 11 , 1989
ALL DISTRICTS
11: APPROVE ADDENDA NOS. 1, 2 AND 3 AND AWARD OF CONTRACT FOR PRIMARY
CLARIFIERS NOS. 6-15 AND RELATED FACILITIES AT RECLAMATION PLANT NO. 1,
JOB NO. P1-33.
In August, the Directors approved the plans and specifications for a 60
mgd primary treatment expansion (new primary clarifiers) and related facilities
at Reclamation Plant No. 1. This project includes the construction of ten new
primary sedimentation basins located on the westerly side of the plant,
immediately south of the shop and warehouse area, in an area currently occupied
by the digester cleaning beds. The basins will be covered for odor control and
parking, similar to Primary Clarifiers Nos. 1 and 2. The design also includes
construction of new digester cleaning beds, influent and effluent piping,
related junction structures, an additional foul air scrubber for odor control ,
and modifications to the waste sidestream pump station.
Addendum No. 1
Addendum No. 1 includes miscellaneous technical clarifications to the
special provisions and detailed specifications.
Staff recommends approval of Addendum No. 1.
Addendum No. 2
Addendum No. 2 includes an extension of the bid date, new insurance
certificates and endorsements, revisions to several drawings to more clearly
delineate existing facilities and better define the scope of certain
construction work, and miscellaneous technical clarifications.
Staff recommends approval of Addendum No. 2.
Addendum No. 3
Addendum No. 3 corrects a discrepancy between two sections in the
detailed specifications pertaining to the time allowed for completion of the
construction work, and also modifies electrical work to be done in Power
Building 4.
Staff recommends approval of Addendum No. 3.
Award of Contract for Job No. P1-33
On September 26, 1989, seven bids were received for Primary Clarifiers
Nos. 6-15 and Related Facilities at Reclamation Plant No. 1, Job No. P1-33. The
bids ranged from a high of $46,566,000.00 to a low of $39,657,000.00. A
complete bid tabulation is attached to the agenda.
Staff recommends award to Gust K. Newberg Construction Co. of Los
Angeles, California for their low bid amount of $39,657,000.00. This project is
the single biggest contract ever awarded by the Districts. The Engineer's
estimate for this work was $46,000,000.00.
-16-
October 11, 1989
12: RECEIVE AND FILE SELECTION COMMITTEE CERTIFICATION AND APPROVE
..i PROFESSIONAL SERVICES AGREEMENT WITH JOHN CAROLLO ENGINEERS FOR
SECONDARY TREATMENT IMPROVEMENTS AT PLANT NO. 1 JOB NO. P1-36, AND
SECONDARY TREATMENT EXPANSION AT PLANT NO. 2, JOB NO. P2-42.
The Districts effluent quality requirements are dictated by the NPDES
ocean discharge permit which limits the mass emission rates of the so-called
conventional pollutants. Suspended solids are limited to 180,000 lbs/day and
biochemical oxygen demand to 189,000 lbs/day. Other constituents, such as heavy
metals, are limited as well . The existing permit expires in February 1990, and
application for renewal of the permit has been filed with EPA and the Regional
Board as previously authorized by the Boards.
Based upon the engineering evaluations conducted as part of the Action
Plan Facilities Master Plan (Volumes 2, 5 and 6), expansion of the Districts
existing secondary treatment facilities must be accomplished under either
Scenario 2 (50% secondary treatment) which is the wastewater management program
selected by the Boards in July, or Scenario 3 (100% secondary treatment) to
enable ongoing compliance with NPDES ocean discharge permit requirements of the
Federal Environmental Protection Agency and the State Regional Water Quality
Control Board. The secondary treatment capacity for the Districts' two
treatment facilities is currently 141 mgd. The necessary improvements will
result in additional secondary treatment capacity of 49 mgd, increasing the
secondary treatment capacity to 190 mgd between the two plants. Total treatment
capability (advanced primary and secondary) of the two plants is currently rated
at 285 mgd.
The Plant 1 activated sludge treatment facilities, built under Job No.
P1-16 in 1978 to handle 46 mgd constant flow, are proposed to be expanded to 80
mgd of secondary treatment capacity (Plant No. 1 also has 20 mgd of trickling
filter secondary treatment capacity). The proposed expansion includes ten new
secondary clarifiers, an upgraded air diffuser system, additional air headers,
one new air blower (electric motor driven) , sludge pumping and piping
improvements, associated auxiliary requirements including converting primary
effluent pump station engine driven equipment to electric motor driven variable
frequency drive, replacing engine driven blowers with a constant speed motor
drive, and an additional power building to supply the increased electrical power
requirements. To accommodate the additional sludge produced under this
expansion, three new 40-foot diameter Dissolved Air Flotation (DAF) units
(including dames for odor control) and modifications to the existing three DAF's
to enhance their performance is recommended. The Master Plan also addresses the
need for a centralized Distributed Control System (DCS) which calls for
Satellite Control Stations (SCS) for individual processes. Under this project
the first SCS will be installed under the separate Job No. J-23-1.
The Plant No. 2 secondary facilities, built under P2-23-6 in 1983 to
handle 75 mgd constant flow, are proposed for expansion to 90 mgd. The 14 mgd
expansion will require no additional secondary clarifiers to be built; however,
to accommodate the increased flow, the existing clarifier launders will be
extended (lengthened) by approximately 50 feet. This will include modifications
to the chains and flight mechanisms, and expanded sludge systems. Additional
auxiliary facilities include one additional DAF (55-foot diameter) with dome,
and modifications to the existing DAF's to enhance performance. A satellite
�..i control station, similar to Plant No. 1, will also be incorporated into the
design.
-17-
October 11, 1989
Other projects which will be included under this design contract include
electrification (elimination of internal combustion engines) of plant water pump
station and primary effluent pump station engines with motor-driven variable
frequency drives. The electrification element as well as these engine
conversions to electric motors described above are to comply with SCAQMD
requirements.
The data accumulated during the design of the project will be used in
conjunction with the cooperative multi-agency pilot effort to aid in
streamlining the processing of necessary regulatory agency permits for such
projects. This pilot effort includes the Districts, SCAQMD, RWQCB, EPA and
SCAG. This data, along with data from other agencies, will provide the baseline
information necessary to hopefully eliminate the delays currently inherent in
the permitting system.
John Carollo Engineers (JCE) designed the existing secondary treatment
facilities at both Plants Nos. 1 and 2 that are proposed to be expanded under
this project. This firm has a history of providing quality engineering services
to the Districts for many years. Some of their most recent major engineering
projects include the Ocean Outfall Booster Station, Headworks No. 2 at Plant
No. 1, Digesters 11-16 at Plant No. 1, and Sludge Handling Facilities at Plant
No. 1. Because of their previous work, JCE is most qualified to design this
project. Accordingly, as authorized by the Boards in July, the Selection
Committee has negotiated a fee with John Carollo Engineers based on hourly rates
plus overhead, plus direct expenses and fixed profit for a total amount not to
exceed $4,997,841.00.
The actions appearing on the agenda are to receive and file the Selection
Committee's certification of the final negotiated fee for the above work and
adoption of a resolution approving a professional services agreement with John
Carollo Engineers to provide consulting services for preparation of plans and
specifications, and construction services for Secondary Treatment Improvements
at Plant No. 1, Job No. P1-36, and Secondary Treatment Expansion at Plant No. 2,
Job No. P2-42. Copies of the certification and resolution are attached with
the supporting documents.
13: REPORT AND RECOMMENDATIONS OF EXECUTIVE COMMITTEE MEETING.
The Executive Committee met on September 27, 1989. Enclosed for the
Directors is a written report on its discussions and recommendations for
consideration by the Boards.
14: PUBLIC HEARING AND CONSIDERATION OF ADOPTION OF ORDINANCES ESTABLISHING
NEW CAPITAL FACILITIES CONNECTION CHARGES.
As part of the recently-completed 02020 VISION° Wastewater Management
Action Plan, the consultants recommended a change in the way the capital
facilities connection fees are calculated. Establishment of the revised
connection fee has been awaiting the Boards' decision on the level of treatment
to be included in the application for renewal of our NPDES permit. The amount of
the fee varies based on the treatment level because of additional facilities
required for higher levels of treatment.
-18-
October 11, 1989
In July the Directors approved the Action Plan and selected the preferred
treatment level alternative. It is, therefore, now appropriate to consider and
adopt revised connection fees that are paid by new development for capacity in
the sewerage system.
Capital facilities connection charges are one-time fees paid at the time
property is developed and connected to the sewerage system. The fees are
Imposed by each individual District pursuant to Section 5471 of the California
Health and Safety Code and are basically a charge to pay for capacity in the
sewerage system.
The capital facilities connection charge is based on the value of both
Joint Treatment and Disposal Works and individual District sewer collection
facilities. Currently each District has the same capital facilities connection
charge; $1,500 per residential unit and $300 per 1,000 square feet for
non-residential properties. (District 14 is an exception as connections within
District 14 are handled by the IRWD.) A uniform charge has been adopted by each
of the Districts to facilitate the administration of these fees by the city
staffs which collect the fees for the Districts.
The Districts' current connection fees are based on the calculated
replacement value of existing facilities. However, many of the Districts'
existing facilities are at or nearing capacity, and the new Facilities Master
Plan adopted by the Boards in July calls for a major investment in new
facilities. The financial consultants have recommended that the connection fee
should be restructured to reflect the expansion and improvements required to
serve new development.
The Master Plan develops a connection fee based on the cost of existing
facilities plus future facilities less future replacements of existing
facilities for Joint Works and trunk sewers. The proposed capital facilities
connection fee is based on the estimated capacity of the facilities in terms of
equivalent dwelling units (EDUs). An EDU is a measurement of demand on the
Districts' system, in terms of flow and strength, equivalent to that of a
typical single-family home. The capacity of the Districts' facilities, with
Master Plan improvements to year 2020, is estimated at one million units.
Continuing the current practice of establishing a uniform capital
facilities connection charge for all Districts in order to facilitate the
collection of fees by the cities would result in a fee of $2,270 per residential
unit. The Joint Treatment Works portion of the fee is $1,630 and the trunk
sewer systems adds $640 per EDU.
Commercial and industrial connection fees are based upon square footage.
The equivalent new fee would be $450 per 1,000 square feet. Under the current
Industrial use ordinance, additional connection fees can be imposed on
industrial users who place larger than average demand on the sewage system.
Connection fees will be reviewed annually to reflect the changes in the
value of the system to which a new customer is connecting. The consultants
recommend the fee be adjusted annually by an amount equal to the annual
percentage change to the ENR Construction Cost Index for Los Angeles. The
Boards will review the automatic adjustment each year and waive or alter the
adjustment based on then-current conditions. The proposed Ordinance contains
language to implement this policy.
-19-
October 11, 1989
At the September 13, meeting each District introduced and held the first
reading of their respective Ordinance. The actions on the agenda for October 11
are to hold a public hearing on the proposed uniform Ordinance, to make findings
that the adoption of said Ordinances are categorically exempt pursuant to
California Environmental Quality Act (CEQA) Guidelines, and for each District
Board to consider adoption of its respective Ordinance. If adopted October 11,
the Ordinances will become effective January 1, 1990.
At the September 13 meeting, District 13 Directors discussed the
provision in their ordinance for charging connection fees to local governmental
installations (the other Districts exempt local agencies) and asked staff and
counsel for additional information. Enclosed with the agenda material for
District 13 Directors is a separate report.
15: AGENDA FOR CLOSED SESSION.
From time to time it is necessary for the Boards to convene in closed
session to consider purchase and sale of real property, potential or pending
litigation, personnel matters or other matters which are exempt from public
disclosure under the California Public Records Act. In order to avoid a
situation where a closed session is needed but does not appear on the agenda,
this standing item is placed on the agenda each month providing for a closed
session at the regular meeting, if deemed necessary by the Boards.
DISTRICTS 6, 7 AND 14
29: CEQA ACTIONS RE SUPPLEMENT NO. 1 TO EIR FOR PROPOSED REORGANIZATION NO.
79 FORMATION COUNTY ANITATION DISTRICT NO. 14 AND REORGANIZATION OF
COUNTY SANITATION DISTRICTS NOS. 7 AND 13 EIR.
Currently being designed under Contracts Nos. 14-1-1A, 14-1-1B and 14-1-2
are joint conveyance facilities to handle flows from Districts 6, 7 and 14.
These improvements were approved as part of the formation of District 14 in
1985. These facilities will transport Districts 7 and 14 wastewater from the
Main Street Pump Station and wastewater from the northern portion of District 6,
connecting at Fairview, to Treatment Plant No. 1 in Fountain Valley.
After discussions with the consulting design engineer and staff of the
City of Costa Mesa, the final alignment of the 72-inch sewer line was changed
from being routed entirely through public streets and easements will now be
required from certain public agencies and private property owners. The size of
the sewer was also increased from the originally envisioned 72 inches to 90
inches because of the revised sewer design capacity peaking policy included as
part of the new 1989 Master Plan.
Because the easement requirements were not addressed in the original
EIR, staff has determined that additional environmental studies may be necessary
In order to comply with California Environmental Quality Act (CEQA) regulations.
In compliance with CEQA, an Initial Study and Environmental Impact Assessment
have been prepared by staff which indicates that the project may have an effect
on the environment and, based on that, finds that a supplement to the EIR for
Proposed Formation of County Sanitation District No. 14 and Proposed
Reorganization No. 79 Involving Reorganization of Districts Nos. 7 and 13, which
originally addressed these projects, should be prepared.
-20-
October 11, 1989
The Boards are being asked to receive and file the Initial Study and
.� Environmental Impact Assessment prepared by staff with the above findings, and
determining that Supplement No. 1 to the above 1985 Environmental Impact Report
is necessary; and declaring intent to have prepared and circulated a Notice of
Preparation for said draft supplement in compliance with CEQA regulations.
Copies of the proposed Notice of Preparation, Initial Study and Environmental
Impact Assessment are included in the supporting agenda material.
DISTRICT 7
34: CONSIDERATION OF REPORT AND RECOMMENDATIONS OF AD HOC COMMITTEE RE
UNSEWERED PROPERTIES.
Portions of areas within and adjacent to Orange County Sanitation
District No. 7 are not connected to the sanitary sewer system. The areas
Include Orange Park Acres, Lemon Heights and Cowan Heights, all within
unincorporated Orange County, and individual parcels within the City of
Tustin. Some of the unsewered properties are adjacent to but not within the
District; some do not have sewers available. Preliminary investigation of
approximately 12,000 lots within the areas mentioned indicates that 15 to 20
percent of the parcels are not connected to the sanitary sewer system.
A preliminary study was authorized by the Board in January 1988, using
Black 8 Veatch Engineers. A preliminary design report was issued, dated January
1989. The study has accomplished the following:
• Identified properties with on-site disposal systems;
. Identified areas where a complaint history is recorded;
. Reviewed general suitability of soils for absorption, hydrogeology of
soils, proximity to well water supplies, and evidence of groundwater
degradation;
• Reviewed applicable health laws and requirements;
. Estimated the benefits of a sewer construction and connection
program, with emphasis on groundwater quality and public health
improvements.
The study reviewed the existing on-site disposal systems and determined
that they do, in fact, contribute to either health hazards or degradation of the
groundwater. Preliminary solutions have been recommended and costs identified
for correcting the problem.
The District's Ad Hoc Committee working on this matter has reviewed the
unsewered property problem In and adjacent to County Sanitation No. 7, and
enclosed with the agenda material is the Committee's report and recommendations.
-21-
RE: AGENDA ITEM NO. 13 COUNTY SANITATION DISTRICTS
.1 ORANGE COUNTY. CALIFORNIA
September 27, 1989
tO nvExuE PO W.
wurtax vuuv.nu GIV
wnxin sz7zea127
nta ssz�tt
REPORT OF THE EXECUTIVE COMMITTEE
Meeting Date: September 27, 1989 - 5:30 P.M.
EXECUTIVE COMMITTEE: OTHERS PRESENT:
Present: Director James Neal
Director Wayne Wedin
Ronald B. Hoesterey Joint Chairman Thomas L. Woodruff, General Counsel
Buck Catlin Vice Joint Chairman
Don R. Griffin Past Joint Chairman
Richard B. Edgar Past Joint Chairman STAFF PRESENT:
Norman E. Culver Past Joint Chairman
Robert Hanson Chairman, District 1 J. Wayne Sylvester, General Manager
William Mahoney Chairman, District 2 Thomas Dawes, Director of Engineering
Richard Polis Chairman, District 3 Gary Streed, Chief Admin. Assistant and
John Cox, Jr. Chairman, District 5 and Acting Director of Finance
James Wahner Chairman, District 6 Michael R. Deblieux, Personnel Director
Tom Mays Chairman, District 11 Ed Hodges, Sr. Facilities Manager
Peer A. Swan Chairman, District 14 Maintenance
Don Roth County Supervisor Robert Ooten, Assistant Superintendent
Roger Stanton County Supervisor Operations
Rich von.Langen, Source Control Manager
Absent:
Don E. Smith Chairman, District 7/Past JC
Hank Wedaa Chairman, District 13
1) Proposed Amendment to Contract with Cooper-Bessemer for Supplying
Engines for Central Power Generation Systems, Job No. J-19.
The Districts are now proceeding with the implementation of the $66.5 million
Central Power Generation Systems project, which includes construction of power
generation facilities at both the Fountain Valley Reclamation Plant and the
Huntington Beach Treatment Plant. Design of the facilities is underway by Brown
and Caldwell , the consulting engineers, and it is expected that plans and
specifications for the Huntington Beach Plant will be submitted to the Boards of
Directors shortly after the first of the year for approval.
The engine generator sets are being supplied by Cooper-Bessemer under
separate contract and they are expected to be able to begin deliveries in the
second quarter of 1990. The original purchase agreement approved by the Boards
provided that the engines would be manufactured, and certain maintenance
services and spare parts provided, for the fixed amount of $18,968,113.00, based
on anticipated receipt of a Permit to Construct (PTC) from the South Coast Air
Quality Management District (SCAQMD) by August 1, 1987. In the event the notice
to proceed to Cooper-Bessemer, triggered by receipt of the PTC, was delayed, a
cost escalation of five percent was included for the first year, to August 1,
1988. The SCAQMD Permit to Construct was finally received in February 1989.
-1-
Executive Committee Report
September 27, 1989
L/
Because of delays in obtaining the PTC, Amendment No. 1 to the purchase
agreement was authorized in June 1988 to escalate the purchase price beyond the
August 1, 1988 date. However, escalation of the maintenance beyond August 1,
1988 was not addressed. The maintenance price is $1,567,500.00, included in the
total package noted above. If maintenance were escalated for the period between
August 1, 1988 and February 1989, when the PTC was received, at the same rate of
one-half percent per month as the engine generator sets, the increase would be
approximately $50,000.
The manufacturer is scheduled to start shipping equipment soon. But
because of the delay in starting construction of the Central Power Generating
Systems and due to other ongoing treatment plant projects, staff would prefer
that the equipment not be received until a contract for construction of the
Huntington Beach generating system is awarded. Until the equipment is ready to
be installed the Districts would incur considerable costs in preparing adequate
environmentally controlled areas to store the equipment.
Staff reported that it therefore believes it may be in the Districts' best
interests to investigate a delay in shipment with Cooper concurrent with price
escalation of maintenance service. Any delay in shipping the equipment would
require storage by Cooper and potential storage charges. However, if the delay
could be negotiated for a reasonable charge, it may be advantageous to proceed
with such an amendment.
The Committee discussed at considerable length the alternatives for
delivery and storage of the engine generator sets, during which it was pointed
out that under either option the overall cost to the Districts would be about
the same, but that by having Cooper-Bessemer retain possession of the equipment
they would be solely responsible for its storage and protection.
Recommendation
The Committee recommends granting staff and counsel authority to negotiate
Amendment No. 2 to the Electrical Equipment Purchase Contract with Cooper-Bessemer
for cost escalation for maintenance services because of delays in issuing the
PTC, and extended storage of said equipment by the manufacturer.
2) Guidelines re Procedures for Appeals of Wastewater Discharge Regulation
Enforcement Actions.
In August the Joint Boards adopted comprehensive, new wastewater discharge
regulations. The new ordinance, among other things, revised the procedures for
pennittees to appeal staff decisions to the Boards. Appeals to the Boards to
the future will be heard by the Executive Committee under the new procedures.
During the ordinance hearing, there was considerable discussion as to
whether every action and decision by the staff should be appealable to the
Committee. Accordingly, upon adoption of the ordinance, the Boards directed
-2-
Executive Committee Report
September 27, 1989
.s
the General Counsel and staff to prepare guidelines and procedures for the
handling of appeals which may be filed with the Districts for use by the
Directors in determining whether to exercise their discretion and grant a full
hearing on the requested appeal .
The Committee reviewed the enclosed (tan) report on the proposed guidelines
and procedures prepared by the General Counsel and staff. It was pointed out
that 15-20 appeals are filed annually. Most are resolved at the staff or
General Manager's level and 2-3 are ultimately filed with the Boards. It was
also pointed out that because of the more stringent provisions of the newly
adopted ordinance, more appeals can be expected in the future. As appeals move
up the enforcement ladder the staff and legal time that must be committed
Increases substantially.
The Committee discussed at some length whether the appellant should be
required to pay the added costs of appeals that go before the Directors. It was
the consensus of the Committee Members that processing of appeals was a "cost of
doing business" for the Districts, but that the appellant should be required to
submit enough copies of the appeal so as to avoid any further reproduction costs
by the Districts.
Recommendation
The Committee recommends approving the draft guidelines in concept and that
the counsel and staff be directed to finalize the guidelines re "Procedures for
Appeals of Wastewater Discharge Regulation Enforcement Actions" for consideration
by the Executive Committee and the Joint Boards of Directors at future meetings.
3) Fixing Date for Hearing on Appeal of Universal Circuits, Inc. re
Industrial Waste Permit Na. -
The General Counsel reported that subsequent to the mailing of the
Executive Committee Agenda, the Districts received a notice of appeal of the
staff's decision not to renew Universal Circuits, Inc. , No. 1, Industrial Waste
Permit No. 1-1-346 (see attached (buff) memorandum from the General Counsel
dated September 27, 1989) , and that the time requirements of the appeals
procedures require that the Committee set a hearing date at this meeting.
Following a brief discussion it was the unanimous determination of the
Committee that the need to fix a hearing date for the appeal of Universal
Circuits, Inc. , No. 1, re non-renewal of Permit No. 1-1-346, arose subsequent
to the meeting agenda being posted, and that pursuant to the authority of
California Government Code Section 54954.2(b)(2), the Committee established
Wednesday, October 18, 1989 at 5:30 p.m. in the Districts' Administrative
offices as the time and place for said hearing.
-3-
Executive Committee Report
September 27, 1989
By separate memorandum the General Counsel has recommended that the Joint
Boards take the following actions regarding the hearing:
(a) Ratify the action of the Executive Committee setting
October 18, 1989 at 5:30 p.m. as the time and date for
hearing the appeal of Universal Circuits, Inc.
(b) Ratify the action of Executive Committee in setting the
appeal hearing for Universal Circuits, Inc. , pursuant to
Ordinance Section No. 619 with finding that the Joint Boards
would have required hearing before the Joint Boards, as
authorized by the terms of the Joint Ownership, Operation
and Construction Agreement of July 1, 1985.
(c) Affirm the use of "Rules on Appeal Pursuant to Section 619
of the Districts' Ordinances Establishing Wastewater
Discharge Regulations of the County Sanitation Districts of
Orange County, California" for conducting hearing on appeal
as submitted to Universal Circuits, Inc.
A copy of the General Counsel 's memorandum dated October 3, 1989 (goldenrod)
is attached.
4) Board Meeting Room Smoking Policy.
In 1984 the Directors established a smoking policy for the Board Meeting
Room that designated tables in the rear of the roam (immediately beneath the
ventilation exhaust system) as a smoking area and the balance of the room as a
non-smoking area. In 1987 the Executive Committee established a non-smoking
policy for Executive Committee meetings.
Some members have requested that the Directors consider revising the Board
Meeting Room policy to prohibit smoking altogether.
Recommendation
The Executive Committee recomnends that the Joint Boards of Directors
establish a policy prohibiting smoking in the Board Meeting rooms.
5) October Executive Committee Meeting Date.
The Executive Committee normally meets on the fourth Wednesday of, the month.
This year the California League of Cities annual meeting will be held that same
week. In order to avoid a conflict, the Committee changed its regular
October 25th meeting to Thursday, October 26th at 5:30 p.m.
-4-
Executive Committee Report
September 27, 1989
6) Position Classification Changes.
Last year the Boards approved three-year memoranda of understanding with
our six employee groups for the period of November 1987 through November 1990.
As part of the meet-and-confer process, the Districts agreed to conduct
classification studies on certain positions. Some of the studies have now been
completed and reviewed by the Committee. Enclosed is a separate confidential
report and recommended position classification changes.
Recommendation
The Executive Committee concurs with the recommendations of the consultant
and staff.
If any Director wishes to discuss the recommendations, the Joint Chairman
will convene the Committee in closed session at the Board Meeting.
-S-
RE: AGENDA ITEM NO, 140 ) - DISTRICT 13
COUNTY SANITATION DISTRICTS
OF ORANGE COUNTY, CALIFORNIA
P.O.BOX 8127,FOUNTAIN VALLEY,CALIFORNIA 92728-8127
10544 ELLIS, FOUNTAIN VALLEY,CALIFORNIA 92708-7018
(714)962-2411
FAX(714(982-0358
II
October 4, 1989
District 13 Board Members
Iry Pickler
Don R. Roth
Don E. Smith
Wayne D. Wedin
Subject: Connection Fees for Local Public Agencies
Following our discussion at the September 13th Board Meeting on the issue of
local public agency exemption froln sewer connection fees, I asked staff and the
General Counsel to prepare a summary report for the Directors on how
District 13's policy of charging connection fees to new or expanding local
government installations evolved.
Enclosed is a copy of the briefing memorandum. I have reviewed and discussed it
with the General Manager and General Counsel. My conclusion is that there was
considerable discussion and thoughtful consideration given when the District 13
Board decided in 1988 to require payment of connection fees by local public
agencies. I believe that the current policy continues to be in the best
interests of District 13 and its constituents. It is therefore my recommendation
that we retain it in Ordinance No. 1306, now scheduled for hearing and final
adoption at the regular Board Meeting on October llth.
If any of the District 13 Directors wish the Board to consider changing this
provision in Ordinance No. 1306 we can futher discuss the issue at the meeting
on October llth. Hopefully it can be resolved then. If not, it can be continued
to an adjourned meeting.
I SS►,�i1(nn�cerely, �
Qh ryWWedaa aGL.
airman
District 13
�../ HWW:sc
Encl.
COUNTY SANITATION DISTRICTS
91 ORANGE COUNTY, CALIFORNIA
September 27, 1989
I ELM AVENUE
iMW.v,"V,nuFOMAs 92M.e+27
n1m99aQa1
MEMORANDUM
TO: District 13 Directors
SUBJECT: Connection Fees for Local Public Agencies
Purpose
At the September 13th Board meeting the District 13 Directors discussed the
policy of charging one-time connection fees to local public agencies at some
length. Several points were made during those discussions:
1) Connection fees are paid by new development for sewerage system
capacity.
2) Existing regulations and policy require all local public agencies
In District 13 to pay connection fees. Local public agencies in the
other Districts are exempt.
3) State and federal agencies pay connection fees in District 13 and all
other Districts.
4) Exempting public installations, particularly large ones, shifts the
financial burden to the residents and businesses of that District.
5) Is it legal to exempt some local governmental installations and not
exempt others?
Staff and Counsel have been asked to provide further information on this issue
for the District 13 Board Members.
Background
In 1988, while updating the District's long-range financial plan, the
District 13 Board Members adopted a policy of charging all local public agencies
for new connections to the sewerage system. Attached are the minutes (blue) of
the June 1, 1988 meeting at which the Board made the decision, along with the
referenced General Counsel 's analysis (yellow).
The concern expressed by Board Members in 1988 was that by exempting local
public facilities projects from paying the capital costs, particularly large
projects such as the proposed new County Jail Complex in District No. 13, the
burden was unfairly shifted to the residents and businesses of the District,
thus increasing the fees that they would have to pay. After considerable
discussion the matter of local agency connection fee exemptions was referred to
the Executive Committee for review.
District 13 Directors
September 27, 1989
Page Two
The Joint Boards' Executive Committee considered the issue and concluded that it
was not prepared to recommend any change in existing policy. However, the
Committee observed that the "Uniform Regulations for Use of Districts' Sewerage
Facilities", which includes the connection fee policy, are adopted separately by
each individual District, and that each District has the option of amending its
ordinance to remove the connection fee exemption for local governing agencies if
the Board in any District determines that local government facilities place a
disproportionate demand on the District's system and the financial burden of
sewage service for that District is not equitably distributed.
Pending Ordinance Revisions
The Directors are presently considering Ordinance No. 1306 that would increase
the residential connection fee to $2270 per dwelling unit and $450/1000 square
feet of non-residential building space (minimum charge $2270). Ordinance
No. 1306, as proposed, will continue to require payment of connection fees by
local government. Thus the connection fee would be the same for a governmental
installation as for a private building. The per 1,000 square foot calculation
and the relatively nominal amount of the fee generally prevents small users from
being unduly burdened.
Legality of "Discriminatory" Fee Exemptions
Also attached is an updated memorandum from the General Counsel (green)
concerning the potential problems of exempting some local governmental
installations and not others.
Pending Fee Structure Study
To help address changing conditions and requirements staff is close to
finalizing a scope of work and a request for proposals to analyze, review and
make recommendations regarding the current connection fee and supplemental user
fee structures of all Districts. It is anticipated that this study will result
in more classes of fees, each of which more closely approximates sewerage system
demands than those now used. The study is expected to be thorough and to
include flow monitoring in sewers with identifiable dischargers and establishing
demand ratios for several classes of user types. The result of the study will
be correlated with the County Assessor's data base so actual users throughout
the service area will be accurately charged.
The results and recommendations of the study will be brought to the Directors
for review and staff will then seek direction for possible changes in connection
fee and user fee policies.
GGS:sc
FIN/DIST.INF89
D13.MM1.1-1.2
COUNTY SANITATION DISTRICT NO. 13
OF RANGE COUNTY, CALIFORNIA
MINUTES OF ADJOURNED REGULAR MEETING
�..i June 1, 1988 - 7:30 p.m.
Yorba Linda City Hall - Council Chambers
4845 Casa Loma Avenue
Yorba Linda, California
Pursuant to adjournment of the regular meeting of May 11, 1988, the Board of
Directors of County Sanitation District No. 13 of Orange County, California,
met in an adjourned regular meeting at the above hour and date.
The Chairman called the meeting to order at 7:30 p.m. The roll was called and the
Secretary reported a quorum present.
DIRECTORS PRESENT: Todd Murphy, Chairman, Ben Bay,
Don E. Smith and John Sutton
DIRECTORS ABSENT: Don R. Roth
STAFF MEMBERS PRESENT: J. Wayne Sylvester, General Manager,
Rita J. Brown, Secretary, Thomas M. Dawes,
Gary G. Streed,
OTHERS PRESENT: Thomas L. Woodruff, General Counsel
Discussion re Ian -ran a in
Staff briefly reviewed proposed
plan modifications and act on modifications to the District' s
eliminating local government long-range financial plan deliberated by
exempt ons from connection fees the Board at its adjourned meeting on
April 25 whereat the Directors reviewed
long-range financial projections and considered alternatives for financing
projected operating and capital funding shortfalls brought about by the rising
costs of complying with stricter environmental standards. Several Directors
expressed their concern at that time over the provision in the District's uniform
"Regulations for Use of District Sewerage Facilities" that exempts local
governing agencies from connection fees used by the District to pay for the
capital costs of sewerage system capacity. Federal and state agencies are
charged the connection fee but local government is not. In District No. 13,
because no ad valorem taxes are received, local governmental agencies are not
exempt from annual user fees which pay the cost of operating, maintaining and
rehabilitating the sewerage system. The concern expressed by Board members was
that by exempting local public facilities from paying the capital costs,
particularly large projects such as the proposed new County jail complex in
District No. 13, the burden was perhaps unfairly shifted to the residents and
businesses of the District, thus increasing the fees they would have to pay.
After considerable discussion, the matter of local agency connection fee
exemptions was referred to the Executive Committee for review.
..i On April 25, after considerable deliberation and with the understanding that
revisions could be made at a later date, the Board proceeded with the
introduction and first reading of proposed changes to the user fee and connection
fee ordinances as follows:
O6/01/88
District 13
Existing Proposed
1987-88 1988-89
ANNUAL USER FEE Fee Fee
Single-Family Dwellings/Condiminiums $70.00/building $78.40/dwelling unit
Multi-Family Dwellings/Apartments $70.00/building $47.04/dwelling unit
Commercial/Industrial/Other $70.00/building $56.12/1,000 sq.ft.
(government buildings, utilities,
nonprofit organizations, etc.)
ONE-TIME CONNECTION FEE
Zone A
Residential $220 $220
Commercial/Industrial/Governmental/Other $45/1,000 sq.ft. $45/1,000 sq.ft.
Zone B
Residential $1,250 $1,500
Commercial/Industrial/Governmental/Other $250/1,000 sq.ft. $300/1,000 sq.ft.
Zone C
Residential $1,500 $1,500
Commercial/Industrial/Governmental/Other $300119000 sq.ft. $300/1,000 sq.ft.
Staff reported that the Joint Boards Executive Committee considered the issue of
local government exemption from connection fees at its May 4th meeting but did
not recommend any change in existing policy. However, the Committee did observe
that the uniform use ordinance, which includes the connection fee policy, is
adopted separately by each individual District and that each District has the
option of amending its ordinance to remove the connection fee exemption for local
governing agencies if the Board in any District determines that local government
facilities place a disproportionate demand on the District's system and does not
equitably distribute the financial burden of sewerage service for that District.
The General Counsel then reviewed a memorandum that he had prepared for the Board
members concerning the issue of connection charges for governmental agencies and
the limits of the Board's discretion in adopting non-discriminatory fees to
equitably distribute the cost of sewerage service.
Following a brief review by staff of new cash flow projections which had been
revised to reflect the latest information and the Board's pending actions from
the April 25th meeting on user fee and connection fee schedules, the Directors
entered into a discussion of the issue of exempting local governmental agencies
from the sewer connection charges. After considerable dialogue and evaluation of
the matter, it was moved, seconded and duly carried:
That the Board hereby declares its intent to revise proposed Ordinance No. 1302,
An Ordinance of the Board of Directors of County Sanitation District No. 13 of
Orange County, California, Amending Ordinance No. 1301 Establishing Regulations
for Use of District Sewerage Facilities relative to connection fees, to strike
Section 701.C. from Ordinance No. 1301 thereby eliminating local governing
agencies exemption from connection charges.
-2-
O6/01/88
District 13
First reading of revised It was moved, seconded and duly carried:
..i r finance No. 1302
That revised Ordinance No. 1302, An Ordinance of the Board of Directors of County
Sanitation District No. 13 of Orange County, California, Amending Ordinance
No. 1301 Establishing Regulations for Use of District Sewerage Facilities, be
read by title only; and,
FURTHER MOVED: That reading of said entire ordinance be, and 1s hereby,
waived.
Following the reading of revised Ordinance No. 1302 by title only, it was then
moved, seconded and duly carried:
That revised Ordinance No. 1302, An Ordinance of the Board of Directors of County
Sanitation District No. 13 of Orange County, California, Amending Ordinance
No. 1301 Establishing Regulations for Use of District Sewerage Facilities, be
Introduced, and passed to the second reading on June 8, 1988, at 7:30 p.m. , at
the District's administrative office.
Second readingof proposed Moved, seconded and duly carried:
rdinance o. 1303
That proposed Ordinance No. 1303, An
Ordinance of the Board of Directors of County Sanitation District No. 13 of
Orange County, California, Establishing Sanitary Sewer Service Charges and
Repealing Sections 703, 704, 705 and 706 of Ordinance No. 1301, be read by title
only; and,
FURTHER MOVED: That the second reading of said ordinance to its entirety be, and
is hereby, waived, whereupon the Secretary read Ordinance No. 1303 by title only.
Adopting Ordinance No. 1303 Moved, seconded and duly carried by the
following roll call vote:
That Ordinance No. 1303, An Ordinance of the Board of Directors of County
Sanitation District No. 13 of Orange County, California, Establishing Sanitary
Sewer Service Charges and Repealing Sections 703, 704, 705 and 706 of Ordinance
No. 1301, be adopted:
AYES: Todd Murphy, Chairman, Ben Bay, Don E. Smith, John Sutton
NOES: None
ABSENT: Don R. Roth
Adjournment Moved, seconded and duly carried:
That this meeting of the Board of Directors of County Sanitation District
No. 13 be adjourned. The Chairman then declared the meeting so adjourned at
8:10 p.m. , June 1, 1988.
�./ Secretary, Boa of D rectors
County Sanitation District No. 13 of
Orange County, California
-3-
RESOLUTIONS AND SUPPORTING DOCUMENTS
WEDNESDAY, OCTOBER 11, 1989 - 7:30 P.M.
FUND NO 9299 - JT DIST HORNING CAPITAL PROCESSING DATE 9/06/89 PAGE 1
Li REPORT NUMBER AP43
a
CLAIMS PAID-09/13189 POSTING DATE 09/23/89
'+01L_
101905 ABC PAINT BTR IPVNG SERVICE f250.B9 PAINT SUPPLIES
INTrATOftq
101907 ADVANCED OFFICE SERVICES $75.77 OFFICE MACNINE REPAIR
• 10190a AIR COLD SUPPLY INC. $196.23 ELECTRIC PARTS
_ _ cesxs
b 101910 AMERICAN DISTRICT TELEGRAPH 560.00 SERVICES AGREEMENT
101911 BOSCO INC. 8/OR AMERICAN SEALS $3,638.07 HARDWARE
101913 R CABLE 1 $109.19 CLEANSES
01914 ARATER SERVICES, INC. $4.695.10 UNIFORM RENTALS
r +O+9ra ea nnxe ru<TanxrNT •pAa_Dn TxsTRlmxuT veRTR
101916 ASPHALT INSTITUTE 5721.50 ASPALT PAVING
3 101937 BC INDUSTRIAL SUPPLY9 INC. 9374.56 BUILDING SUPPLIES
1 n151a aeRxPl n0 pprVrMTtnN nrVFfP ti[n_un R1PNYl ON TFCTTNC
101919 HILARY BARER 3670.00 CONSULTING SERVICES - ANNUAL REPORT
W 10I920 P.V. GAROTTE AND ASSOC. 13,720.00 CONSTRUCTION SERVICES PI-25626, P2-33,14,3]
1 1019P1 RSR iLi NELIC 6CC OfleTrO ip ApM1�nP RNf.TNPPRTNC CPR9T!!PC MCCTFP 9T AN
ID2922 DORENICH BASSO, INC. 39+371.b9 AUTOMOBILE
b 101923 BAXTER SCIENTIFIC PP ODUCTS i2.926.87 LAB SUPPLIES
K I— Iu 122A Ytl TAM Ar G P4S_l0 tdN11 C!'A 9R C11991 TPC
I4r 101925 BENZ ENGINEERING. INC. $889.64 COMPRESSOR PARTS
tv 101926 BOISE CASCADE OFFICE PRODUCTS $5.44 OFFICE SUPPLIES
n. .�
pI �
..71ii• wyr.T xRRRTxc <xxy.ewC 301918 BROOKS INSTRUMENT DIV. 5414.96 METER
A•
101929 BROWN 8 CALOYELL CONSULTING $6,139.53 ENGINEERING SERVICES PI-35,P2-39
l7 30193E GATT G. STR EED - $452.65 PETTY CASH REIMBURSPS@NT
1i°I N 101932 C 8 R RECONDITIONING CO. $210.30 MECHANICAL PARTS
MAINTENANCE CONTRACT M.0.2-11&99
101934 CS COMPANY f99175.08 Van PARTS
»I 101935 CAL-FAC CHEMICAL CO.. INC. 3150.47 CHEMICALS
101937 JOHN P. CALAPRICE. PhD $840.00 CONSULTING SERVICES
301938 CALIF. ASSOC. OF SANITATION 368D.06 REGISTRATION PEE
1 m 9Po
101948 JOHN CAROLLO ENGINEERS f39931.29 ENGINEERING SERVICES
pi 161941 CHEMWEST INDUSTRIES. INC. '6693tl9.51 FERRIC CHLORIDE M.0.11-09-88
A
101943 CHEVRON U.S.A.. INC. $241.95 PAINT THINNER
102944 CLOSSON 8 CLOSSON $1,896.50 ENGINEERING SERVICES - LANDSCAPING
...pea ...IN WE TECHNICAL JOURNALS
�I 101946 C.I.E.S. 9 CO. 9 INC. 6239634.75 PUMPS
Iw� 101947 COMPRESSOR COMFONENTS OF CALIF 5381.60 MECHANICAL PARTS
e• b 191949 CONSOLIDATED ELECTRICAL DIST. 35.344.8E ELECTRIC SUPPLIES
1 10195D CONSOLIDATED REPROGRAPHICS 1119847.40 BLUEPRINTING
I
N FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/06/69 PAGE 2
L� REPORT NUMBER AP43
'I CLAIMS PAID 091l3/89 POSTING DATE 09/13/89
301951 CONTINENTAL GRAPHICS $27,249.51 BLUEPRINTING M.O.7-12-89
e1 101953 COURTT WHOLESALE ELECTRIC $3,336.07 ELECTRIC SUPPLIES
101954 CPA NE VEY OR CORP. $344.58 PIPE
101956 CAL WATER $272.44 RENTAL EQUIPMENT
12 101957 LARRY CURT TRUCK S EQUIPMENT $22.800.00 SLUOGE REMOVAL M.O.4-13-88
iI z 101959 DANIELS TIRE SERVICE S430.44 TIR85
° C 101960 DANNY•S CUSTOM WAXING $920.00 AUTOMOBILE REPAIRS OVERSPRAY RMOVAL
n
TECHNICAL EXPENSES
n�°j 201962 TOM DARES ,320.30 MEETING SANALYS
ITI 301963 DEL MAR ANALYTICAL 58.32U.00 EMISSIONS ANALYSIS
CONSTRUCTION J-22 M.0.4-13-88
301965 DE2UR IK AND/OR CS CO. 51.325.43 VALVE PARTS
101966 DIATEC POLYMERS SS.793.17 ANIONIC POLYMER M.0.8-10-88
6a 1 101968 DUNN EDWARDS CORP. S584.7P PAINT SUPPLIES
n 101969 DIVALS SALES S309.7E CONNECTORS
u4 1 507970 ENS RESAWI INC SRA6 AR CONSULTING - REGUTAMN 6iE8IS6 EV8-ABPAER6
a f 101971 EASTMAN• INC. f21964.21 OFFICE SUPPLIES
j'° A 101972 EBERHARD EQUIPMENT f65.04 AUTOMOTIVE PARTS
1" `"•RT3 EGOAN04Y612 ING S5 667 4T COMPUTER CONSULTING GERVESEB
° Cq 101974 EFFECTIVE VISUAL IMAGERY S271.89 PRESENTATION AIDS
a0� 101975 EDWARD L. ELLIOT, JR. $1,355.00 ENGINEERING SERVICES
102977 ENCHANTER. INC. $4,200.00 OCEAN MONITORING M.D.6-10-87
201978 ENGINEERS SALES-SERVICE CO. f452.62 PUMP PARTS
CONSULTING - FEES ONNEW-RMV
1 j 301980 JEFF ESKER S152.40 MILEAGE EXPENSES
3C19801 ESPRIT SYSTEMS. INC. $61.74 INSTRUMENT
101983 FARR SALES S SERVICE $2,396.96 ELECTRIC PARTS
j°j 101989 FEDERAL EXPRESS CORP. $261.25 AIR FREIGHT
301985 ee""SLAG . -.9 59- PROPANE
16198E FI
1 PST
AMERICAN TITLE INSURANCE f6.059.06 TITLE REPORTS
�a 01967 FISCHER S PORTER CO. S174..7 CHLORINATION PARTS
101989 FOXBORO/JORDA NI NC f365.00 INSTRUMENT PARTS
101990 TRUCK A BUS GROUP/GM S23.662.64 VANS
101992 GENERAL TELEPHONE CO. S261.69 TELEPHONE
101993 GIERLPCH-MITCMELL. INC. $48,987.21 MECHANICAL SUPPLIES
IF.o94 W r ECK aASSOC'"" - " 00 ENGINEERING OERVEGES RES 88 72
101995 HARRINGTON IRDUSTPIAL PLASTICS $4,764.33 INSTRUMENT SUPPLIES
0° n 101996 HATCH A KIRK. INC. $5,412.10 MECHAICAL REPAIRS
I
w
FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/06/89 PAGE 3
L REFORT NUMBER AP43
CLAIMS PAID 09/13/09 POSTING DATE 09/23/89
WARRANT Nn, wunne nrcrezea nu
101997 S. 4. HEASEELY CO. A$102.015.63 CONSTRUCTION 11-35-1
el
'I 101999 HOUSE OF BATTERIES $50D.66 BATTERIES
° 102000 R.E. HUSHES CO.. INC. E701.12 PAINT SUPPLIES
1020C2 HUNTI MOTOR BEACH RUBBER STAMP 5172.25 RUBBER STARS
102003 HUNTIN GTON VALLEY ECHWINN CYCL BICYCLE$445.69 PARTS
= 1n2rn4 - eVnRnTry FTr n Qr RVTrr tL F21-10 ^lOKP PA8T5
r�C7 102005 IND INDUSTRIES $348.61 ELECTRIC SUPPLIES
Ha 3o 102006 ISCD COMPANY E7T0.87 LAB SUPPLIES
1K> , .uA rur.TNFFRQ .n-anz-nz a�Kevo.R�gp0l... o- _-_,-�^-, .
1e�3 302111 INCON SYSTEMS. INC. $763.20 MECHANICAL PARTS
302009 INDUSTRIAL THREADED PRODUCTS $1,060.64 FITTINGS
,j* 102011 IRON OAKS 1105.15 VALVE PARTS
ICK) 302012 J E Y SCIENTIFIC 51.468.45 LAB SUPPLIES
Je0. a en E02 ^ 161 S" POW'S SYSTEM SORES
302C14 JENSEN TOOLS E ALLOYS 5301.92 TOOLS
weir 102015 JOHNSTONE SUPPLY $119.59 ELECTRIC PARTS
1nPeu ouoTru u .inure_ oun <..oz. wn CGNEN.TS010 ERPVIfi6 - BGRMI BNTPALb
102017 KALLEEN°S COMPUTER SUPPLIES SL 296.41 OFFICE SUPPLIES
m,d 202018 HAMAN EA PINGS E SUFP LY i2 775.74 FITTINGS
10o n'n u.urn rnu..u' f5 769 94 "'^PbS
(aj�l 102020 KEEN-KU T ABRASIVE CO. $198.75 TOOLS
102P21 K EN-S OIL. INC. S25.OD WASTE OIL DISPOSAL
I�IInD7' v1YG BEAeTunT I r '2*3 " NBGNANI 1 P .l.
102023 MARTIN KORp IC K.uSR S2.866.1O CONSTRVCTION SERVICES 14-1,5-34
ialy 102029 LAB SAFETY SUPPLY CO. 51.168.89 LAB SUPPLIES
sere < <eRVICE 3A4G 92 PRINTING &pPAIFS6
W 102026 LEE I RO CONSULTING ENGR. f26.505.0G ENGINEERING SERVICES P1-33
102 C27 LIF ECOM-SAFETY SERVICE SUPPLY $216.55 CYLINDER REPAIRS
r� 102029 LOTUS DEVIL. CORR. 5159.00 SOFTWARE
102 D30 LUSTRE-CAL $491.50 PRINTING
CF&
IC2032 MPS $14.84 PHOTOGRAPHIC SERVICES
it 2333 MACONCD $442.80 MAINTENANCE CONTRACT
Mz
IO2B3S M4RVAC ELECTRONICS $49.86 INSTRUMENT SUPPLIES
wl 102036 MASTER TOOLS SERVICES f47.91 TOOL REPAIR
InP 0%T M4TT ru nR. Tar_ .anr-ao GELRE W.R., PARTS
102038 DON MAURER 54.375.00 CONSULTING SERVICES - OCEAN MONITORING
102039 MCKEKMICRON4 ENGR. I EDUIF. $6.164.2E POMP PARTS
SO
Y 102041 MICROAGE COMPUTER $1,903.76 COMPUTER SOFTWARE/HARDWARE
102042 MOBILE HOSE AND HYDRAULIC SUPP $145.74 HOSE
io
r
FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/06/89 PAGE 4
�.. REPORT NUMBER AP43
CLAIMS PAID 09/13/89 POSTING DATE 09/13/89
102043 MONITEK• INC. 93,333.57 INSTRUMENT PARTS
102045 MOTION INDUSTRIES. INC. $20.72 HARDWARE
°I 102046 NEWARK ELECTRONICS $302.66 INSTRUMENT
r yn2 ne• CH—LES-lAi CJ10 LL t4N AG MBRiiMC MRP8M6B
I11 102048 NOPCAL CONTROLS. INC. 3763.07 MECOANICAL PARTS
(In 102049 NOR IN SUPPLY f° S283.49 TOOLS
102nv E OAEnl ELECTRIC
L 136 17 ELECTiIICMO -I042-BB
1,•ID 102051 ORANGE COAST ECHEMICA SUPPLY t136.85 ELECTRIC SUPPLIES
I D2052 ORANGE COUNTY CHEMICAL CO. $1.613.85 HYDROCHLORIC ACID
m 1GA' R=Tmas
2154 OSCAR`S LOCK t SAFE S20.A7 KEYS
�3 102055 OXYGEN SERVICE $1,184.18 SPECIALTY GASES
1°I Tt 102057 PSSI $2.521.U0 TV SEWER SERVICES
102058 PACIFIC DATA CON SYSTEMS $3,556.78 MONITOR
' s .nGnny G.rIf1LSeG FTY EU U1ly1E NT CO `76..1. el SAFYiY-CWG.In
102060 PACIFIC SEWER MAINTENANCE CORP 61.300.0C SEWER INSPECTION
302061 PACIFIC BELL 529.87 TELEPHONE
102063 PACTEL CELLULAR $126.47 CELLULAR TELEPHONE SERVICES
U'�CJ IC2064 PATTEN CORP./ TAYLOR INSTR. $2,889.16 STRIP CHARTS
!� 102066 POLYPURE. INC. t15.759.56 CATIONIC POLYMER M.O. 3-8-89
302067 POWER ELECTRO SUPPLY CO. $30.79 ELECTRIC SUPPLIES
102069 HAROLD PRIMROSE ICE $109.00 ICE
102070 THE PROJECTS SOLUTION CO. S2.000.13 INSTRUMENTATION INSPECTION M.D.8-10-88
v
102072 RECYC. iNC. 539.520.4 b' SLUDGE REMOVAL N.0.5-11-88
IPee 1D2073 RED WING SHOES $96.65 SAFETY SHOES
-2s.736 METER ID
1020]S REMEDY TEMP $1.243.20 TEMPORARY SERVICES
IfOI 102076 THE REPUBLIC SUPPLY CO. $1.086.08 PIPE/FITTINGS
112171 REMOLD POWER TRANSMISSION $621.22 lECHANICAL PARTS
ril 102079 R1CnAROS. WATSON L GERSHON 97,862.82 LEGAL SERVICES
102081 ROMAN ENGINEERING CO. 165.07 INSTRUMENT PARTS
202082 ROSEMONT ANALYTICAL $240.47 INSTRUMENT PARTS
302084 JOSEPH T. RYERSON A SON, INC. $2,423:16 STEEL
rol 102[B5 SAFETY-KLEEN CORP. 79680 PARTS CLEANER
PI 7 14R
iY>I 102087 SCIENCE APPLICATIONS INT•L .111.662.29 OCEAN MONITORING M.0.6-Ib-89
I°C t 102088 SEA COAST DESIGNS S5.211.81 OFFICE EQUIPMENT
�w�
FUND NO 91w9 JT DIST WORMING CAPITAL PROCESSING 00.TE 9/06/89 PAGE 5
REPORT NUMBER AP43
CLAIMS PAID 09/13/89 POSTING DATE 09/13/89
102089 SEA OYN• INC. S4t860.CC CONSULTING - SEDIMENT ROOMING
"I 102091 SECURITY SPECIALISTS $2,963.44 SECURITY SYSTEM
poi 102092 SHAMROCK SUPPLY 447.90 TOOLS
a .n119c cure eev ue- 1. urnrr .Ye_.10 _T IT,. .e..T wr
10209/ SMITH-EMERY CO. $206.00 SOIL TESTING
P m 1D2095 SOFTWARE WAREHOUSE $455.44 SOFTWARE
,_�� tn2 n9a cn. me er etv r e Iry <sc_� vt nrre Ynu
y 102A97 SOUTMCRN CALIF. EDISON CO. $10.827.32 POWER j
eI� 202098 S0. CAL. GAS CO. $3,950.96 NATURAL GAS
102100 SPEC TECH WESTERN S558.23 WELDING SUPPLIES
Ie1 3 102101 SPEEDE SPEEDOMETER S287.19 DRIVER TESTING
�� crew rnm . mmoi v rn_ _ .gnv_T<
1004303 STERLING ART $140.84 GRAPHICS SERVICES
4I 12104 SUBIA. INC. $265.00 PRESENTATION AIDS
ayln 202106 SUPELCO. INC. $151.58 LAB SERVICES
t if— 102107 CONTINENTAL AIR TOOL. INC. $5,099.74 TOOLS/HARDWARE
_ uner.e.wr
102169 TEKMAR COMPANY 9478.93 LAB SERVICES
e` 102120 3T EQUIPMENT COMPANY $981.03 FITTINGS
n
'ej� 302112 TRUCK 8 AUTO SUPPLY. INC. $4,048.61 TRUCK PARTS
2. 102113 J.G. TUCKER B SON, INC. S4.4D6.96 INSTRUMENT PARTS
SOIL TESTING u n ^-•^-R9
102115 UNOCAL $229.63 UNLEADED GASOLINE
a� 102216 UNITED NOTTINGHAM $347.36 PORTABLE TOILETS
m� 202110 DATAVAULT U.S.SAFE DEPOSIT CO. S1,I24.00 COMPUTER PACK STORAGE
102219 UNIVERSAL MACK $413.60 TRUCK PARTS
e l02121 VALLEY CITIES SUPPLY CO. $3,476.73 FITTINGS
IAi 102122 VAREC DIVISION $256.46 MECHANICAL PARTS
102124 VERTEK SYSTEMS 1780.10 COMPUTER SERVICES
"i 102225 VIKING INDUSTRIAL SUPPLY $924.44 SAFETY SUPPLIES
IC2127 JOHN R. WAPLES $546.35 ODOR CONTROL CONSULTANT
102128 WELLS FARGO GUARD SERVICE B1.29C.60 CAM SERVICES
LAB SERVICES
102130 WESTERN STATE CHEMICAL SUPPLY 132.351.46 CAUSTIC SODA M.0.8_10-86
102231 WEST-LITE SUPPLY CO. $395.28 ELECTRIC SUPPLIES
<' 302133 AEROA CORP. 52.770.89 COPIER LEASES
ee Vl -----------------
TOTAL CLAIMS PAID 69/13/89 $3,442,263.35
3;
Ol FUND NO 9199 — JT DIST WORKING CAPITAL PROCESSING DATE 09/06/69 PAGE 6
REPORT NUMBER M43
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY
CLAIMS PAID 09/13/89 POSTING DATE 09/13/89
SUMMARY AMOUNT
s
e� 92 OPER FUND 5,523.58
F2 AGO FUND 149,418.15
nUP" 59239
rn Ss OPER FUND 15,707.1E
g F5 All FUND 274.10
0
n ;�I 06 AM FUND 62,795.41
O OPER PUND_ 9.132.18
m Pll OPER FUND 74.62
,e! F14 ACO POND 43,101.19
•031.01
00 P� 9566 AM FUND 280.00
F667 OPEN FUND 2,686.48
lac a1 17 .
3. JT OPER FUND 460,788.90
CORF 2,502,232.16
p ' JT DIST WORKING CAPITAL FUND 155.213.48
CA
I
Iw
� Iw'
FUND NO( 9199 - JT DIST WORKING CAt ITAL PROCESSING 06TE 9/21/89 PAGE I
REPORT NUMBER AP43
I CLAIMS PAID 09/27/89 POSTING DATE 09/27/89
a H
WARRANT NO. V,NnnR .fflINT
102149 ABC VIDEO. INC. $119.50 INSTRUMENT REPAIR
n
102151 AIRPAK CORP. CAME IDGE DIV. 5495.72 CIRCUIT BREAKER
102152 LEASING ASSOCIATES/ALLSTtTE $1,290.34 AUTOMOBILE LEASES
aI 1C2154 ROBCO INC. E/OR AMERICAN SEALS $4,267.44 BAKDNARH
262155 AMERITECH $97.52 COPIER LEASES
IC2157 ANISTER - 1111 1 CABLE $743.98 E.ECTROMIC SUPPLIES
202158 ARATEK SERVICES, INC. S316.69 UNIFORM RENTALS
1e 102160 ATLAS CHRYSLER PLYMOUTH t3,6Be.61 TRUCK PARTS
102161 AUTO SHOP EQUIPMENT CO. S260.UG TRUCK PARTS
Z
1° D 102163 FALCON DISPOSAL SERVICE $60,912.45 GRIT REMOVAL M.0.7-13-88
102164 BANK OF AMEFICA-C.A.S.C. $8,486.13 ADKIMISTEATION PER - CEATIF. OF PARTICIPATION
ITT 102166 P.Y. BAROTTI AND ASSOC. S5.520.06 CONSTRUCTION SERVICES PI-25.26,P2-32.33.34.37
3 102167 B. BATEMAN 5575.GO DEFERRED COMP DISTRIBUTION
a 'f0 102169 BARTER SCIENTIFIC PRODUCTS S29962.54 LAB SUPPLIES
xl I 102270 ROBERT BEIN,NILLIAM FROST 1 AS $4,939.55 ENGINEERING SERVECES 5-31
T 17, an,cr reerenr nrr,fr c nM „
n 102272 BOLTRONIR CATA MAINTENANCE Yr $275.00 MAINTENANCE CONTRACT
r 102173 BROOK LYN THERMOMETER CO.. INC. S9B.6P LAB SUPPLIES
r ,n:,7a Ronuu t re run mae♦_c/ ,.e RRMIre
u CJ 102175 BROWN 1 CALDWELL CONSULTING $1.928.16 ENGINEERING SERVICES PI-35, P2-39
N 102176 GARY G. STREED $805.91 PETTY CASH REIMBURSPOUNT
S 10217E CFT CORPORATION SP4.74 OFFICE SUPPLIES
202179 CRC PRESS , INC. $132.50 CHEMICALS
m� ♦02162 rS -GLASS I wr
j� 102182 CAL-GLASS INC RESEARCH. INC. 5662.5E LAB RETIRES
102182 [AL TROL ♦ INC. S3♦260.]3 REGULATOR PARTS
ID2284 CASE POWER A EQUIPMENT S346.67 TRUCK PARTS
102185 CENTURY PAINT 2172.14 PAINT
102187 CHEMVEST INDUSTRIES, INC. $68.943.35 FERRIC CHLORIDE M.0.11-09-88
102188 CHEVRON U.S.A.. INC. S979.44 CRE"R 6 OIL
to 102190 COMPRESSOR COMPONENTS OF CtLIF $1.179.05 BEARINGS
102191 CONFUTER DATACOM S1.413.68 OFFICE SUPPLIES
gel 102193 HUNG LONG 445.60 EMPLOYEE MILEAGE
'y ]02194 CONNELL C.M. PARTS / DIV. 5155.5C TRUCK PARTS
N
FUND NO 9199 - JT UIST WORKING CAPITAL PROCESSING OATE 9/20169 PAGE 2
REPORT NUPBER AP43
CLAIMS PAID 59/27/89 POSTING DATE C9/27/89
a
162195 CON-WAY WESTERN EXPRESS $79.24 FREIGHT
162197 CONTINENTAL GRAPHICS $7.046.97 BLUEPRINTING
102198 CORMIER SUZUKI 5686.69 SALES In
° n 102200 COUNTY WHOLESALE ELECTRIC $1.277.49 ELECTRIC SUPPLIES
m 102201 CAL WATER $15.46 RENTAL EQUIPMENT
D 202203 ONE, INC. E815.9C FITTINGS
102204 DAILY PILOT $66.00 NOTICES A ADS
TEST EQUIPMENT
f l 102206 DE2URIK AHD/OR CS CO. $1,688.05 VALVE
r 3 102207 DIATEC POLYMERS E2.d11.2• ANIONIC POLYMER M.0.8-10-88
Y•r`^'1NG
1° Ri 102289 DORADO ENTERPRISES, INC. 52.960.P0 PLANT MAINTENANCE 6 REPAIR
CD 102210 FRANK DRYDEN A ASSOC. E300.90 SCRUBBER INSPECTION
.nP,n c.r_i _ ru c,Rouru,e. rur_ upy.,n ++.�.+,• s_ALIRs
LWr- 1C2212 EASTMAN, INC. 3317.66 OFFICE SUPPLIES
102213
rr ECCANALYSIS. INC. E2737.78 OCRAN MONITORING
rA223A
YRBR =ATT0W AIMS
f' 102215 ENCHANTER. INC. $2,380.00 OUTFALL VIDEO
�r C7 102216 ERNST A WHINNEY E9.900.30 CONSULTING SERVICES - CLASSIFICATION STUDY
.u<-ND AND r S34G RIAA➢ USE
_., 102219 FAT SAND AND GRAVEL. INC. $3AG.29 ROAD BASE CO"
� 302219 MARGHALL FA IPREB E39J.1C DEFERRED 014 DISTRIBUTION
102220 FANu SALES
I SERVICE
c •y o• 00 FILTERIlfTi0Y 6JIRYSfSi J-20 17-A
� 102222 FARR SALEB 8 SEP VICE $536SIT7.00 AIR PBEICNT
IIb 102224 FISCHEP E FCRTER CO. E4.929.08 CHLORINATION PARTS
202.25 FLAT A VERTICAL CONCRETE E395.1J CONCRETE CUTTING
rro,>c ci n.<vcrrN< i38e ELEfT°
102227 FOUNTAIN VALLEY CAMERA 5551-.30 FILM J
102228 FOX ENTERPPISE$ E1.825.06 SAFETY CONSULTING
U 102230 FROST E146INEERING SEPVICES CO. $78.77 VALVE PARTS
1 J2231 CITY OF FULLERTON $137.86 WATER USEACE
°tI 102233 GATES FIBERGLASS INSTALLERS E1.689.OG REPAIR MANIFOLD
WI 302234 GENERAL TELEPHONE CO. $6,746.29 TELEPHONE
302236 GIERLICH-MITCHELL. INC. S5.9J2.33 ELECTRIC PARTS
1C2237 GOLDEN COAST BIOMASS ENEFGY CO $3,816.04 SAWDUST
"'1I7,1J IC2239 MALPRIN SUPPLY CO. • S7.1P OPERATING SUPPLIES
Al 102296 FR ED A. RAPPER 33.R50.00 DEFERRED COIB DISTRIBUTION
W
FUND No 9199 - JT GIST WORKING CAPITAL PROCESSING DATE 9/23104 PAGE 3
L REPORT NUMBER AP43
CLAIMS PAID 09/27/89 POSTING DATE 09/27/89
s
102241 HARRINGTON INDUSTRIAL PLASTICS S1.311.33 INSTRUMENT PART
102243 S. A. HEALY CO. $327♦713.87 CONSTRUCTION PI-35-1
132244 HOERPIGER C.V.S. CALIF. ♦ INC. S3♦382.C6 MECHANICAL PARTS
• 302216 DONALD D. HONOMICHL 5376.00 DEFERR®'COMP DISTRIBUTION
Pm 1022.7 R.S. HUGHES Co., INC. S1♦'115.29 SAFETY SUPPLIES
1npPYp NIINT IN6TOP PP1fN p Ppra cieYp tLt l_a ws
r D 202249 HUNTINGTON VALLEY SCHVINN CYCL S54.03 BICYCLE PUTS
102250 INDUSTRIAL THREADED PRODUCTS 5578.05 CONNECTORS
' —4 102252 INLAND EMPIRE EQUIPMENT CO. S1.322.9W EQUIPMENT RENTAL
IL2253
IRVINE RANCH WATER DISTRICT $17.35 WATER USEAGE
102255 RIVIERA FINANCE S526.01 JANITORIAL SUPPLIES
CK) 102256 DAVID JENKINS S ASSOC.. INC. $2.905.35 SOURCE CONTROL CONSULTING
102258 KALLEEN•S CCMPUTER SUPPLIES 5159.99 OFFICE SUPPLIES
" n 1G2259 KAMAN BEAPIAGS S SUPFLY $784.28 FITTINGS
r
102211 KEENAN 6 ASSOCIATES S3.162.59 WORKERS COKP ADKINISTRATION
102262 KEENAN SUPPLY S190.16 VALVE
IC 2264 KING BEARING• INC. $9,162.57 MACHINE SUPPLIES
102265 DONALD E. KINNEY $815.I9 DEFERRED CON? DISTRIBUTION
102267 MARTIN KORDICK♦ SR $2.972.10 CONSTRUCTION SERVICES 14-1.2-26
N 102268 L48 SAFETY SUPPLY CO. $614.34 YLCTRIC PARTS
102270 LIMITORQUC CORP. 321.376.81 VALVE
102271 MPS $191.86 PHOTOGRAPHIC SERVICES
102273 MARVAC ELECTRONICS S1.052.75 INSTRUMENT SUPPLIES
102274 MASTER TOOLS SERVICES S331.57 TOOL REPAIR
102276 MCKENNA ENGP. C EOUIP. S2♦198.90 PUMP PARTS
112277 MCMAST EP-CAPP SUPPLY Co. S1.828.45 HARDWARE
r
102279 METER CRAFT INC. $79.21 METER
I02280 MICRO MOTION $3.357.69 INSTRUKENT REPAIR
.•
jh 1022P2 SEPPENTIN AND/ S4♦757.42 NECHANIOAL Mpa PARTS l 102283 MLADEN PUNTICH CONSTRUCTION CO 338.213.82 CONSTRUCTION 3-34R
i.".. Ilk" Nncr eNn 6YTP elll .f f,lrSr a{4_9P
ri b7 1022E5 MONOIGAN TREES $583.33 WNDSCAPING SUPPLIES
�W 102286 MOTION INDUSTRIES. INC. $222.68 MECHANICAL PARTS
F
FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/20/89 PAGE 4
[- REPORT NUMBER AP43
CLAIMS PAID 09/27/89 POSTING DATE 09/27/89
I° 102287 NO PRODUCTS, INC. 1229.34 PIPE SUPPLIES
102299 NEUTRON 5450.OU EENTAL EQUIPMENT
e
162290 NEWARK ELECTRONICS $273.75 ELECTRIC SUPPLIES
1O� 102292 OFFICIAL AIRLINE GUIDES 5335.D0 PUBLICATION
m 102293 OSU/SMEAC. 831.1J PUBLICATION
v
Y7 102295 ORANGE COUNTY AUTO PARTS CO. S1,O2O.87 TRUCE PASTS
10229E ORANGE COUNTY FARM SUPPLY CO. S1.376.11 LANDSCAPING SUPPLIES
162258 0 GE VALVE 0 FITTING CO. $299.74 FITTINGS
"m 102299 OSCAR�S LOCK S SAFE $47.45 KETS
n3
1°3t 102301 COUNTY SANITATION DISTRICT 583.92 DEFERRED COMP DISTRIBUTION
�I00 102302 COUNTY SANITATION DISTRICT $3.324.35 RIEDURRSE WORKERS COIF INSURANCE
n vvnv ne eurc rn. m nnn nu.o n 1 _ <c2J1' ST • nn°° 9 nnuSTEUC WI— T°
IC2304 Cl IC PARTS m n <, ^�1d'°56,259.19 INSTRUMENT PARTS
ID 102305 PACIFIC PROCESS EOUIPMENT.INC. 5438.P4 PUP PARTS
Wr I .' e.r,°,r --. 1�_ "130' is SABE2Y-sn°°I.Iss
102307 PACIFIC BELL 9664.48 TELEPHONE
t7 182308 PAINE A ASSOCIATES $8.271.25 COMMUNITY RELATIONS CONSULTING
1pgXrq 'ON' " RAW
102310 PARTS UNLIMITED $1,762.2A AUTOMOTIVE PARTS
m 102312 FEAT, MARWICK, MAIN S CO. 34,62B.D7 AUDITING SERVICES
S40O •. Dvvvoovn nwn nISTHIHVT10u
102313 PHOTOr 6nSOUND vCO. $6,656.44 COMPUTER EQUIPMENT
�NiC 102314 PIMA GRO SYSTEMS. INC. $89,602.45 SLUDGE REMOVAL M.0.5-11-88
102316 PLAN-SAK $122.75 MAILING SUPPLIES
102317 POLYPURE, INC. 320,46B.u3 CATIONIC POLYMER M.0.3-8-89
102319 HAROLD PRIMROSE ICE $180.09 ICE
102320 THE PRD JECTS SOLUTION CO. $4,240.00 INSTRUMENTATION INSPECTION N.O. 8-10-88
ENGINEERING PLANS REVISIONS
102322 RAINBOW DISFOSAL CO. SA34.J3 TRASH REMOVAL
102323 R.D SYSTEMS, INC. 3368.2C INSTRUENT REPAIR
302325 FEDI EMPRESS 33 J.CC MESSENGER SERVICES
1G2326 THE REGISTER 5900.37 NOTICES 6 ADS
162328 REMOTE METER RESETTING SYSTEM 33,600.Dr POSTAGE
1D2329 THE REPUBLIC SUFFLY CC. S1B5.71 HARDWARE
° CO 102331 JOSEPH T. RYERSON A SON. INC. $1,780.45 METAL
° 102332 SANCON ENGINEERING , INC. $8,950.00 SEWER REPAIRS
� F
yl
_ FUND NO 9199 - JT DIST NOR°ING CAPITAL PROCESSING DATE 9/20/R9 PAGE 5
REPORT NUMBER AP43
CLAIMS PAID 09/27/89 POSTING DATE 09/27/B9
la
le 102333 SEA COAST DESIGNS $354.02 OFFICE FURNIT➢RE
' 102335 SHAMROCN SUPPLY $62.06 SAFETY SUPPLIES
° 102336 SIERRA EVIR ON.ENGP..INC. 59.830.00 ENGINEERING SERVICES - VOC TESTING
102338 SMITH PIPE S SUPPLY. INC $336.71 PLUMBING SUPPLIES
z 102339 SOIL AND TESTING ENGINEERS $348.16 SOIL TESTING
102341 SOUTHERN CALIF. EDISON CO. 1441.02248, POWER
102342 $0. CAL. GAS CO. $287.53 NATURAL CAS
n 3 IG2344 SOUTHERN COUNTIES OIL CO. $4,156.21 DIESEL FUEL
e
102345 SPARKLETTS DRINKING WATER 52.183.62 DRINKING WATER/COOLER RENTALS
1°00 102347 STAR TOOL S SUPPLY CO. $1,483.96 TOOLS
s 1 182348 STERLING ART 332.30 OFFICE SUPPLIES
1n P A09 cn xYli cTPcl ..-Ill .. 16TAL
l iD> 102350 SUPELCC. INC. S1.U34.60 LAB SUPPLIES
r 102351 CONTINENTAL AIR TOOL. INC. $1,217.04 TOOLS
102353 TAK TAKAMINE 5360.00 LANSCAPING SUPPLIES
ii° 202354 TAYLOR-DUNN 5438.99 TRUCK PARTS
.n2955 olrueRn _ it u9 ..e_ee NFLNAGR RT�BNI'
102356 THERMO ANALYTICAL. INC./NORCAL 5315.C9 LAB SERVICES
102357 CHARLES E. THOMAS 5632.99 TRUCK PARTS
102359 TOTAL PREVENTION SYSTEMS $6.174.9C ENGINEERING SERVICES PI-27-1
102360 TRAFFIC CONTROL SERVICE. INC. 57.150.OG TRAFFIC CONTROL SERVICES ➢IST 2
in"" TY°vri I.I.F. c-r- ..... .......
112362 T.S. TRIPP S11U40.D0 WINDOW WASHING
102363 TRUCK L UT AO SUPPLY. INC. E164.94 TRUCK PARTS
INC
PARTS
102365 U.S. WATER RE US 539.00 SUBSCRIPTION
- 6. 102366 UNDERGROUND SERVICE ALERT $156.JO MEMBERSHIP FEES
102368 UNITED WESTERN ELEVATOR $326.15 SERVICE AGREEMENT
2369 UPJ041 HEALTHCARE GEN VICES 5490.00 CPR TRALMING
1 P1,0117P9
IS2371 VALLEY CITIES SUPPLY CO. S8.B76.43 FITTINGS
Le 102372 VARIAN INSTRUMENT DIVISION $632.42 LAB REPAIRS
W 102379 VEPTEK SYSTEMS $5.235.00 COMPUTER SUPPORT
-.iy A 102375 VIKING INDUSTRIAL SUPPLY 511.36 FREIGHT
0
1C2377 WELLS FARGO GUARD SERVICE 32,359.83 GUARD SERVICES
IP" 102318 WEST COAST ANALYTICAL SPY. 510.00 LAB SERVICES
z
s
FUND NO 0199 - JT DIST HORNING CAPITAL PROCESSING DATE 9/24/89 PAGE 6
REPORT NUMBER AP43
a
CLAIMS PAID 09/27/69 POSTING DATE 09/27/89
a
° 102379 WESTERN METRO SUPPLY $13.19 MIGHT
° 102381 WEST-LITE SUPPLY CO. $933.54 ELECTRIC SUPPLIES
° 102382 ROURKE A WOGDRUFF $36,919.97 LEGAL SERVICES M.0.6-04-89
° CONSULTING SERVICES
1O a 102384 :IC
YOUNG PROD. 33u2.10 OFFICE SUPPLIES
Fri
m 102385 RICH ARD S. EDGAR $269.00 DEFERRED COMP DISTRIBUTION
a
u l7
a a TOTAL CLAIMS PAID 69/27/89 S1.782.064.18
a --1
° m
u 3 SUIOIARY AMOUNT
QO /1 OPER FUND 9 1.111.77
Al CONST Fuero 1,79791.9494
vFLKy /2 AGO FUND 63.187.62
A2 CONST FUND 3.213.88
u 334.91
p 03 ADD FUND �228.00
n . 03 CONST FOND 3.482.31
2. A /5 AGO FUND 15,365.92
06 OPER FUND 1,325.18
go Acu FUND 156.76
11 N 0
7 OPER FUND 10.915.40
07 AGO FUND 1,447.00
All AGO FUND 3.30
ae 013 OPER FOND 126.48
A14 AGO FUND 1,596.84
0566 OPER FUND 3.070.43
3,716.93
0667 OPER FUND 36.28
A7414 OPER FUND 3.394.3E
CORP 439,688.74
SELF FUNDED WORKERS COMP INSURANCE FUND 11.268.85
6.529.26
$ L.782,064.78
EDI
m
RESOLUTION NO. 89-138
AWARDING CONTRACT FOR PURCHASE OF CHLORINE
IN BULK, SPECIFICATION NO. C-025
A JOINT RESOLUTION OF THE BOARDS OF DIRECTORS OF
COUNTY SANITATION DISTRICTS NOS. 1, 2, 3, 5, 6, 7,
11, 13 AND 14 OF ORANGE COUNTY, CALIFORNIA, AWARDING
CONTRACT FOR PURCHASE OF CHLORINE IN BULK,
SPECIFICATION NO. C-025, TO OLYMPIC CHEMICAL COMPANY
k k k # # k k # # # # k k k # # k #
The Boards of Directors of County Sanitation Districts Nos. 1, 2, 3, 5, 6,
7, 11, 13 and 14 of Orange County, California,
DO HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That the written recommendation this day submitted to the
Boards of Directors by the Districts' Purchasing Manager that award of purchase
contract be made to Olympic Chemical Company for Purchase of Chlorine in Bulk,
Specification No. C-025, and the bid tabulation and recommendation, and proposal
submitted for said specification are hereby received and ordered filed; and,
Section 2. That said purchase contract for Specification No. C-025 be
awarded to Olympic Chemical Company at the unit price of $212.70 per ton plus
sales tax, furnished and delivered in accordance with the terms and conditions
of said specification and the bid proposal therefor; and,
Section 3. That the Chairman and Secretary of County Sanitation District
No. 1, on behalf of itself and Districts Nos. 2, 3, 5, 6, 7, 11, 13 and 14, are
hereby authorized and directed to enter into and sign a purchase contract with
said supplier to supply chlorine pursuant to the specifications and purchase
contract documents therefor, in form approved by the General Counsel ; and,
Section 4. That all other bids received for said work are hereby
rejected.
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
"C-:" AGENDA ITEM #9(a) - ALL DISTRICTS 11C-1"
MEMORANDUM COUNTY SANNATION DISTRICTS
of ONANOE COUNTY. CAUFORNIA
r.aew Etn
fWWP VAY ..CPlMR"W2 8127
UE
To: J. Wayne Sylvester, General Manager 1®V eL6AAEI
yn y g WUWNN VGnEY,GIIPoNML 822(IB./1�
p14�10
RE: Purchase of Chlorine in Bulk, 914)MR 11
Specification No. C-025
Sealed bids were opened Tuesday, September 5, 1989 for the
purchase and delivery of Chlorine in Bulk for a one year period,
beginning November 1, 1989.
Tabulation of Bids as follows:
Unit Price
Vendor Per ton
1. Olympic Chemical Co. $212.70
Orange, CA
2. All Pure Chemical Co. $260.00
Santa Fe Springs, CA
It is recommended the award be made to Olympic Chemical Company,
low bidder, for a one year contract period, starting November 1,
1989. The total estimated annual cost of $1, 340,010.00, plus sales
tax, is based on furnishing 6, 300 tons at a unit price of $212.70
per ton. The new bid price is higher than the existing contract
with Olympic Chemical by $33 .20 per ton. Provisions are in the
specifications for a one year contract extension.
Respectfully submitted:
Ted Hof£ma%f,
Purchasing MaLger
We hereby concur with the above recommendation:
G ry G. S. eed, '
Chief Ad T nistrative Assistant and
Act(i-1/ng, (Director of Finance
Bob ooten,
Assistant Superintendent
"C-2" AGENDA ITEM #9(a) - ALL DISTRICTS "C-2"
t
RESOLUTION NO. 89-139
AWARDING CONTRACT FOR PURCHASE OF CHLORINE
IN ONE-TON CYLINDERS. SPECIFICATI N N . C- 26
A JOINT RESOLUTION OF THE BOARDS OF DIRECTORS OF
COUNTY SANITATION DISTRICTS NOS. 1, 2, 3, 5, 6, 7,
11, 13 AND 14 OF ORANGE COUNTY, CALIFORNIA, AWARDING
CONTRACT FOR PURCHASE OF CHLORINE IN ONE-TON CYLINDERS,
SPECIFICATION NO. C-026, TO CONTINENTAL CHEMICAL
COMPANY
* k * k k k k k k k k k k k k k k k
The Boards of Directors of County Sanitation Districts Nos. 1, 2, 3, 5, 6,
7, 11, 13 and 14 of Orange County, California,
DO HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That the written recommendation this day submitted to the
Boards of Directors by the Districts' Purchasing Manager that award of contract
be made to Continental Chemical Company for Purchase of Chlorine in One-Tan
Cylinders, Specification No. C-026, and the bid tabulation and proposal
submitted for said specification are hereby received and ordered filed; and,
Section 2. That said purchase contract for Specification No. C-026 be
awarded to Continental Chemical Company at the price of $265.00 per ton plus
sales tax, furnished and delivered in accordance with the terms and conditions
of said specification and the bid proposal therefor; and,
Section 3. That the Chairman and Secretary of County Sanitation District
No. 1, on behalf of itself and Districts Nos. 2, 3, 5, 6, 7, 11, 13 and 14, are
hereby authorized and directed to enter into and sign a contract with said
supplier to supply chlorine pursuant to the specifications and contract
documents therefor, in form approved by the General Counsel ; and,
Section 4. That all other bids received for said work are hereby
rejected.
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
"D-1" AGENDA ITEM #9(b) - ALL DISTRICTS "D-1"
September 18, 1989 COUNTY SANITATION DISTRICTS
of ORANGE COUNTY, CALIFORNIA
MEMORANDUM
P 0.BOX 8127
To: J. Wayne Sylvester FOUNTAIN VALLEY.CAAAMMIA 92728-91V
Y Y 10860 EW6 AVENUE 1
FOUMAW vALLEY,CAUFOaNIA 92>OB-�(1{1Y�
Fm: Ted Hoffman n1A�sa0.2s1a
0191962-2411
Subject: PURCHASE OF CHLORINE IN ONE-TON CYLINDERS,
SPECIFICATION NO. C-026
Sealed bids were opened Tuesday, September 5, 1989 for the purchase
and delivery of Chlorine in One-Ton Cylinders, for a one year
period, beginning November 1, 1989.
Tabulation of bids is as follows:
Supplier Unit price per ton
1. Continental Chemical Company $265.00
Sacramento, CA
2 . Olympic Chemical 337.80
Orange, CA
3 . All Pure Chemical Company 375.00
Santa Fe Springs, CA
It is recommended the award be made to Continental Chemical
Company, for a one-year period, beginning November 1, 1989. The
total estimated cost of $159,000.00, plus sales tax, is based on
furnishing 600 tons at a unit price of $265.00 per ton, plus sales
\ tax._
Ted Hoffman,
Purchasing Manager
We hereby concur with the above recommendation:
Gaky G. S$ eed,
Chief A nistrative Assistant and
Acting Director of Finance
A
1 t I �
Bob Ooten,
Assistant Superintendent
"D-2" AGENDA ITEM #9(b) - ALL DISTRICTS "D-2"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 1 of 3
P. 0. BOX 8127 - 10844 ELLIS AVENUE
�..� FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C.O. NO. Twelve (12)
CONTRACTOR: J. R. Roberts Corporation DATE September 18, 1989
JOB: ADMINISTRATION BUILDING ADDITION, JOB NO. J-7-4
Amount of this Change Order (Add) (Deduet) $ 4,530.00
In accordance with contract provisions, the following changes in the contract
and/or contract work are hereby authorized and as compensation therefor, the
following additions to or deductions from the contract price are hereby approved.
Item 1 LOW VOLTAGE LIGHTING PANEL ADDITION
The Contractor was directed to furnish and install a new eight circuit low
voltage lighting relay panel in Room 104 of the new South Wing. The additional
relay panel was required by the Districts' representative to facilitate
independent operation of lighting and fan circuits in Bathrooms 113, 116 and
118. Also included in this change order item is the furnishing and installation
of fifty switch box extensions for the interior partition office walls in order
to provide clearance for lighting switches. The additional relay panel and
wiring was not shown on the contract drawings nor included in the contract
specifications. This work was negotiated pursuant to Section 10-6(b)2(B) of the
General Provisions. (Reference: PCH #46)
ADDED COST THIS CHANGE ORDER ITEM $ 2,851.00
TIME EXTENSION THIS CHANGE ORDER 0 Calendar Days
Item 2 BATHROOM CERAMIC TILE ADDITION
The Contractor was directed to add additional ceramic tile around the light
switches and paper towel dispensers above the tile wainscot in Bathrooms 113,
116 and 118. This tile addition was requested by the Districts' representative
in order to provide finished tile trim surfaces where light switch boxes and
paper towel dispensers continue above the tile wainscot. The above additional
tile work was not shown on the contract drawings or included in the contract
specifications. This work was negotiated pursuant to Section 10-6(b)2(A) of the
General Provisions. (Reference: FCO #53)
ADDED COST THIS CHANGE ORDER ITEM $ 664.00
TIME EXTENSION THIS CHANGE ORDER 0 Calendar Days
"E-1" AGENDA ITEM #9(d) - ALL DISTRICTS "E-I
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 2 of 3
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92798
CHANGE ORDER
C.O. NO. Twelve (12)
CONTRACTOR: J. R. Roberts Corporation DATE September
JOB: ADMINISTRATION BUILDING ADDITION, JOB NO. J-7-4
Item 3 PLUMBING CHANGES
The Contractor was directed to change the plumbing in several locations in the new
South Wing. These changes included adding two recessed cold water valves in
Kitchen 126 for future connection to vending machines; rerouting of Kitchen 126
sink vent which conflicted with electrical boxes; relocation of 2-inch water lines
under air handling units that conflicted with installation of additional roof
trusses under contract Change Order No. 9, Item 3. These changes were requested
by the Districts' representative and were not shown on the contract plans or
included in the contract specifictions. This work was negotiated pursuant to
Section 10-6(b)2(B) of the General Provisions. (Reference: FCO #55)
ADDED COST THIS CHANGE ORDER ITEM: $ 1,015.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
TOTAL ADDED COST THIS CHANGE ORDER: $ 4,530.00
TOTAL TIME EXTENSION THIS CHANGE ORDER: 0 Calendar Days
The additional work contained within this Change Order can be performed incidental
to the prime work and within the time allotted for the original Contract and any
revisions to the Contract Time made by this and any previously issued Change
Orders. It is therefore mutually agreed that no time is required for this
Change Order, and no direct or indirect, incidental or consequential costs or
expenses have been or will be incurred by the Contractor.
�a✓
"E-2" AGENDA ITEM #9(d) - ALL DISTRICTS "E-2"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 3 of 3
P. 0. BOX 8127 - 10844 ELLIS AVENUE
�./ FOUNTAIN VALLEY, CALIFORNIA 92798
CHANGE ORDER
C.O. NO. Twelve (12)
CONTRACTOR: J. R. Roberts Corporation DATE September
JOB: ADMINISTRATION BUILDING ADDITION, JOB NO. J-7-4
SUMMARY OF CONTRACT TIME
Original Contract Date July 11, 1988
Original Contract Time 602 Calendar Days
Original Completion Date March 4, 1990
Time Extension this C.O. 0 Calendar Days
Total Time Extension 80 Calendar Days
Revised Contract Time 682 Calendar Days
Revised Final Completion Due Date May 23, 1990
Time Subject to Liquidated Damages Not Applicable
Actual Final Completion Date Not Applicable
Original Contract Price S 3,549,000.00
Prev. Auth. Changes SOU—
This Change (Add) (Sedwet) $ :53050
Amended Contract Price $ 3,883,654.00
Board Authorization Date: October 11, 1989
COUNTY SANITATION DISTRICTS
OF ORANGE COUNTY, CALIFORNIA
RECOMMENDED BY:
Con ruction Manager Date
J. R. ROBERTS CORPORATION
ACC T BY: APPRO
o tractor ate Director of Engineering Date
"E-3" AGENDA ITEM #9(d) - ALL DISTRICTS "E-3"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 1 of 4
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708 �...�
CHANGE ORDER
C. 0. N0. Twent 20
CONTRACTOR: ADVANCO CONSTRUCTORS, INC. DATE Octc er 11, 1
JOB: OCEAN OUTFALL BOOSTER STATION "C" AT PLANT NO. 2, JOB NO. J-1S
Amount of this Change Order (Add) (gedust) E 17,165.82
In accordance with contract provisions, the following changes in the contract
and/or contract work are hereby authorized and as compensation therefor, the
following additions to or deductions from the contract price are hereby approved.
ITEM 1 - UNLOAD AND TRANSPORT PIPE SECTIONS
In order to protect the engines, motors and pumps at the Rothrock and Foster
Pumping Stations from the effects of sandblasting and spray painting, the
Contractor was directed to off load, sandblast and paint in a remote yard and
then reload and haul to their final placement, the final two 120-inch diameter by
40-foot long sections of the outfall main. These sections sit between and
immediately adjacent to the two pump stations and, due to the fact that the
engines and pumps cannot stop operating, the work was performed elsewhere. This
work was accomplished by Contractor's force account pursuant to Section 10-6(b)28
of the General Provisions. (Reference: PCH 105)
ADDED COST THIS CHANGE ORDER ITEM: E 6,473.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
ITEM 2 - TEMPORARY ELECTRICAL POWER
The J-15A Contractor, General Electric Company, was directed to move their
equipment (2500 horse power electric motors, load commutator invertors, reactors,
etc.) into the building to facilitate the construction schedule. This equipment
requires electrical power for heating while it is in storage and permanent power
was not yet available. Therefore, the J-15 Contractor was instructed to provide
temporary power to protect the equipment from damage from the environment for a
period from 9/26/88 through 2/15/89. This work was accomplished by Contractor's
force account pursuant to Section 10-6(b)(2)8 of the General Provisions.
(Reference: ACI No. 9113)
ADDED COST THIS CHANGE ORDER ITEM: E 1,835.82
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"F-1" AGENDA ITEM #9(e) - ALL DISTRICTS "F-1"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 2 of 4
P. 0. BOX 8127 - 10844 ELLIS AVENUE
�.,.' FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. N0. Twent (20)
CONTRACTOR: ADVANCO CONSTRUCTORS, INC. DATE Octo er 98
JOB: OCEAN OUTFALL BOOSTER STATION "C" AT PLANT NO. 2, JOB NO. J-15
Item 3 - MODIFY BUBBLER PANELS
The bubbler system is a means of determining the level of water in the wet well of
the pumping station. The contract specifications did not provide for a back-up
power source for the system to continue to operate in the event of computer
control system failure. The Contractor was instructed to provide a 24-volt OC
power supply along with an air-operated "blow down" system that would clean the
instrumentation tubing periodically to assure proper operation. This work was
accomplished by Contractor's force account pursuant to Section 10-6(b)2B of the
General Provisions. (Reference: PCH 94)
ADDED COST THIS CHANGE ORDER ITEM: $ 1,802.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 4 - HARMONIC FILTERS
Upon testing of the newly installed electrical equipment in the pumping station,
there appears to be a harmonic distortion created that has an adverse effect on
existing breakers in the 12KV Service Center. The Contractor was instructed to
furnish and install two harmonic filters on two voltage unbalance relays. This
work was accomplished by Contractor's force account pursuant to Section
10-6(b)(2)B of the General Provisions. (Reference: PCH 106)
ADDED COST THIS CHANGE ORDER ITEM: $ 1,696.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 5 - SKYLIGHT HANDRAIL
A total of four 2 x 4 wooden framing handrails were construction around skylights
on the roof of the pumping station for the protection of personnel, insuring that
they would not step on or fall through the skylights. This work was accomplished
by Contractor's force account pursuant to Section 10-6(b)(2)B of the General
Provisions. (Reference: PCH 107)
ADDED COST THIS CHANGE ORDER ITEM: $ 1,806.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"F-2" AGENDA ITEM #9(e) - ALL DISTRICTS -F-2"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 3 of 4
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Twent (20)
CONTRACTOR: ADVANCO CONSTRUCTORS, INC. DATE Octo ell, 198T
JOB: OCEAN OUTFALL BOOSTER STATION "C" AT PLANT NO. 2, JOB NO: J-15
Item 6 - CABLE TRAY SLAB CLOSURE
The two electrical cable trays penetrating the main floor of the pumping station
had a hole in the floor that was much larger than the tray. This provided a
12-inch open space that created a safety hazard for personnel . Aluminum-checkered
plate of 2 by 6 feet with supporting angles was placed around the openings. This
work was accomplished by Contractor's force account pursuant to Section 10-6(b)2B
of the General Provisions. (Reference: PCH 108)
ADDED COST THIS CHANGE ORDER ITEM: $ 928.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 7 - AIR CONDITIONER ALARM
The air conditioning system is essential to maintaining operations of the variable
frequency drives during high load, high temperature conditions. It is necessary
to respond quickly to any failure of an operating air conditioning unit. The
Contractor was instructed to provide for the modification of the computer control
system by adding control logic for alarm purposes. This work was negotiated
with the Contractor pursuant to Section 10-6(b)2A of the General Provisions.
(Reference: PCH 038A)
ADDED COST THIS CHANGE ORDER ITEM: $ 2,625.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
TOTAL ADDED COST THIS CHANGE ORDER: $ 17,165.82
TOTAL TIME EXTENSION THIS CHANGE ORDER: 0 Calendar Days
The additional work contained within this Change Order can be performed incidental
to the prime work and within the time allotted for the original Contract and any
revisions to the Contract Time made by this and any previously issued Change
Orders. It is therefore mutually agreed that no time is required for this
Change Order, and no direct or indirect, incidental or consequential costs or
expenses have been or will be incurred by the Contractor.
-F-3" AGENDA ITEM #9(e) - ALL DISTRICTS "F-3"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 4 of 4
�..' P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Twent (20)
CONTRACTOR: ADVANCO CONSTRUCTORS, INC. DATE October 11, 1989
JOB: OCEAN OUTFALL BOOSTER STATION "C" AT PLANT NO. 2, JOB NO. J-15
SUMMARY OF CONTRACT TIME
Original Contract Date July 20, 1987
Original Contract Time 940 Calendar Days
Original Completion Date February 13, 1990
Time Extension This C.O. 0 Calendar Days
Total Time Extension 74 Calendar Days
Revised Contract Time 1014 Calendar Days
Revised Completion Date April 28, 1990
Actual Final Completion Date Not Applicable
Time Subject to Liquidated Damages Not Applicable
Original Contract Price $18,476,243.00
Prev. Auth. Changes $-4ft.MT79
This Change (Add) (Dedust)B�,1bb.8Z
Amended Contract Price ,405,345.E
Board Authorization Date: October 11, 1989
COUNTY SANITATION DISTRICTS OF
ORANGE COUNTY, CALIFORNIA
RECOMMENDED BY:
9' 9 Zd-a
on ruc on manager Date
ADVANCO CONSTRUCTORS, INC.
ACCEPTED BY: APPRO Y://
o f act r Uirector of Engineering 7ae
"F-4" AGENDA ITEM #9(e) - ALL DISTRICTS "F-4"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 1 of 5
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Twent�Two (22)
CONTRACTOR: Kiewit Pacific Co. DATE Octo e� 11,1989
JOB: HEADWORKS NO. 2 AT PLANT N0. 1 JOB No. P1-20; AND DEMOLITION OF DIGESTERS
EMENT I PIPING LE ; AND GRADING AND
PAVING AT PLANT�NO. 1, JUB NU.
Amount of this Change Order (Add) (Deduet) E 25,662.11
In accordance with contract provisions, the following changes in the contract
and/or contract work are hereby authorized and as compensation therefor, the
following additions to or deductions from the contract price are hereby approved.
Job No. P1-31
Item 1 GAS FLOW METER INSTALLATION
The Contractor was directed to install a dry gas flow meter in the boiler
digester gas supply piping. The Districts purchased the flow meter under a
separate purchase order. The flow meter was a requirement of South Coast Air
Quality Management District and was not specified in the contract. This item was
negotiated with the Contractor pursuant to Section 10-6(b)(2)A of the General
Provisions. (Reference: FCO 131)
ADDED COST THIS CHANGE ORDER ITEM: S 1,198.70
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Jab No. P1-20
Item 1 LANDING PAD ADDITION FOR CATWALK TO EXISTING HEADWORKS
The Contractor was directed to install a concrete landing pad at the connection
of the splitter box catwalk and the roof of the existing headworks. As stated
on the contract plans, the catwalk dimensions conflicted with the elevation of
the existing headworks roof. The addition of a concrete landing pad at the
existing headworks roof was the most cost effective solution to the conflict.
This item was negotiated with the Contractor pursuant to Section 10-6(b)(2)A of
the General Provisions. (Reference: FCO 166)
ADDED COST THIS CHANGE ORDER ITEM: 8 477.86
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"G-1" AGENDA ITEM #9(f) - ALL DISTRICTS "G-1"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 2 of 5
P. 0. BOX 8127 - 10844 ELLIS AVENUE
`./ FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Twenty-Two (22)
CONTRACTOR: Kiewit Pacific Co. DATE October
JOB: HEADWORKS NO. 2 AT PLANT N0. 1 JOB N0. P1-20• AND DEMOLITION OF DIGESTERS
• R EN B ING N U , N N AND
VN AlPLN N
Job No. P1-20
Item 2 DRAIN LINE ADDITION AT SUNFLOWER PUMP STATION
The Contractor was directed to install a new drain line in the Sunflower Pump
Station trench. This item involves the coring of two concrete walls and the
installation of piping and supports. The new line was needed to drain the trench
of future periodic wash down water and was not provided for in the contract.
This item was negotiated with the Contractor pursuant to Section 10-6(b)(2)A of
the General Provisions. (Reference: FCO 133)
ADDED COST THIS CHANGE ORDER ITEM: $ 1,956.29
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 3 CHLORINE SOLUTION PIPING REVISION AT SPLITTER BOX
The Contractor was directed to reroute three chlorine solution lines at the
splatter box parapet wall. These lines were installed per the contract drawings
and were found to conflict with the installation of a stop plate at the southeast
orner of the splitter box roof elevation. The 6-inch diameter piping was
rerouted outside the parapet wall in the area of conflict and involved the
assembly of scaffolding concrete core drilling, new piping and supports. This
item was negotiated with the Contractor pursuant to Section 10-6(b)(2)A of the
General Provisions. (Reference: FCO 167, PCH 100)
ADDED COST THIS CHANGE ORDER ITEM: $ 7,726.32
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 4 ACCESS LADDER ADDITION TO BELT CONVEYOR CATWALK
The Contractor was directed to furnish and install a new aluminum ladder to
access the belt conveyor catwalk near the Barscreen Building. The
contract-specified stairway conflicted with electrical conduit and the roll-up
door at the south side of the Barscreen Building. This item was negotiated with
the Contractor pursuant to Section 10-6(b)(2)A of the General Provisions.
(Reference: PCH 99 and FCO 178)
ADDED COST THIS CHANGE ORDER ITEM: $ 2,670.61
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"G-2" AGENDA ITEM #9(f) - ALL DISTRICTS "G-2"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 3 of 5
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708 �d
CHANGE ORDER
C. 0. NO. Twent -Two (22)
CONTRACTOR: Kiewit Pacific Co. DATE October
JOB: HEADWORKS NO. 2 AT PLANT N0. 1 JOB N0. P1-20• AND DEMOLITION OF DIGESTERS
NOS. AND E L NT OF BOILER; PIPING CLEAN UTS• AND UKAUINU AND
PAVING AT PLANT NO. 1, JOB NU. P -31
Jab No. P1-20
Item 5 STILE-TYPE STAIRWAY MODIFICATION
The Contractor was directed to modify the stile-type stairway in Tunnel No. 1.
The stile-type stairway was fabricated per the contract drawings to be 48 inches
wide but conflicted with the clear tunnel opening between the vertical pipe
supports which are 36 inches wide. The contract-specified stile-type stairway
was modified to allow for installation in the as-built tunnel width condition.
This item was negotiated with the Contractor pursuant to Section 10-6(b)(2)A of
the General Provisions. (Reference: FCO 177)
ADDED COST THIS CHANGE ORDER ITEM: $ 689.47
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 6 TRENCH COVER MODIFICATION
The Contractor was directed to modify a stainless steel cover at the piping
trench between the Sunflower Pump Station and Tunnel No. 1. The intent of the
contract drawings was to have all the piping trench covers designed for vehicle
crossing (H-20 loading). At an intersection in piping trench one of the covers
needed additional reinforcing to maintain the designed H-20 loading. As shown on
the contract drawings, the referenced cover was not designed for vehicle
crossing. This item was negotiated with the Contractor pursuant to Section
10-6(b)(2)A of the General Provisions. (Reference: FCO 150)
ADDED COST THIS CHANGE ORDER ITEM: $ 474.02
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 7 COVER PLATE ADDITION AT SUNFLOWER PUMP STATION
The Contractor was directed to furnish and install a a fiberglass cover over an
opening in the discharge channel of the Sunflower Pump Station. The cover was
required to maintain odor control in the area and was not shown on the contract
drawings. This item was negotiated with the Contractor pursuant to Section
10-6(b)(2)A of the General Provisions. (Reference: FCO 169)
ADDED COST THIS CHANGE ORDER ITEM: $ 3,519.29
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"G-3" AGENDA ITEM #9(f) - ALL DISTRICTS "G-3"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 4 of 5
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Twenty-Two (22)
CONTRACTOR: Kiewit Pacific Co. DATE October 11, 1989
JOB: HEADWORKS NO. 2 AT PLANT N0. 1, JOB NO. P1-20; AND DEMOLITION OF DIGESTERS
S. AN LAC N F E N UTS; AND G ING AND
AVN Al PLANT NU. L, dUtSN . Fi-di No. P1-20
Item 8 ADDED GRATING AT FOUL AIR AREA
The Contractor was directed to furnish and install fiberglass grating and
aluminum kick plates to several locations within the foul air area. For safety
reasons the opening around the control panel piping protruding through the
grating needed to be blocked off. The contract drawings did not shown these
areas to receive grating or kick plates. This item was negotiated with the
Contractor pursuant to Section 10-6(b)(2)A of the General Provisions.
(Reference: FCO 153)
ADDED COST THIS CHANGE ORDER ITEM: $ 5,949.55
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 9 CHLORINE GAS LEAK DETECTOR MODIFICATIONS
The Contractor was directed to add a second vertical member and two knee braces
to each of the four chlorine gas leak detector supports mounted outside the
Chlorine Building Area. Exterior housings were provided by the Districts under a
separate purchase order to weather-proof the sensitive detector units as the
contract-specified units were not rated for outdoor installations. The
additional housings increased the total weight of the units causing the need for
support modification. This item was negotiated with the Contractor pursuant to
Section 10-6(b)(2)A of the General Provisions. (Reference: FCO 182)
ADDED COST THIS CHANGE ORDER ITEM: $ 1,000.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
TOTAL COST THIS CHANGE ORDER: $ 25,662.11
TOTAL TIME EXTENSION THIS CHANGE ORDER: 0 Calendar Days
The additional work contained within this Change Order can be performed
incidental to the prime work and within the time allotted for the original
Contract and any extension to the Contract Time made by this and all previously
issued Change Orders. It is therefore mutually agreed that no time is required
for this Change Order, and no direct or indirect, incidental or consequential
costs, expenses, losses or damages have been or will be incurred by Contractor.
"G-4" AGENDA ITEM #9(f) - ALL DISTRICTS "G-4"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 5 of 5
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Twent -Two 1121
CONTRACTOR: Kiewit Pacific Co. DATE October
JOB: HEADWORKS NO. 2 AT PLANT N0. 1 J08 N0. P1-20• AND DEMOLITION OF DIGESTERS
N
N .
SUMMARY OF CONTRACT TIME
Original Contract Date October 21, 1987
Original Contract Time 920 Calendar Days
Original Completion Date April 27, 1990
Time Extension this C.O. 0 Calendar Days
Total Time Extension 63 Calendar Days
Revised Contract Time 983 Calendar Days
Revised Completion Date June 29, 1990
Time Subject to Liquidated Damages Not Applicable
Actual Final Completion Date Not Applicable
Original Contract Price $ 31 458 000.00
Prev. Auth. Changes $- 1' 6�02
This Change (Add) Wedwsti) $�662-T1-
Amended Contract Price $ 3347, 50.1
Board Authorization Date: October 11, 1989
COUNTY SANITATION DISTRICTS OF
ORANGE COUNTY, CALIFORNIA
RECOMMENDED BY:
KIEWIT PACIFIC CO. P2S-8y
Construction manager Uate
ACCEPTED BY: APPROVED BY:
j �
Contractor )[late rector of Engineering Date
"G-5" AGENDA ITEM #9(f) - ALL DISTRICTS "G-5"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 1 of 5
P. 0. BOX 8127 - 10844 ELLIS AVENUE
�./ FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Nineteen (19)
CONTRACTOR: Advanco Constructors, Division of DATE October 11, 1989
Zurn Constructors, Inc.
JOB: COVERS FOR PRIMARY BASINS AT PLANT NO. 1, JOB N0. P1-25; FOUL AIR SCRUBBER
SYSTEM AT PLANT NO. JOB N0. P - , COV S FOR PRIMARY BASINS Al PLANT
N0. 2 JOB .NO. P2-32• FOUL AIR SCRUBBER SYSTEMS AT PLANT NO. 2, JOB NO.
- 3• ANO IMPR EATS 0 GR T FACILIT "B", BILLINGS TUNffEL AND
IBUTI N S RUCTURE 'A", dud NO.
Amount of this Change Order (Add) (Deduct) $ 58,245.54
In accordance with contract provisions, the following changes in the contract
and/or contract work are hereby authorized and as compensation therefor, the
following additions to or deductions from the contract price are hereby approved.
Job No. P2-33
Item 1 ELECTRICAL MODIFICATIONS AT RECTANGULAR CLARIFIERS
The location and routing of existing conduit, wiring and electrical equipment at
existing rectangular Clarifiers "A", "B" and "C" was not addressed in the plans
for the installation of the new flat covers. Existing power, control and
lighting conduits attached to the walkway surface were in direct conflict with
the location of the new flat covers at each of the three basins. Locations of
existing light standards and push button stations were also in conflict with the
new covers. This change order item provides for the removal of the major
portion of existing walkway mounted conduit and its replacement with new
materials at locations where it did not conflict with the new covers. This item
also provides for the relocation of existing light standards and push button
stations to locations that did not present a conflict with new covers. Work was
accomplished by Contractor's force account pursuant to Section 10-6(b)(2)B of
the General Provisions. (Reference: FCO 057)
ADDED COST THIS CHANGE ORDER ITEM: $ 6,860.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 2 RELOCATION OF LIGHT STANDARDS AT PRIMARY CLARIFIERS "D", "E", "F" and
„G„
Existing light standards at each of the subject clarifier walkways were not
shown on the contract drawings and did conflict with the installation of new
structural framing for the new domes. This change order item provides for the
relocation of the light standards at each of the four basins from the typical
walkway location to the area of the scum boxes. Work was accomplished by
Contractor's force account pursuant to Section 10-6(b)(2)B of the General
Provisions. (Reference: FCO 054)
ADDED COST THIS CHANGE ORDER ITEM: $ 4,609.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"H-1" AGENDA ITEM #9(9) - ALL DISTRICTS "H-1"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 2 of 5
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Nineteen (19)
CONTRACTOR: Advanco Constructors Division of DATEOctober
urn onstrut ors, nc.
JOB: COVERS FOR PRIMARY BASINS AT PLANT N0-Coll JOB NO. P1-25; FOUL AIR SCRUBBER
SYSTEMPLANT N BN ; V R M YBA N
B N - RUBE SYSTEMS AT PLANT NO. 2, JOB N .
AND IMPROVEMEN S TO GRIT FACILITY "B" BILLINGS TUNNEL AND
N 5TRUCTURL "A B NU.
Item 3 MODIFICATION TO GROUND CABLE INSTALLATION AT CIRCULAR CLARIFIERS
According to the plans each of the dome structures were to be grounded at two
locations using ground rods and bare 4/0 copper cable. Details for the
installation of the bare copper cable placed portions of it in the primary
effluent liquid and in the corrosive atmosphere of the effluent launder
enclosures. This change order item provides for the use of insulated copper
cable in lieu of the bare copper cable originally specified. Insulated cable
will not deteriorate in the atmosphere of the effluent launder enclosures. Work
was accomplished by Contractor's force account pursuant to Section 10-6(b)(2)B
of the General Provisions. (Reference: FCO 060)
ADDED COST THIS CHANGE ORDER ITEM: $ 2,215.33
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 4 PROVISION OF ORITEX WEAR SURFACE ON OVERHEAD FRP DUCTWORK AT SUPPORTS
There are 84 saddle-type structural aluminum supports for the various overhead
FRP foul air duct systems. The overhead circular foul air duct systems are
exposed to temperature variations created by the sun and seasonal changes and
are exposed to the effects of wind conditions. The exposure to the elements
-uses the FRP ductwork to move within the saddles of their structural aluminum
supports. This movement between the ductwork and support, if not addressed,
would cause the load-bearing surface of the FRP ductwork to wear and reduce its
wall thickness and its resistence to the elements. To allow the ductwork to
move in the supports without wear or binding, this change order item provides
for the bonding of Oritex sheet to the full circumference of the foul air duct
at each support location. Based on actual installation conditions the 3/16-inch
thick Oritex sheet will provide a load-bearing surface that will not wear
significantly due to anticipated movement between the duct system components.
Work was accomplished by Contractor's force account pursuant to Section
10-6(b)(2)8 of the General Provisions. (Reference: PCH 099)
ADDED COST THIS CHANGE ORDER ITEM: $ 21,899.41
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"H-2" AGENDA ITEM #9(g) - ALL DISTRICTS "H-2"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 3 of 5
P. 0. BOX 8127 - 10844 ELLIS AVENUE
`./ FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Nineteen (19)
CONTRACTOR: Advanco Constructors Division of DATE October
urn ons ruc ors, nc.
JOB: COVERS FOR PRIMARY BASINS AT PLANT NO. 1, JOB NO. P1-25; FOUL AIR SCRUBBER
SYSTEM T N N B N . P - • C B N ANT
No. JOB . P2-32; FOUL A R SCRUBBER SYSTEMS AT PLANT No. 2 JOB N0.
BILLINGSNN
DISTRIBUTION STRUCTURE "A", JOB NO. P2-34.
Job No. P2-34
Item 5 FOUL AIR CONNECTION AND PRIMARY EFFLUENT SAMPLE LINE AT JUNCTION BOX "A"
Prior to the completion of the new underground primary effluent system at Plant
No. 2 the major portion of the malodorous gases collected in the old system at
Junction Box "A" located ,just north of Primary Clarifier "K". The gases were
vented from the ,junction box into the launder channel of Clarifier "K" through
the use of a 12-inch PVC pipeline. During the construction of the new primary
effluent system, provided by Change Order No. 2, staff recommended that the new
effluent system be vented into the new overhead foul air duct system to prevent
the malodorous gases from being carried out to and emitted from Junction Box "1"
adjacent to the Santa Ana River levee road. This change order item provides for
the installation of a 24-inch vent and control valve installed between the
underground primary effluent system and the 54-inch FRP .overhead foul air duct
at a location ,just north of Primary Clarifier "K". This change order item also
provides for the installation of a 1-inch PVC primary effluent sample line
between Junction Box "A" and a location selected for the future construction of
a new sampler facility in the north west quadrant of Primary Clarifier "K".
Work was accomplished by Contractor's force account pursuant to Section
10-6(b)(2)B of the General Provisions. (Reference: FCO 027)
ADDED COST THIS CHANGE ORDER ITEM: $ 14,722.44
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 6 REPAIR 42-INCH RCP INFLUENT LINE TO PRIMARY CLARIFIER "I"
In preparation for the driving of shoring piles for work to be performed under
Change Order No. 2, the Contractor and the Districts reviewed the "As-Built"
drawings for underground piping and utilities in the area north of Primary
Clarifier "I". Drawings indicated that the locations selected by the Contractor
for the placement of sharing piles were unobstructed by the existing underground
utilities or piping. White driving one of the first shoring piles the
Contractor damaged the top of the 42-inch RCP influent line to Primary Clarifier
"I" as it was not where it was shown to exist on the "As-Built" drawings. This
change order item reimburses the Contractor for the cost to repair the damaged
�.✓ line with cost being calculated by Contractor's force account pursuant to
Section 10-6(b)(2)B of the General Provisions. (Reference: CL-P234-001)
ADDED COST THIS CHANGE ORDER ITEM: $ 1,500.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"H-3" AGENDA ITEM #9(g) - ALL DISTRICTS "H-3"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 4 of 5
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Nineteen (19)
CONTRACTOR: Advanco Constructors, Division of DATE October
urn onstructors nc.
JOB: COVERS FOR PRIMARY BASINS AT PLANT N0. 1 JOB NO. P1-25; FOUL AIR SCRUBBER
SYSTEM T PL N OB N COV MARY BASINS AT PL NT
OB NO. - 2; FOUL AIR SCRUBBER SYSTEMSPLANT N NO.
N ROVEM N RIT B" LLINW) 1UNNtL ANU
TIN STRUCTUREBNO. P -
Item 7 CHANGE TREAD PLATE HOLD-DOWN ANCHORS - HEADWORKS "C"
New tread plates that were to be installed over existing floor openings in the
bar screen area and the upper grit chamber area at Headworks "C" were to be held
in place by stainless steel stud bolts that would have projected approximately
1-1/2-inch above area walkways. To eliminate the tripping hazard that would
have resulted from the use of stud bolts as hold-down devices, the Contractor
was instructed to furnish and install flat head anchor screws that would not
project above the top of the new tread plates. This change order item provides
for counter sinking all the new tread plates and changing the specified 316
stainless steel stud bolts to 316 stainless steel flush anchors and flat head
machine screws. Work was completed on a lump sum basis pursuant to Section
10-6(b)(2)A of the General Provisions. (Reference: FCO 063)
ADDED COST THIS CHANGE ORDER ITEM: $ 6,439.36
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
TOTAL ADDED COST THIS CHANGE ORDER: $ 58,245.54
TOTAL TIME EXTENSION THIS CHANGE ORDER: 0 Calendar Days
The additional work contained in this Change Order can be performed incidental
to the prime work and within the time allotted for the original Contract and any
revisions to the Contract Time made by this and all previously issued Change
Orders. It is therefore mutually agreed that no time is required for this
Change Order, and no direct or indirect, incidental or consequential costs,
expenses have been or will be incurred by the Contractor. .
"H-4" AGENDA ITEM #9(g) - ALL DISTRICTS "H-4"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 5 of 5
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Nineteen (19)
CONTRACTOR: Advanco Constructors, Division of DATE October 11, 1989
Zurn Constructors, Inc.
JOB: COVERS FOR PRIMARY BASINS AT PLANT N0. 1 JOB NO. P1-25; FOUL AIR SCRUBBER
SYSTEM N N B N ASIN L NT
0. 2, JOB N - ; FOUL AIR SCRUBRCRSYSTEMS T PLANT NO.--2—,7JUF—NO.
P - ; AND IMPKE)VEMENIN TO GRIT FACILITY "B" BILLINGS TUNNEL KND
DISTRIBUTION STRUCTURE ", JOB NO. -34.
SUMMARY OF CONTRACT TIME
Original Contract Date November 24, 1987
Original Contract Time 540 Calendar Days
Original Completion Date May 16, 1989
Time Extension This C.O. 0 Calendar Days
Total Time Extension 151 Calendar Days
Revised Contract Time 691 Calendar Days
Revised Completion Date October 14, 1989
Actual Final Completion Date Not Applicable
Time Subject to Liquidated Damages Not Applicable
Original Contract Price S 15 893 393.00
Prev. Auth. Changes
This Change (Add) (Deduct:) 834
Amended Contract Price $ 20839,E
Board Authorization Date: October 11, 1989
COUNTY SANITATION DISTRICTS OF
ORANGE COUNTY, CALIFORNIA
RECOMMENDED BY:
f7- /-LS-ay
struct on manager Date
ADVANCO CONSTRUCTORS, DIVISION OF
ZURN CONSTRUCTORS, INC.
ACCEPTED BY: APPR BY:
qn rac or t a e Director of Engineering Date
"H-5" AGENDA ITEM #9(9) - ALL DISTRICTS "H-5"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 1 of 3
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708 �..'
CHANGE ORDER
C. 0. NO. Five (5)
CONTRACTOR: Kiewit Pacific Co. DATE October 11, 1989
JOB: ENTRANCES, SITE SECURITY AND INTERIOR ROAD IMPROVEMENTS AT PLANT N0. 1
0.
Amount of this Change Order (Add) (Deduet:) 8 6,787.15
In accordance with contract provisions, the following changes in the contract
and/or contract work are hereby authorized and as compensation therefor, the
following additions to or deductions from the contract price are hereby approved.
Item 1 CARD READER MODIFICATIONS
The Contractor was directed to furnish and install transformers and additional
wiring at the two card readers which operate Entrance Gates Nos. 1 and 5. A
9-volt power source was required for proper card reader operation which had been
omitted from the contract drawings. This item was negotiated with the Contractor
pursuant to Section 10-6(b)(2)A of the General Provisions. (Reference: FCO 25)
ADDED COST THIS CHANGE ORDER ITEM: S 1,353.29
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 2 COMMUNICATION LINK BETWEEN CARD READERS AND SYSTEM CONTROLLER
The Contractor was directed to install a Districts-furnished multiplexer in the
Metering and Diversion Building (M & D Building). The multiplexer installation
was required to facilitate communications between the present card readers, future
card readers and the Cassi Rusco controller. The extra work involved with this
item was more cost effective than purchasing and installing additional conductors
between the M & D Building and the Administration Building. This item of work was
required to implement proper operation of the entrance gates and to provide
capacity for expansion of controls on the entire gate system. This item was
negotiated with the Contractor pursuant to Section 10-6(b)(2)A of the General
Provisions. (Reference: FCO 26)
ADDED COST THIS CHANGE ORDER ITEM: S 2,353.55
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"I-1" AGENDA ITEM #9(h) - ALL DISTRICTS "I-1"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 2 of 3
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Five (5)
CONTRACTOR: Kiewit Pacific Co. DATE Oc o er
JOB: ENTRANCES SITE SECURITY AND INTERIOR ROAD IMPROVEMENTS AT PLANT NO. 1
--Juls No.Item 3 LANDSCAPING REPAIRS
The Contractor was directed to regrade, prepare and seed an area in the middle of
the Wastehauler Building lawn area. During the installation of the
Districts-furnished palm trees in the referenced area, damage occurred to the
grass seedings and repairs were required. This item was negotiated with the
Contractor pursuant to Section 10-6(b)(2)A of the General Provisions.
(Reference: FCO 27)
ADDED COST THIS CHANGE ORDER ITEM: $ 1,552.93
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 4 GATE OPERATOR RELAY MODIFICATIONS
Due to excessive voltage drop during the gate motor start-up the Contractor was
directed to replace the contract-specified 120-volt relays with 24-volt relays.
The 24-volt relays are less sensitive to voltage drop. Modification to gate
control circuitry was required to accommodate the 24-volt relays. This item was
negotiated with the Contractor pursuant to Section 10-6(b)(2)A of the General
Provisions. (Reference: FCO 28)
ADDED COST THIS CHANGE ORDER ITEM: $ 772.40
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 5 STRIPING AND SIGN MODIFICATIONS
The Contractor was directed to modify the contract-installed CALTRANS signs within
the plant and re-stripe a left turn pocket on Ellis Avenue. The signs were
installed as per contract and needed to be lowered in height to conform with the
Districts' standard sign heights throughout the plant. The left turn pocket
striping on Ellis Avenue was modified to allow for a one-week delay in the closing
of the existing main gate. This item was negotiated with the Contractor pursuant
to Section 10-6(b)(2)A of the General Provisions. (Reference: FCO 29)
ADDED COST THIS CHANGE ORDER ITEM: $ 754.98
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
TOTAL ADDED COST THIS CHANGE ORDER ITEM: $ 6,787.15
TOTAL TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"I-2- AGENDA ITEM #9(h) - ALL DISTRICTS "I-2"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 3 of 3
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708 �.✓
CHANGE ORDER
C. 0. NO. Five (5)
CONTRACTOR: Kiewit Pacific Co. DATE October 11, 1989
JOB: ENTRANCES, SITE SECURITY AND INTERIOR ROAD IMPROVEMENTS AT PLANT NO. 1,
TO No. P -
The additional work contained within this Change Order can be performed
incidental to the prime work and within the time allotted for the original
Contract and any extensions to the Contract Time made by this and all previously
issued Change Orders. It is therefore mutually agreed that no time is required
for this Change order, and no direct or indirect, incidental or consequential
costs, expenses, losses or damages have been or will be incurred by Contractor.
SUMMARY OF CONTRACT TIME
Original Contract Date November 10, 1988
Original Contract Time 250 Calendar Days
Original Completion Date July 17, 1989
Time Extension this C.O. 0 Calendar Days
Total Time Extension 24 Calendar Days
Revised Contract Time 274 Calendar Days
Revised Final Completion Due Date August 10, 1989
Actual Final Completion Date Not Applicable
Time Subject to Liquidated Damages Not Applicable
Original Contract Price $ 1,590,000.00
Prev. Auth. Changes $ 80 3 8
This Change (Add) (Deduet) 1% b'/d7T5
Amended Contract Price $ 1,677,521.73
Board Authorization Date: October 11, 1989
COUNTY SANITATION DISTRICTS OF
ORANGE COUNTY, CALIFORNIA
RECO FENDED BY:
A9. 4=9 f-zs- d
Co struction Manager Date
KIEWIT PACIFIC CO.
ACCEPTED BY/: Zec
BY:
Contractor a e 4 ngineering Date
"I-3" AGENDA ITEM #9(h) - ALL DISTRICTS "I-3"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 1 of 3
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Five (5)
CONTRACTOR: ZIEBARTH AND ALPER DATE October 11, 1989
JOB: MISCELLANEOUS MODIFICATIONS AND IMPROVEMENTS TO FACILITIES AT TREATMENT
PLANTNO. 2, JOB-NO.- P2-37
Amount of this Change Order (Add) (Deduet) $ 77,047.00
In accordance with contract provisions, the following changes in the contract
and/or contract work are hereby authorized and as compensation therefor, the
following additions to or deductions from the contract price are hereby approved.
Item 1 PLACEMENT OF FILL CONCRETE IN DIGESTERS A AND B
The floors in Digesters A and B do not have cone shaped floors as do all other
digesters at Plant No. 2. The floors in Digesters A and B are flat and contain
many recirculation pipe supports along their interior perimeters. The flat floor
design with the multitude of vertical concrete pipe supports reduces the
efficiency of the sludge recirculation system and increases the amount of manpower
required to perform routine digester cleaning operations. The placement of the
sloped reinforced fill concrete along the perimeter of each of the two digesters
will enhance the flow characteristics of the sludge recirculation systems, reduce
digester cleaning costs, and shorten down time needed for cleaning operations.
The work is to be completed on a lump sum basis pursuant to Section 10-6(2)A of
the General Provisions. (Reference: PCH-P237-032)
ADDED COST THIS CHANGE ORDER ITEM: $55,047.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
Item 2 BONUS PAYMENT
The contract time for the P2-37 project is 425 calendar days. The time allotted
to complete the modifications to Digesters A and B, a milestone activity, is 300
calendar days. A bonus/penalty of $500.00 per day early/late completion is
included in the provisions set forth for the milestone activity. As a result of
inclement weather and unanticipated additional demolition at the site of the
digesters, the contractor was delayed and was granted a six-calendar day extension
of time on the digester milestone activity per Change Order 1, Item 11.
(Reference: Detailed Specification Sections 50-8 and 52-1700)
Milestone Milestone Actual
Completion Completion Milestone Bonus Bonus per Amount of
Date Date/COY1 Date Days Day Bonus
8/28/89 9/3/89 7/21/89 44 $500.00 $22,000.00
ADDED COST THIS CHANGE ORDER ITEM: $22,000.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
"J-1" AGENDA ITEM k90 ) - ALL DISTRICTS "J-1"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 2 of 3
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708 �.✓
CHANGE ORDER
C. 0. NO. Five (5)
CONTRACTOR: ZIEBARTH AND ALPER DATE Octo er 98
JOB: MISCELLANEOUS MODIFICATIONS AND IMPROVEMENTS TO FACILITIES AT TREATMENT
PLANT NO. 2, JOB NO.
TOTAL ADDED COST THIS CHANGE ORDER: $ 77,047.00
TOTAL TIME EXTENSION THIS CHANGE ORDER: 0 Calendar Days
The additional work contained within this Change Order can be performed incidental
to the prime work and within the time allotted for the original Contract and any
extensions to the Contract Time made by this and all previously issued Change
Orders. It is therefore mutually agreed that no time is required for this Change
Order, and no direct or indirect, incidental or consequential costs, expenses,
losses or damages have been or will be incurred by Contractor, except as expressly
granted and approved by this Change Order.
SUMMARY OF DIGESTER MILESTONE TIME
Original Activity Start Date November 2, 1988
Original Activity Duration Time 300 Calendar Days
Original Activity Completion Date August 28, 1989
Adjustment Milestone Time This Change Order 0 Calendar Days
Total Adjustment Milestone Time 6 Calendar Days
Revised Activity Duration 306 Calendar Days _
Revised Milestone Date September 3, 1989
SUMMARY OF CONTRACT TIME
Original Contract Date November 2, 1988
Original Contract Time 425 Calendar Days
Original Completion Date December 31, 1989
Time Extension this C.O. 0 Calendar Days
Total Contract Time Extension 0 Calendar Days
Revised Contract Time No Change
Revised Final Completion Due Date No Change
Actual Final Completion Date Not Applicable
Time Subject to Liquidated Damages Not Applicable
"J-2" AGENDA ITEM #9( i) - ALL DISTRICTS "J-2"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 3 of 3
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. Five (5)
CONTRACTOR: ZIEBARTH AND ALPER DATE October 11, 1989
JOB: MISCELLANEOUS MODIFICATIONS AND IMPROVEMENTS TO FACILITIES AT TREATMENT
PLANT NO. 2, JOB NO.
Original Contract Price $ 5 395 000.00
Prev. Auth. Changes
This Change (Add) (BeAue%) $�ti
Amended Contract Price9�d�
Board Authorization Date: October 11, 1989
COUNTY SANITATION DISTRICTS OF
ORANGE COUNTY, CALIFORNIA
RE PM NDED BY:
v 9- l�-2- By
Cdfistruction Manager Date
ACCEPTED BY: APPROVED BY:
ZIEBARTH AND ALPER G
Cont ctor Date erector oEngineering a e
�.J
"J-3" AGENDA ITEM #90 ) - ALL DISTRICTS "J-3"
RESOLUTION NO. 89-140
ACCEPTING JOB NO. P1-35-1-1 AS COMPLETE
A JOINT RESOLUTION OF THE BOARDS OF DIRECTORS OF `a✓
COUNTY SANITATION DISTRICTS NOS. 1, 2, 3, 5, 6, 7,
11, 13 AND 14 OF ORANGE COUNTY, CALIFORNIA,
ACCEPTING CLEANING OF DIGESTERS 7 AND 8 AT PLANT
NO. 1, JOB NO. P1-35-1-1, AS COMPLETE AND APPROVING
FINAL CLOSEOUT AGREEMENT
R t f f Y f f Y • f t 1 Y Y R Y
The Boards of Directors of County Sanitation Districts Nos. 1, 2, 3, 5, 6,
7, 11, 13 and 14 of Orange County, California,
DO HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That the contractor, Dorado Enterprises, Inc. , has completed
the project in accordance .with the terms of the contract for Cleaning of
Digesters 7 and 8 at Plant No. 1, Job No. P1-35-1-1, on September 1, 1989; and,
Section 2. That by letter the Districts' Director of Engineering has
recommended acceptance of said work as having been completed in accordance with
the terms of the contract, which said recommendation is hereby received and
ordered filed; and,
Section 3. That Cleaning of Digesters 7 and 8 at Plant No. 1, Job
No. P1-35-1-1, is hereby accepted as completed in accordance with the terms of
the contract therefor, dated August 1, 1989; and,
Section 4. That the Districts' Director of Engineering is hereby
authorized and directed to execute a Notice of Completion therefor; and,
Section 5. That the Final Closeout Agreement with Dorado Enterprises,
Inc. , setting forth the terms and conditions for acceptance of Cleaning of
Digesters 7 and 8 at Plant No. 1, Job No. P1-35-1-1, is hereby approved and
accepted in form approved by the General Counsel ; and,
Section 6. That the Chairman and Secretary of District No. 1, acting for
itself and on behalf of Districts Nos. 2, 3, 5, 6, 7, 11, 13 and 14, are hereby
authorized and directed to execute said agreement on behalf of the Districts.
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
"K" AGENDA ITEM #9(j ) - ALL DISTRICTS "K"
RESOLUTION NO. 89-141
APPROVING ADDENDUM NO. 1 TO PROFESSIONAL SERVICES
AGREEMENT WITH ARTHUR YOUNG 8 COMPANY FOR DATA
PROCESSING PROGRAM DESIGN
A JOINT RESOLUTION OF THE BOARDS OF DIRECTORS OF
COUNTY SANITATION DISTRICTS NOS. 1, 2, 3, 5, 6,
7, 11 AND 13 OF ORANGE COUNTY, CALIFORNIA,
APPROVING ADDENDUM NO. 1 TO AGREEMENT WITH ARTHUR
YOUNG 8 COMPANY FOR DATA PROCESSING PROGRAM DESIGN
TO ACCOMMODATE DISTRICTS' BILLING AND COLLECTION
OF SUPPLEMENTAL USER FEES ON THE ANNUAL PROPERTY
TAX BILL, PROVIDING FOR AN EXPANDED SCOPE OF WORK
TO INCLUDE PROGRAM MODIFICATIONS REQUESTED BY THE
COUNTY ASSESSOR TO FACILITATE DATA TRANSFERS TO
OTHER AGENCIES
WHEREAS, the Districts have heretofore entered into an agreement with
Arthur Young 8 Company for the functional design and redevelopment of the
Districts' supplemental user fee data processing programs to interface with the
County Assessor's and County Auditor's new data base management systems and for
the training and oversight necessary to implement the new programs for billing
and collecting the Districts' supplemental user fees on the annual property tax
bill to replace the services previously provided by the County Assessor; and,
WHEREAS, it is now deemed appropriate to amend said agreement with Arthur
Young 8 Company to provide for an expanded scope of work to include additional
program modifications requested by the County Assessor to facilitate data
transfers to other agencies.
NOW, THEREFORE, the Boards of Directors of County Sanitation Districts
Nos. 1, 2, 3, 5, 6, 7, 11, 13 and 14 of Orange County, California,
DO HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That Addendum No. 1 dated October 11, 1989, to that certain
Professional Services Agreement dated January 11, 1989, by and between County
Sanitation Districts Nos. 1, 2, 3, 5, 6, 7, 11, 13 and 14 of Orange County and
"L-1" AGENDA ITEM k9(n) - ALL DISTRICTS "L-1"
Arthur Young 8 Company, for the functional design and redevelopment of the
Districts' supplemental user fee data processing programs to interface with the
County Assessor's and County Auditor's new data base management systems and for
the training and oversight necessary to implement the new programs for billing
and collecting the Districts' supplemental user fees on the annual property tax
bill to replace the services previously provided by the County Assessor,
providing for an expanded scope of work to include additional program
modifications requested by the County Assessor to facilitate data transfers to
other agencies, is hereby approved and accepted; and,
Section 2. That the payment provision of said agreement be amended,
providing for payment in an amount not to exceed $37,180.00 for said additional
services, the cost of which shall be shared by each District, and increasing the
total authorized compensation from $161,882.00 to an amount not to exceed
$199,062.00. Said increase shall be deducted from the County Assessor's charges
to the Districts for data base information and processing; and,
Section 3. That the General Manager is hereby authorized and directed to
execute said Addendum No. 1 in form approved by the General Counsel.
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
"L-2" AGENDA ITEM p9(n) - ALL DISTRICTS "L-2"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 1 of 2
P. 0. BOX 8127 - 10844 ELLIS AVENUE
�./ FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. One (1)
CONTRACTOR: W. H. Ebert Corp. DATE OctoberTr,-7989
JOB: Portion of Euclid Interce for Sewer between Ed in er Avenue and Lam son
Avenue Contract No. - and Sou
na eim Re ie Sewer on a Roa
between Euclid Street and Wa nut Street, ontract No. 2-21
Amount of this Change Order (Add) (Deduet) $ 98,532.00
In accordance with contract provisions, the following changes in the contract
and/or contract work are hereby authorized and as compensation therefor, the
following additions to or deductions from the contract price are hereby approved.
Item 1
The Contractor was directed to furnish and place 1,610 tons of additional asphalt
paving on Ball Road between Euclid Street and Walnut Street. The contract
documents indicated a total of 800 tons of asphalt would be required for paving
replacement in conjunction with the construction of the VCP sewer line in Ball
Road. The actual quantity of asphalt required to complete the paving was 2,410
tons. This added work was negotiated with the Contractor pursuant to Section
10-6(b) (2)A of the General Provisions.
ADDED COST THIS CHANGE ORDER ITEM: $ 98,532.00
TIME EXTENSION THIS CHANGE ORDER ITEM: 0 Calendar Days
TOTAL ADDED COST THIS CHANGE ORDER: $ 98,532.00
TOTAL EXTENSION THIS CHANGE ORDER: 0 Calendar Days
The additional work contained within this Change Order can be performed
incidental to the prime work and within the time allotted for the original
Contract and any extensions to the Contract Time made by this and all previously
issued Change Orders. It is therefore mutually agreed that no time is required
for this Change order, and no direct or indirect, incidental or consequential
costs, expenses, losses or damages have been or will be incurred by Contractor,
except as expressly granted and approved by this Change Order.
"M-1" AGENDA ITEM #9(p) - DISTRICT 2 "M-1"
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY Page 2 of 2
P. 0. BOX 8127 - 10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA 92708
CHANGE ORDER
C. 0. NO. One (1)
CONTRACTOR: W. H. Ebert Corp. DATE October 11, 1989
JOB: Portion of Euclid Interce for Sewer, between Edi per Avenue and Lam son
Avenue, Contract No. - an South Ana N Reef Sewer, on Ba Roa
between Euc i treet anJ Wa nut Street, ontract No. 2-27
SUMMARY OF CONTRACT TIME
Original Contract Date March 22, 1989
Original Contract Time 365 Calendar Days
Original Completion Date March 22, 1990
Time Extension this C.O. 0 Calendar Days
Total Contract Time Extension 0 Calendar Days
Revised Contract Time 365 Calendar Days
Revised Final Completion Due Date March 22, 1990
Actual Final Completion Date Not applicable
Time Subject to Liquidated Damages Not applicable
Original Contract Price $ 9 242 538.00
Prev. Auth. Changes $ 0
This Change (Add) (Pedust) 8�5,-532�6b-
Amended Contract Price $ 9,34
Board Authorization Date: October 11, 1989
COUNTY SANITATION DISTRICTS OF
ORANGE COUNTY, CALIFORNIA
RECDED BY:
sz-89
Construction Manager Date
W. H. EBERT CORP.
ACCEPTED BY: APP OV D BY:
9ma , *", l/ u, = z,-e)
(��arntractbt Date erector of Engineering Date
"M-2" AGENDA ITEM #9(p) - DISTRICT 2 "M-2"
PETITION FOR ANNE7ATION
Date:
TO: Board of Directors
County Sanitation District No. 2
P. O. Box 8127
�✓ Fountain Valley, CA 92728-8127
I (lee), the undersigned lacdamer(s), do heraby request that proceedings be
taken to annex 1 .8 acres (Gross - to nearest hundredth) of territory to
the District located in the vicinity of Vista Del Sol & Country Hill Road
(Indicate adjacent street intersection or area description)
in the city of Anaheim , more particularly
(Indicate city or unincorporated territory)
described and shown on the LEGAL DESCRIPTION and IAP enclosed herewith which
has been prepared in accordance with the District's arms tion procedures. The
street address of the property is: 7521 , 7515, 7511 Vista Del Sol
The reason for the proposed annexation is: Building of Private Residence
Said property is _Inhabited / X Uninhabited. Number of registered voters,
if any: 2 . The assessed value of the property is: $ 7521 S162.000
f.
7515 0 /9�,®o - , 75ii W ie�7sob.
Also enclosed are the •JUSTIFICATION OF PROPOSAL QUESTIONNAIRE required by the
Local Agancy Formation Canniasion (and an Environmental Impact Report, if
approoriate) and a check in the amount of $500.00 representing Payment of the
DISTRICT PROCESSIM FEE.
Notices and communications relative- to this proposal for annexation should be
sent to the following.
V. A. Bauerlein 6ewve G.Wiase-/
632 Nenno Ave izTsi o�roorr
Placentia. CA 92670 .014 0 +vGeo
�- vc.� 9za or
Tele: 714/5 Tale: dig) b98-9r�8
Sa5-45 3 b
SIGNATURE OF LANDOMM �DATE SIGND ADDRESS OF LaMOWNER
7521 x 1T, nae�q_ 632 UeKan AUt
Y.A3aDe�leT� �l�eew�I� Cn-1 4z67Q
Na[7: (Tubed oror�prrntadl
761-5 x (7 /7w 1 -�E.e"w,a
Name It FYP9`1or prn )
�.s 6eNeG.e>,li�l �ce^(�Foyc,us.4Zoas
Naha
"N" AGENDA ITEM #9(r) - DISTRICT 2 "N"
RESOLUTION NO. 89-144-2
AUTHORIZING INITIATION OF PROCEEDINGS AND
FILING F APPLICATION TO LAFCO RE ANNEXATION
F TERRITORY TO DISTRICTANNEXATION
NO. 77- WfC�ON A Nf7 Ear N
A RESOLUTION OF THE BOARD OF DIRECTORS OF COUNTY
SANITATION DISTRICT NO. 2 OF ORANGE COUNTY, CALIFORNIA,
AUTHORIZING INITIATION OF PROCEEDINGS AND REQUESTING
THE LOCAL AGENCY FORMATION COMMISSION TO TAKE PROCEEDINGS
FOR ANNEXATION TO THE DISTRICT OF TERRITORY KNOWN AS
ANNEXATION NO. 70 - WILSON ANNEXATION TO COUNTY SANITATION
DISTRICT NO. 2
f f f f f f f f f f f f f f f f
The Board of Directors of County Sanitation District No. 2 of Orange
County, California,
DOES HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That proceedings are hereby authorized to be initiated by
District No. 2, and the Local Agency Formation Commission of Orange County is
hereby requested to take proceedings for the annexation of territory designated
as "Annexation No. 70 - Wilson Annexation to County Sanitation District No. 211,
the boundaries of which are more particularly described and delineated on
Exhibits "A" and "B" attached hereto and by reference made a part of this
resolution, according to the terms and conditions hereinafter set forth in this
resolution in the manner provided by the Cortese-Knox Local Government
Reorganization Act of 1985; and,
Section 2. That this proposal is made pursuant to the Cortese-Knox Local
Government Reorganization Act of 1985, Division 3, commencing with Section 56000
of the California Government Code; and,
Section 3. That this application is for the purpose of annexing
approximately 2.102 acres of territory to District No. 2 in the vicinity of
Country Hill Road and Vista Del Sol in the City of Anaheim, to provide sanitary
sewer service to said territory, which said service is not now provided by any
"0-1" AGENDA ITEM #9(r) - DISTRICT 2 "0-1"
public agency, as requested by Gene C. Wilson, Walter D. Posey and
�..✓ V. A. Bauerlein, owners of said property; and,
Section 4. That the territory to be annexed is uninhabited; and,
Section 5. That this proposal is consistent with the adopted sphere of
influence of the affected District; and,
Section S. That proposed Annexation No. 70 - Wilson Annexation to County
Sanitation District No. 2 shall be subject to the condition that all fees
required to be paid to the District must be satisfied prior to completion of the
annexation proceedings; and,
Section 7. That the District hereby agrees, pursuant to Section 99.1 of
the Revenue and Taxation Code, to waive its ad valorem property tax allocation
exchange with other affected taxing agencies.
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
"0-2" AGENDA ITEM #9(r) - DISTRICT 2 "0-2"
RESOLUTION NO. 89-145-3
ACCEPTING CONTRACT NO. 3-34R AS COMPLETE
A RESOLUTION OF THE BOARD OF DIRECTORS OF COUNTY
SANITATION DISTRICT NO. 3 OF ORANGE COUNTY,
CALIFORNIA, ACCEPTING MANHOLE ADJUSTMENTS AND
STREET REPAIRS ON KNOTT INTERCEPTOR SEWER, CONTRACT _
NO. 3-34R, AS COMPLETE AND APPROVING FINAL CLOSEOUT
AGREEMENT
The Board of Directors of County Sanitation District No. 3 of Orange
County, California,
DOES HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That the contractor, Mladen Buntich Construction Co. , has
completed the construction in accordance with the terms of the contract for
Manhole Adjustments and Street Repairs on Knott Interceptor Sewer, Contract
No. 3-34R, on August 5, 1989; and,
Section 2. That by letter the Districts' Director of Engineering has
recommended acceptance of said work as having been completed in accordance with
the terms of the contract, which said recommendation is hereby received and
ordered filed; and,
Section 3. That Manhole Adjustments and Street Repairs on Knott
Interceptor Sewer, Contract No. 3-34R, is hereby accepted as completed in
accordance with the terms of the contract therefor, dated November 9, 1988;
and,
Section 4. That the Districts' Director of Engineering is hereby
authorized and directed to execute a Notice of Completion therefor; and,
Section 5. That the Final Closeout Agreement with Mladen Buntich
Construction Co. setting forth the terms and conditions for acceptance of
Manhole Adjustments and Street Repairs on Knott Interceptor Sewer, Contract
No. 3-34R, is hereby approved and accepted in farm approved by the General
�.d
11P-1" AGENDA ITEM #9(t) - DISTRICT 3 "P-1"
Counsel ; and,
�..✓ Section 6. That the Chairman and Secretary of District No. 3 are hereby
authorized and directed to execute said agreement on behalf of the District.
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
"P-2" AGENDA ITEM #9(t) - DISTRICT 3 "P-2"
RESOLUTION NO. 89-146
AWARDING CONTRACT NOS. 5-27-1 AND 5-37-2
A RESOLUTION OF THE BOARDS OF DIRECTORS OF COUNTY
SANITATION DISTRICTS NOS. 5 AND 6 OF ORANGE COUNTY,
CALIFORNIA, AWARDING CONTRACT FOR BALBOA TRUNK
SEWER, BETWEEN 32ND STREET AND CORONADO STREET,
CONTRACT NO. 5-27-1, AND INVESTIGATION OF PACIFIC
COAST HIGHWAY GRAVITY SEWER, CONTRACT NO. 5-37-2
The Boards of Directors of County Sanitation Districts Nos. 5 and 6 of
Orange County California,
DO HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That the proposed construction contract is for two projects
which are portions of the previously-approved Master Plan Report for District
No. 5 and the Southern Half of District No. 6. The projects are to be
constructed as per the Master Plan approval . In accordance with the California
Environmental Quality Act of 1970, as amended, and Section 15090 of the
Districts' Guidelines, a Final Environmental Impact Report covering these
projects was approved by the Districts' Boards of Directors on June 13, 1984;
and,
Section 2. That the written recommendation this day submitted to the
Boards of Directors by the Districts' Director of Engineering that award of
contract be made to National Plant Services, Inc. for Balboa Trunk Sewer,
Between 32nd Street and Coronado Street, Contract No. 5-27-1, and Investigation
of Pacific Coast Highway Gravity Sewer, Contract No. 5-37-2, and bid tabulation
and proposal submitted for said work are hereby received and ordered filed;
and,
Section 3. That the contract for Balboa Trunk Sewer, Between 32nd Street
and Coronado Street, Contract No. 5-27-1, and Investigation of Pacific Coast
"a-1" AGENDA ITEM #9(v) - DISTRICTS 5 & 6 "0-1"
Highway Gravity Sewer, Contract No. 5-37-2, be awarded to National Plant
�../ Services, Inc. in the total amount of $108,321.40, in accordance with the terns
of their bid and the prices contained therein, as follows:
Contract No. 5-27-1 (DISTRICT 5 ONLY) $ 30,800.00
Contract No. 5-37-2 (DISTRICTS 5 8 6) 77,521.40
$108,321.40
Section 4. That the Chairman and Secretary of District No. 5, acting for
itself and as agent for District No. 6, are hereby authorized and directed to
enter into and sign a contract with said contractor for said work, pursuant to
the specifications and contract documents therefor, in form approved by the
General Counsel ; and,
Section 5. That all other bids for said work are hereby rejected.
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
"�-2" AGENDA ITEM #9(v) - DISTRICTS 5 & 6 "0-2"
COUNTY SANITATION DISTRICTS
N ORANGE COUNTY. CAUFORNIA
September 19, 1989
11:00 a.m. t°B0 vo.8ox e�z0.812`"
7
NO ADDENDA zounraN VA"Y.MWOm Azrze.eT
B I D T A B U L A T I O N
H E E T
Contracts Nos. 5-27-1 and 5-37-2
PROJECT TITLE Rehabilitation of Balboa Trunk Sewer between 32nd Street and
Coronado Street, Contract No. 5- 7-1, and Investigation of Pacific Coast Highway
ravity Sewer, ontract No. - 7-2
PROJECT DESCRIPTION Seal pipe joints: videotape pipe and perform manhole
survey to determine condition of pipel ne.
BUDGET (5-27-1) $50,000
ENGINEER'S ESTIMATE $ 130,000.00 AMOUNT (5-37-2) Not Budgeted
CONTRACTOR TOTAL=BID
==.==__
Cont. 5-27-1: $ 30,800.00
1. National Plant Services, Inc. Cont. 5-37-2: 77,521.40
Long Beach, CA Total : 1
Only one bid was received, with a price lower than the estimate. This
contractor has successfully performed similar work for the District.
I have reviewed the proposal submitted for the above project and find that it is
a responsible bid. I, therefore, recommend award to National Plant Services,
Inc. in the bid amount of $108,321.40. _
i
`Tfiomas M. Dawes
Director of Engineering
"G-3" AGENDA ITEM #9(v) - DISTRICTS 5 & 6 "0-3"
RESOLUTION NO. 89-147-7
APPROVING PLANS AND SPECIFICATIONS
R CONTRACT NOS. 7-11-1 AND - 1-
A RESOLUTION OF THE BOARD OF DIRECTORS OF COUNTY
SANITATION DISTRICT NO. 7 OF ORANGE COUNTY,
CALIFORNIA, APPROVING PLANS AND SPECIFICATIONS
FOR ABANDONMENT OF LANE ROAD PUMP STATION, CONTRACT
NO. 7-11-1, AND ABANDONMENT OF CASTLEROCK AND DOW
AVENUE PUMP STATIONS AND MODIFICATIONS TO MACARTHUR
PUMP STATION, CONTRACT NO. 7-11-3
WHEREAS, Boyle Engineering Corporation, District's engineers, have
completed preparation of the plans and specifications for Abandonment of Lane
Road Pump Station, Contract No. 7-11-1, and Abandonment of Castlerock and Dow
Avenue Pump Stations and Modifications to MacArthur Pump Station, Contract
No. 7-11-3.
NOW, THEREFORE, the Board of Directors of County Sanitation District No. 7
of Orange County, California,
DOES HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That pursuant to the District's Guidelines Implementing the
California Environmental Quality Act of 1970, as amended, the District has
concurrently undertaken an environmental review of the proposed project and
hereby determine that said project is categorically exempt from further CEQA
requirements; and,
Section 2. That Abandonment of Lane Road Pump Station, Contract
No. 7-11-1, and Abandonment of Castlerock and Dow Avenue Pump Stations and
Modifications to MacArthur Pump Station, Contract No. 7-11-3, is hereby
approved, and that the Secretary be directed to file any documents required by
said Guidelines Implementing the California Environmental Quality Act of 1970,
as amended; and,
Section 3. That the detailed plans, specifications and contract documents
"R-1" AGENDA ITEM #9(w) - DISTRICT 7 "R-1"
this day submitted to the Board of Directors by Boyle Engineering Corporation,
District's engineers, for Abandonment of Lane Road Pump Station, Contract
No. 7-11-1, and Abandonment of Castlerock and Dow Avenue'Pump Stations and
Modifications to MacArthur Pump Station, Contract No. 7-11-3, are hereby
approved and adopted; and,
Section 4. That the Secretary be authorized and directed to advertise for
bids for said work pursuant to the provisions of the Public Contracts Code of
the State of California; and,
Section S. That the General Manager be authorized to establish the date
and time at which said bids will be publicly opened and read; and,
Section 6. That the Secretary and the District's Director of Engineering
or his designee be authorized to open said bids on behalf of the Board of
Directors.
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
dad
"R-2" AGENDA ITEM #9(w) - DISTRICT 7 "R-2"
RESOLUTION NO. 89-148-7
ACCEPTING GRANTS OF EASEMENT FROM ALLEN D. GAGE
RE CONTRACT NO. 7-11-3
A RESOLUTION OF THE BOARD OF DIRECTORS OF COUNTY
SANITATION DISTRICT NO. 7 OF ORANGE COUNTY,
CALIFORNIA, APPROVING AND ACCEPTING GRANTS OF
EASEMENT FROM ALLEN D. GAGE IN CONNECTION WITH
ABANDONMENT OF CASTLEROCK AND DOW AVENUE PUMP
STATIONS AND MODIFICATIONS TO MAC ARTHUR PUMP
STATION, CONTRACT NO. 7-11-3
* * * * * * It * * * * * * * * * * * *
The Board of Directors of County Sanitation District No. 7 of Orange
County, California,
DOES HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That the certain Grant of Easement dated September 18, 1989,
wherein a temporary construction easement in the vicinity of Strawberry Ridge
and Castlerock Lane in the City of Orange for right of way required in
connection with Abandonment of Castlerock and Dow Avenue Pump Stations and
Modifications to MacArthur Pump Station, Contract No. 7-11-3, is granted to
County Sanitation District No. 7, is hereby accepted from Allen D. Gage; and,
Section 2. That the certain Grant of Easement dated September 18, 1989,
wherein a permanent ingress and egress easement, in the vicinity of Strawberry
Ridge and Castlerock Lane in the City of Orange for right of way required in
connection with Abandonment of Castlerock and Dow Avenue Pump Stations and
Modifications to MacArthur Pump Station, Contract No. 7-11-3, is granted to
County Sanitation District No. 7, is hereby accepted from Allen D. Gage; and,
Section 3. That the real property over which said temporary and permanent
easements are granted is more particularly described and shown on Exhibits "A",
"B", "C" and "D", attached hereto and made a part of this resolution; and,
Section 4. That payment in the amount of $3,000.00 for said temporary and
permanent right of way is hereby authorized; and,
"S-1" AGENDA ITEM #9(x) - DISTRICT 7 "S-1"
Section 4. That the Secretary of the Boards of Directors is hereby
authorized and directed to record said permanent Grant of Easement in the
Official Records of Orange County, California.
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
"S-2" AGENDA ITEM #9(x) - DISTRICT 7 "S-2"
RESOLUTION NO. 89-142
AWARDING JOB NO. P1-33
A JOINT RESOLUTION OF THE BOARDS OF DIRECTORS
OF COUNTY SANITATION DISTRICTS NOS. 1, 2, 3, 5,
6, 7, 11, 13 AND 14 OF ORANGE COUNTY, CALIFORNIA,
AWARDING CONTRACT FOR PRIMARY CLARIFIERS NOS. 6-15
AND RELATED FACILITIES AT RECLAMATION PLANT NO. 1,
JOB NO. P1-33
k k k k k k * k k k k * k k *
The Boards of Directors of County Sanitation Districts Nos. 1, 2, 3, 5, 6,
7, 11, 13 and 14 of Orange County, California,
DO HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That the proposed construction contract is for a project which
is a portion of the previously-approved Supplement No. 1 to the 1985 Joint
Treatment Works Wastewater Master Plan. The project is to be constructed as per
the Master Plan approval . In accordance with the California Environmental
Quality Act of 1970, as amended, and Section 15090 of the Districts' Guidelines,
a Final Supplement to the Joint Treatment Works Wastewater Master Plan
Environmental Impact Report covering this project was approved by the Boards of
Directors on November 18, 1987; and,
Section 2. That the written recommendation this day submitted to the
Boards of Directors by the Districts' Director of Engineering that award of
contract be made to Gust K. Newberg Construction Co. for Primary Clarifiers
Nos. 6-15 and Related Facilities at Reclamation Plant No. 1, Job No. P1-33, and
bid tabulation and proposal submitted for said work are hereby received and
ordered filed; and,
Section 3. That the contract for Primary Clarifiers 6-15 and Related
Facilities at Reclamation Plant No. 1, Job No. P1-33, be awarded to Gust
K. Newberg Construction Co. in the total amount of $39,657,000.00 in accordance
with the terms of their bid and the prices contained therein; and,
"T-1" AGENDA ITEM #11(e) - ALL DISTRICTS "T-1"
Section 4. That the Chairman and Secretary of District No. 1, acting for
itself and as agent for Districts Nos. 2, 3, 5, 6, 7, 11, 13 and 14, are hereby
authorized and directed to enter into and sign a contract with said contractor
for said work, pursuant to the specifications and contract documents therefor,
in form approved by the General Counsel ; and,
Section 5. That all other bids for said work are hereby rejected.
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
"T-2" AGENDA ITEM #11(E) - ALL DISTRICTS "T-2"
COUNTY SANITATION DISTRICTS
If ORANGE COUNTY. CALIFORNIA
September 26, 1989
11:00 a.m. +aee.zuisev
*o.soxmn
3 ADDENDA wuxrux v.usr.uuwaxiesnze-e,n
B I D T A B U L A T I O N n+elssz-ze.,
H E E
JOB NO. P1-33
PROJECT TITLE Primary Clarifiers Nas. 6-15 and Related Facilities at
eclamat on P ant No. 1
PROJECT DESCRIPTION Construction of ten covered primary clarifier basins
associated influent and effluent piping, .function structures digester c eaning
beds foul a r scrubber for odor control modifications to the waste sidestream
pump station, CWD pipel ne and interior roads
Pi-33 $40,811,_0_0.W__
ENGINEER'S ESTIMATE $46,000,000.00 BUDGET AMOUNT: OCWD $ 1,000,000.00
Roads $ 1,100,000.00
TOTAL: T42, 117U .00
CONTRACTOR ¢a*at TOTAL BID c
1. Gust K. Newberg Const. Co. , Los Angeles, CA $39,657,000.00
2. S. A. Healy Company, Azusa, CA $41,892,900.00*
3. Kiewit Pacific Co., Santa Fe Springs, CA $42,826,000.00
4. Advanco Constructors, Upland, CA $43,928,215.00
5. Dillingham Construction N.A., Inc. , Pleasanton, CA $44,444,000.00
6. Margate-Rados, A Joint Venture, Carson, CA $44,621,000.00
7. M. A. Mortenson Co., Minneapolis, MN $46,566,000.00
*Error in addition - corrected total.
I have reviewed the proposals submitted for the above'project and find that the
low bid is a responsible bid. I, therefore, recommend award to Gust K. Newberg
of Los Angeles, California in the bid IZ
$39,65L/I7,,00\I0�.�0.00 as the lowest and
best bid.
Thomas M. Dawes
Director of Engineering
"T-3" AGENDA ITEM #11(e) - ALL DISTRICTS "T-3"
COUNTY SANITATION DISTRICTS
OF ORANGE COUNTY, CALIFORNIA
a�g P.O. BOX 8127, FOUNTAIN VALLEY.CALIFORNIA 92728-8127
10844 ELLIS.FOUNTAIN VALLEY. CALIFORNIA 92708-7018
(714)962-2411
September 20, 1989
Boards of Directors
County Sanitation Districts of
Orange County, California
10844 Ellis Avenue
Fountain Valley, California 92708-7018
Subject: Certification of Negotiated Fee for Professional Engineering Services
with John Carollo Engineers in Connection with Secondary Treatment
Improvements at Plant No. 1, Job No. P1-36, and Secondary Treatment
Expansion at Plant No. 2, Job No. P2-42
In accordance with the Districts' procedures for selection of professional
engineering services, the Selection Committee has negotiated the following fee
with John Carollo Engineers for design and construction services for Secondary
Treatment Improvements at Plant No. 1, Job No. PI-36, and Secondary Treatment
Expansion at Plant No. 2, Job No. P2-42, on an hourly-rate basis including labor
plus overhead, plus direct expenses, and fixed profit, in an amount not to
exceed $4,997,841.00.
Engineering Services, (hourly rates
including labor plus overhead
at 155%) , not to exceed $4,313,341.00
Direct Expenses, not to exceed 180,000.00
Fixed Profit 504,500.00
TOTAL CONTRACT, not to exceed $4,997,841.00
The Selection Committee hereby certifies the above final negotiated fee
as reasonable for the services to be performed and that said fee will not
result in excessive profits for the consultant.
/s/Ronald B. Hoeste rey /s/A. B. Catlin
Ronald B. Hoeste rey A. B. "Buck" Catlin
Joint Chairman Vice Joint Chairman
Selection Committee Selection Committee
/s/Thomas M. Dawes
Thomas M. Dawes
Director of Engineering
Selection Committee
'lull AGENDA ITEM #12(b) - ALL DISTRICTS 'lull
RESOLUTION NO. 89-143
�../ APPROVING PROFESSIONAL SERVICES AGREEMENT
WITH JOHN CAROLLO ENGINEER FOR DESIGN,
CONSTRUCTION SERVICES, OPERATION AND
MAINTENANCE MANUAL5 AND TRAINING RE JOB
NOS. Pl-36 AND P2-42
A JOINT RESOLUTION OF THE BOARDS OF DIRECTORS
OF COUNTY SANITATION DISTRICTS NOS. 1, 2, 3,
5, 6, 7, 11, 13 AND 14 OF ORANGE COUNTY,
CALIFORNIA, APPROVING PROFESSIONAL SERVICES
AGREEMENT WITH JOHN CAROLLO ENGINEERS FOR
DESIGN AND CONSTRUCTION SERVICES, PREPARATION OF
OPERATIONS AND MAINTENANCE MANUALS, AND TRAINING
SERVICES RE SECONDARY TREATMENT IMPROVEMENTS AT
PLANT NO. 1, JOB NO. P1-36, AND SECONDARY
TREATMENT EXPANSION AT PLANT NO. 2, JOB NO. P2-42
} k Y Y f Y f f R R R * t f ! It f
WHEREAS, the Boards of Directors of County Sanitation Districts Nos. 1, 2,
3, 5, 6, 7, 11, 13 and 14 of Orange County have heretofore adopted a policy
establishing procedures for the selection of professional engineering and
architectural services; and,
WHEREAS, pursuant to said procedures an agreement has been negotiated with
John Carollo Engineers for design and construction services, preparation of
operations and maintenance manuals, and training services required relative to
Secondary Treatment Improvements at Plant No. 1, Job No. P1-36, and Secondary
Treatment Expansion at Plant No. 2, Job No. P2-42; and,
WHEREAS, pursuant to authorization of the Boards of Directors on
July 12, 1989, the Selection Committee, established pursuant to said procedures,
has negotiated and certified the final negotiated fee for said services.
NOW, THEREFORE, the Boards of Directors of County Sanitation Districts
Nos. 1, 2, 3, 5, 6, 7, 11, 13 and 14 of Orange County, California,
DO HEREBY RESOLVE, DETERMINE AND ORDER:
Section 1. That the proposed Professional Services Agreement is for two
"V-1" AGENDA ITEM #12(C) - ALL DISTRICTS "V-1"
projects which are portions of the previously-approved Collection, Treatment and
Disposal Facilities Master Plan. The projects are to be designed as per the
Master Plan approval . In accordance with the California Environmental Quality
Act of 1970, as amended, and Section 15069 of the Districts' Guidelines, a Final
Program Environmental Impact Report covering these projects was approved by the
Districts' Boards of Directors on July 19, 1989; and,
Section 2. That the certain Professional Services Agreement dated
October 11, 1989, by and between County Sanitation Districts Nos. 1, 2, 3, 5,
6, 7, 11, 13 and 14 of Orange County and John Carollo Engineers, for design and
construction services, preparation of operations and maintenance manuals, and
training services required relative to Secondary Treatment Improvements at Plant
No. 1, Job No. P1-36, and Secondary Treatment Expansion at Plant No. 2, Job No.
P2-42, is hereby approved and accepted; and,
Section 3. That payment for said services is hereby authorized in
accordance with the provisions set forth in said agreement, as follows:
Professional Services at hourly
rates plus overhead at 155%,
not to exceed $ 4,313,341.00
Direct Expenses, not to exceed 180,000.00
Fixed Profit 504,500.00
TOTAL, not to exceed $ 4,997,841.00
Section 3. That the Chairman and Secretary of District No. 1, acting for
itself and on behalf of Districts Nos. 2, 3, 5, 6, 7, 11, 13 and 14, are hereby
authorized and directed to execute said agreement in form approved by the
General Counsel .
PASSED AND ADOPTED at a regular meeting held October 11, 1989.
"V-2" AGENDA ITEM#12(c) - ALL DISTRICTS "V-2"
ORDINANCE NO.
�..,/ AN ORDINANCE OF THE BOARD OF DIRECTORS OF
COUNTY SANITATION DISTRICT NO. OF ORANGE
COUNTY, CALIFORNIA, AMENDING ORDINANCE
NO. ESTABLISHING WASTEWATER DISCHARGE
REGULATIONS FOR USE OF DISTRICT SEWERAGE
FACILITIES
x x x x x x x x x x x x
The Board of Directors of County Sanitation District No._ of Orange County,
California, does hereby FIND:
A. That a Comprehensive 30-year Master Plan of Capital Facilities entitled
"Collection, Treatment and Disposal Facilities Master Plan-1989", hereinafter
the "Master Plan", which includes detailed financial and engineering reports has
been prepared, approved and adopted by the Board of Directors setting forth and
identifying the required future development of District and jointly owned
facilities, including the financial projections for providing sewer service to
all properties within the District service area; and,
B. That the financial and engineering reports of the Master Plan have been
made available to the public and been subject to noticed public hearings, all in
accordance with the provisions of Government Code Section 54992 and other
provisions of law; and,
C. That the adoption of the proposed Capital Facilities connection charges
will provide revenue to assist in the financing of Capital Facilities identified
in the adapted Master Plan and deemed necessary to maintain service within the
existing service area; and,
D. That the change in rate structure will not necessarily result in an
expansion of facilities to provide for growth outside the existing service area.
The adoption of these rates will not result in any specific project nor result
-1-
"W-1" AGENDA ITEM #14 - DISTRICTS 1,2,3,5,6,7 & 11 11W-1"
in a direct physical change in the environment; and,
E. That the District has, on July 19, 1989, adopted a Final Program
Environmental Impact Report in accordance with legally required notices and
public hearing, relating to the Master Plan including the financial program to
implement the construction of capital facilities identified in the Master Plan;
and,
F. That the District either has or will produce Negative Declarations,
Environmental Impact Reports or other CEQA compliance prior to the construction
of any capital improvement project planned for in the District's adopted Master
Plan; and,
G. That the proposed increases in the capital facilities connection charges
are established upon a rational basis between the fees charged each customer and
the service and facilities provided to each new customer to the District; and,
H. That the adoption of this Ordinance is statutorily exempt under the
California Environmental Quality Act from further environmental assessment
pursuant to the provisions of California Public Resources Code Section
21080(b)(8) and California Code of Regulations Section 15273(a)(4) ; and,
I. That the new capital facilities connection fees established by this
Ordinance do not exceed the estimated amount required to provide the sewer
service for which the fee is levied, as provided in Government Code Sections
54991 and 54992.
NOW, THEREFORE, The Board of Directors of County Sanitation District No.
of Orange County, California, does hereby ORDAIN as follows:
Section 1. Section No. 702 of Ordinance No. _ is hereby amended to
read:
_2_
"W-2" AGENDA ITEM #14 - DISTRICTS 1,2,3,5,6,7 & 11 "W-2"
"702. DISTRICT NO. CONNECTION CHARGES
A. District Connection Permit Required
No application for a permit for a connection to a District
sewerage facility or to any sewerage facility which discharges
into a District sewerage facility shall be considered until a
District connection charge is paid by the applicant. No
connection permit shall be issued unless there is an established
use of the property to be served or a valid building permit
issued which establishes the use of said property.
B. District Connection Charge Amounts
The following District connection charges are hereby established
commencing January 1, 1990, and shall be paid to the District or
to an agency designated by the District:
(1) Connection charge for new construction dwelling buildings:
For each new dwelling unit constructed, the connection
charge shall be $2,270 per dwelling unit.
(2) Connection charge for existing dwelling buildings:
For the connection of each existing dwelling building,
the connection charge shall be $2,270 per dwelling unit.
(3) Connection charge for new construction and existing structures,
other than dwelling buildings:
For all other new construction, including but not limited to
commercial and industrial buildings, hotels and motels and
-3-
"W-3" AGENDA ITEM #14 - DISTRICTS 1,2,3.5,6,7 & 11 "W-3"
public buildings, the connection charge shall be $450 per
1,000 square feet of floor area contained within such
construction, provided that the minimum connection charge
for such new construction shall be $2,270.
(4) Connection charge for replacement buildings:
For new construction replacing former buildings, the
connection charge shall be calculated on the same basis as
provided in Paragraphs 1 and 3 above. If such replacement
construction is commenced within two years after demolition
or destruction of the former building, a credit against such
charge shall be allowed and shall be the equivalent
connection charge for the building being demolished or
destroyed, calculated on the basis of current charges for
new construction. In no case shall such credit exceed the
connection charge.
(5) Connection charges for additions or alterations of existing
buildings:
In the case of structures where further new construction or
alteration is made to increase the occupancy of family
dwelling buildings or the area of buildings to be used for
other than family dwelling buildings, the connection charge
shall be $2,270 for each dwelling unit added or created,
and, in the case of new construction other than family
dwelling buildings, it shall be $450 per 1,000 square feet of
-4-
"W-4" AGENDA ITEM #14 - DISTRICTS 1,2,3,5,6,7 & 11 "W-4"
additional floor area contained within such new construction,
provided such new construction shall contain additional plumbing
fixture units.
C. Annual Adjustment of Charges
Each year, commencing on July 1, 1990, and continuing thereafter
on each July 1, the capital facilities connection fee shall be
adjusted by an increment based on the change in the ENR
Construction Cast Index for Los Angeles over the prior year,
and rounded to the nearest $10.
However, the District Board of Directors may at its option
determine, by resolution adopted prior thereto, that such
adjustment shall not be effective for the next succeeding year,
or may determine other amounts, as appropriate."
Section 2. Fees established by Section 702 shall be effective January 1,
1990.
Section 3. This Ordinance shall be effective January 1, 1990.
Section 4: If any provision or Section of this Ordinance is declared to be
unlawful , invalid, or in any manner unenforceable, then each and every other
provision herein shall remain in force as though enacted independently.
The Secretary of the Board is hereby directed to certify to the adoption
of this Ordinance and cause it to be published in a newspaper of general
circulation within the County.
" -5-
"W-51 AGENDA ITEM #14 - DISTRICTS 1,2,3,5,6,7 & 11 "W-5"
PASSED AND ADOPTED by the Board of Directors of County Sanitation District
No. of Orange County, California, at a regular meeting held October 11, 1989.
Chairman of the Board of Directors
County Sanitation District No.
of Orange County, California
ATTEST:
Secretary of the Board of Directors
County Sanitation District No.
of Orange County, California
-6- dad
"W-6" AGENDA ITEM #14 - DISTRICTS 1,2,3,5,7,7 & 11 "W-6"
ORDINANCE NO. 1306
�...' AN ORDINANCE OF THE BOARD OF DIRECTORS OF
COUNTY SANITATION DISTRICT NO. 13 OF ORANGE
COUNTY, CALIFORNIA, AMENDING ORDINANCE
NO. 1305 ESTABLISHING WASTEWATER DISCHARGE
REGULATIONS FOR USE OF DISTRICT SEWERAGE
FACILITIES
x x x x x x x x x x x x
The Board of Directors of County Sanitation District No. 13 of Orange County,
California, does hereby FIND:
A. That a Comprehensive 30-year Master Plan of Capital Facilities entitled
"Collection, Treatment and Disposal Facilities Master Plan-198911, hereinafter
the "Master Plan", which Includes detailed financial and engineering reports has
been prepared, approved and adopted by the Board of Directors setting forth and
identifying the required future development of District and jointly owned
facilities, including the financial projections for providing sewer service to
all properties within the District service area; and,
B. That the financial and engineering reports of the Master Plan have been
made available to the public and been subject to noticed public hearings, all in
accordance with the provisions of Government Code Section 54992 and other
provisions of law; and,
C. That the adoption of the proposed Capital Facilities connection charges
will provide revenue to assist in the financing of Capital Facilities Identified
in the adopted Master Plan and deemed necessary to maintain service within the
existing service area; and,
D. That the change in rate structure will not necessarily result in an
expansion of facilities to provide for growth outside the existing service area.
The adoption of these rates will not result in any specific project nor result
11X-1" AGENDA ITEM #14 - DISTRICT 13 11X-1"
in a direct physical change in the environment; and,
E. That the District has, on July 19, 1989, adopted a Final Program �...'
Environmental Impact Report in accordance with legally required notices and
public hearing, relating to the Master Plan including the financial program to
implement the construction of capital facilities identified in the Master Plan;
and,
F. That the District either has or will produce Negative Declarations,
Environmental Impact Reports or other CEQA compliance prior to the construction
of any capital improvement project planned for in the District's adopted Master
Plan; and,
G. That the proposed increases in the capital facilities connection charges
are established upon a rational basis between the fees charged each customer and
the service and facilities provided to each new customer to the District; and,
H. That the adoption of this Ordinance is statutorily exempt under the
California Environmental Quality Act from further environmental assessment
pursuant to the provisions of California Public Resources Code Section
21080(b)(8) and California Code of Regulations Section 15273(a) (4) ; and,
I. That the new capital facilities connection fees established by this
Ordinance do not exceed the estimated amount required to provide the sewer
service for which the fee is levied, as provided in Government Code Sections
54991 .and 54992.
NOW, THEREFORE, The Board of Directors of County Sanitation District No. 13
of Orange County, California, does hereby ORDAIN as follows:
Section 1. Section No. 702 of Ordinance No. 1305 is hereby amended to
read:
�...
-2-
"X-2" AGENDA ITEM #14 - DISTRICT 13 "X-2"
"702. DISTRICT NO. 13 CONNECTION CHARGES
A. District Connection Permit Required
No application for a permit for a connection to a District
sewerage facility or to any sewerage facility which discharges
into a District sewerage facility shall be considered until a
District connection charge is paid by the applicant. No
connection permit shall be issued unless there is an established
use of the property to be served or a valid building permit
Issued which establishes the use of said property.
B. District Connection Charge Amounts
The following District connection charges are hereby established
commencing January 1, 1990, and shall be paid to the District or
to an agency designated by the District:
(1) Connection charge for new construction dwelling buildings:
For each new dwelling unit constructed, the connection
charge shall be $2,270 per dwelling unit.
(2) Connection charge for existing dwelling buildings:
For the connection of each existing dwelling building,
the connection charge shall be $2,270 per dwelling unit.
(3) Connection charge for new construction and existing structures,
other than dwelling buildings:
For all other new construction, including but not limited to
commercial and industrial buildings, hotels and motels and
../ -3-
"X-3" AGENDA ITEM #14 - DISTRICT 13 11X-3"
public buildings, the connection charge shall be $450 per
1,000 square feet of floor area contained within such
construction, provided that the minimum connection charge
for such new construction shall be $2,270.
(4) Connection charge for replacement buildings:
For new construction replacing former buildings, the
connection charge shall be calculated on the same basis as
provided in Paragraphs 1 and 3 above. If such replacement
construction is commenced within two years after demolition
or destruction of the former building, a credit against such
charge shall be allowed and shall be the equivalent
connection charge for the building being demolished or
destroyed, calculated on the basis of current charges for
new construction. In no case shall such credit exceed the
connection charge.
(5) Connection charges for additions or alterations of existing
buildings:
In the case of structures where further new construction or
alteration is made to increase the occupancy of family
dwelling buildings or the area of buildings to be used for
other than family dwelling buildings, the connection charge
shall be $2,270 for each dwelling unit added or created,
and, in the case of new construction other than family
dwelling buildings, it shall be $450 per 1,000 square feet of
�,..✓
-4-
"X-4" AGENDA ITEM #14 - DISTRICT 13 "X-4"
additional floor area contained within such new construction,
provided such new construction shall contain additional plumbing
fixture units.
(6) Capital facilities connection charges will be assessed to local
government agencies for connecting directly or indirectly to
the Districts' sewerage facilities.
C. Annual Adjustment of Charges
Each year, commencing on July 1, 1990, and continuing thereafter
on each July 1, the capital facilities connection fee shall be
adjusted by an increment based on the change in the ENR
Construction Cost Index for Los Angeles over the prior year,
and rounded to the nearest $10.
However, the District Board of Directors may at its option
determine, by resolution adopted prior thereto, that such
adjustment shall not be effective for the next succeeding year,
or may determine other amounts, as appropriate."
Section 2. Fees established by Section 702 shall be effective January 1,
1990.
Section 3. This Ordinance shall be effective January 1, 1990.
Section 4: If any provision or Section of this Ordinance is declared to be
unlawful , invalid, or in any manner unenforceable, then each and every other
provision herein shall remain in force as though enacted independently.
"X-5" AGENDA ITEM #14 - DISTRICT 13 "X-5"
The Secretary of the Board is hereby directed to certify to the adoption
of this Ordinance and cause it to be published in a newspaper of general
circulation within the County.
PASSED AND ADOPTED by the Board of Directors of County Sanitation District
No. 13 of Orange County, California, at a regular meeting held October 11, 1989.
Chairman of the Board of Directors
County Sanitation District No. 13
of Orange County, California
ATTEST:
Secretary of the Board of Directors
County Sanitation District No. 13
of Orange County, California
-6-
"X-6" AGENDA ITEM #14 - DISTRICT 13 "X-6"
COUNTY SANITATION DISTRICTS
d ORANGE COUNTY, CALIFORNIA
18 EW Awwe
PO BOX 8127
i011NiGM VGIIEY.CpLRpP,Us 9272881$7
INITIAL STUDY 01m BB2.2211
(To Be Completed by Lead Agency)
I. Background
A. Name of Proponent County Sanitation Districts 6, 7 and 14
B. Address and Phone Number of Proponent
10844 Ellis Avenue, Post Office Box 8127
Fountain Valley, CA 92728-8127
C. Contact Person Thomas M. Dawes, Director of Engineering
D. Title and Location of Project
Draft Supplement No. 1 to Environmental Impact Report for Proposed
Formation of County Sanitation District No. 14 and Proposed
Reorganization No. 79 Involving Reorganization of Districts Nos. 7
and 13 re Baker-Gisler Interceptor, Contracts Nos. 14-1-1A and
14-1-18, and Baker Force Mains, Contract No. 14-1-2
E. Description of Project
Additional study to assess impacts of change in alignment of the
Baker Force Mains and the Baker-Gisler Interceptor sewer lines
addressing the necessity for acquisition of easements not specified
in original EIR
"Y-1" AGENDA ITEM #29(b) - DISTRICTS 6, 7 & 14 "Y-1"
II. Guidelines
A. Does the proposed activity qualify as a project as defined in Section
28.
Yes XX No —
(If activity does not qualify as project, do not complete remainder of
form).
B. Does the project qualify as:
1. Ministerial (Section 6) Yes No XX
2. Emergency (Section 13) Yes _ No XX
3. A feasibility or planning study (Section 33) Yes _ No XX
4. Categorically exempt pursuant to Article 8 of the State Guidelines
(Section 40) Yes — No XX
S. Involves another agency which constitutes the lead agency
(Section 36) Yes — No XX If yes, identify lead agency:
(If yes has been checked for any of the above, an Environmental Impact
Assessment/Environmental Impact Report or Negative Declaration need
not be prepared).
III. Environmental Impacts
(Explanations of all "yes" and "maybe" answers are required on attached sheets) .
Yes Maybe No
A. Earth. Will the proposal result in:
1. Unstable earth conditions or in changes
in geologic substructures? X
2. Disruptions, displacements, compaction
or overcovering of the soil? X _
3. Change in topography or ground surface
relief features? X
4. The destruction, covering or modification
of any unique geologic or physical features? X _
S. Any increase in wind or water erosion of
soils, either on or off the site? X
-2-
"Y-2" AGENDA ITEM #29(b) - DISTRICTS 6, 7 8 14 "Y-2"
Yes Maybe Wo
�.J 6. Changes in desposition or erosion of beach
sands or changes in silation, deposition
or erosion which may modify the channel
of a river or stream or the bed of the
ocean or any bay, inlet or lake? X
7. Exposure of people or property to geological
hazards such as earthquakes, landslides,
mudslides, ground failure or similar
hazard? X
B. Air. Will the proposal result in:
1. Substantial air emissions or deterioration
of ambient air quality? X
2. The creation of objectionable odors? X
3. Alteration of air movement, moisture or
temperature or any change in climate,
either locally or regionally? X
C. Water. Will the proposal result in:
1. Change in currents or the course of
direction of water movements in either
marine or fresh water? X
2. Changes in absorption rates, drainage
patterns or the rate and amount of
surface runoff? X
3. Alterations to the course of flow of
flood waters? X
4. Change in the amount of surface water
in any water body? X
S. Discharge into surface waters or in any
alteration of surface water quality,
including, but not limited to, temperature,
dissolved oxygen or turbidity? X
6. Alteration of the direction or rate
of flow of ground waters? X
7. Change in the quantity of ground waters,
either through direct additions or
withdrawals, or through interception of an
aquifer by cuts or excavations? X
-3-
"Y-3" AGENDA ITEM k29(b) - DISTRICTS 6, 7 & 14 "Y-3"
Yes Maybe No
8. Substantial reduction in the amount of
water otherwise available for public
water supplies? x
9. Exposure of people or property to related
hazards such as flooding or tidal waves? x
D. Plant Life. Will proposal result in:
1. Change in the diversity of species or
numbers of any species of plants (including
trees, shrubs, grass, crops and aquatic
plants)? X
2. Reduction of the numbers of any unique,
rare or endangered species of plants? x
3. Introduction of new species of plants into
an area or in a barrier to the normal
replenishment of existing species? x
4. Reduction in acreage of any agriculture
crop? x
E. Animal Life. Will proposal result in:
1. Change in the diversity of species or
numbers of any species of animals (birds,
land animals including reptiles, fish
and shellfish, benthic organisms or
insects? x
2. Reduction of the numbers of any unique,
rare or endangered species of animals? x
3. Introduction of new species of animals
into an area or result in a barrier to
the migration or movement of animals? x
4. Deterioration to existing fish or
wildlife habitat? x
F. Noise. Will the proposal result in:
1. Increase in existing noise levels? X
2. Exposure of people to severe noise levels? x
G. Light and Glare. Will the proposal produce
light or glare? x
-4-
"Y-4" AGENDA ITEM #29(b) - DISTRICTS 6, 7 & 14 "Y-4"
Yes Maybe No
�..� H. Land Use. Will the proposal result in a
substantial alteration of the present or
planned land use of an area? X
I. Natural Resources. Will the proposal result in:
1. Increase in the rate of use of any
natural resources? x
2. Substantial depletion of any nonrenewable
natural resource? x
J. Risk of Upset. Will the proposal involve:
1. A risk of an explosion or the release of
hazardous substances (including, but not
limited to, oil , pesticides, chemicals
or radiation) in the event of an accident
or upset conditions? x
2. Possible interference with an emergency
response plan or an emergency evacuation
plan? x
K. Population. Will the proposal alter the
location, distribution, density or growth
rate of the human population of an area? x
L. Housing. Will the proposal affect existing
housing or create a demand for additional
housing? x
M. Transportation/Circulation. Will the proposal
result in:
1. Generation of substantial additional
vehicular movement? x
2. Effects on existing parking facilities
or demand for new parking? x
?. Substantial impact upon existing
transportation systems? x
4. Alterations to present patterns of
circulation or movement of people
and/or goods? x
5. Alterations to waterborne, rail or air
traffic? x
-5-
"Y-5" AGENDA ITEM #29(b) - DISTRICTS 6. 7 & 14 "Y-5"
Yes Maybe No
6. Increase in traffic hazards to motor
vehicles, bicyclists or pedestrians? X
N. Public Services. Will the proposal have an
effect upon or result in a need for new or
altered governmental services in any of the
following areas:
1. Fire protection? X
2. Police protection? X
3. Schools? X
4. Parks or other recreational facilities? X
5. Maintenance of public facilities,
including roads? X
6. Other governmental service? X
0. Energy. Will the proposal result in:
1. Use of substantial amounts of fuel
or energy? X
2. Substantial increase in demand upon
existing sources of energy or require
the development of new sources of energy? x
P. Utilities. Will the proposal result in a need
for new systems or substantial alterations to
the following utilities:
1. Power or natural gas? X
2. Communications systems? X
3. Water? X
4. Sewer or septic tanks? X
S. Storm water drainage? X
6. Solids waste and disposal? X
Q. Human Health. Will the proposal result in:
1. Creation of any health hazard or potential
health hazard (excluding mental health?) X
"Y-6" AGENDA ITEM #29(b) --6DISTRICTS 6, 7 & 14 "Y-6"
Yes Maybe Wo
2. Exposure of people to potential health
hazards? X
R. Aesthetics. Will the proposal result in the
obstruction of any scenic vista or view open
to the public or will the proposal result in
the creation of an aesthetically offensive
site open to the public view? X
S. Recreation. Will the proposal result in an
impact upon the quality or quantity of
existing recreational opportunities? X
T. Cultural Resources.
1. Will the proposal result in the alteration
of or the destruction of a prehistoric
or historicarcheaological site? x
2. Will the proposal result in adverse
physical or aesthetic effects to a
prehistoric or historic building,
structure or object? X
3. Does the proposal have the potential to
cause a physical change which would
affect unique ethnic cultural values? X
4. Will the proposal restrict existing
religious or sacred uses within the
potential impact area? X
U. Mandatory Findings of Significance.
1. Does the project have the potential to
degrade the quality of the environment,
substantially reduce the habitat of a
fish or wildlife species, cause a fish
or wildlife population to drop below
self-sustaining levels, threaten to
eliminate a plant or animal community,
reduce the number or restrict the range
of a rare or endangered plant or animal ,
or eliminate important examples of the
major periods of California history or
prehistory? x
_?_
"Y-7- AGENDA ITEM #29(b) - DISTRICTS 5, 7 & 14 "Y-7"
Yes Maybe No
2. Does the project have the potential to
achieve short-term, to the disadvantage of
long-term, environmental goals? (A short-
term impact on the environment is one which
occurs in a relatively brief, definitive
period of time, while long-term impacts
will endure well into the future). X
3. Does the project have impacts which are
individually limited but cumulative
considerable? (A project may impact on
two or more separate resources where the
impact on each resource is relatively
small , but where the effect of the total
of those impacts on the environment is
significant). X
4. Does the project have environmental
effects which will cause substantial
adverse effects on human beings,
either directly or indirectly? X
IV. Discussion of Environmental Evaluation
See attached sheet.
V. Discussion of Zoning Compatibility
Not applicable.
VI. Determination
On the basis of this initial evaluation:
I find that the proposed project COULD NOT have a significant
effect on the environment and a NEGATIVE DECLARATION will be
prepared.
I find that although the proposed project could have a
significant effect on the environment, there will not be
a significant effect in this case because the mitigation
measures described on an attached sheet have been added
to the project. A NEGATIVE DECLARATION WILL BE PREPARED.
I find the proposed project MAY have a significant effect
on the environment and an ENVIRONMENTAL IMPACT REPORT is
required. XX
Date: October 3, 1989 COUNTY SANITATION DISTRICTS OF
ORA/NNCE-CDUNTYYY
Thomas M. Dawes
Director of Engineering
-8-
"Y-8" AGENDA ITEM #29(b) - DISTRICTS 6, 7 & 14 "Y-8"
IV. DISCUSSION OF ENVIRONMENTAL EVALUATION
�...✓ (Explanations of Yes and Maybe Notations)
A.2. , A. 3 . , and A.4:
Temporary construction, disruption and displacements will
occur as a result of the installation of the sewer pipe.
This was noted in the original EIR, however, since the
alignment has changed, it will be reviewed again.
F.1 . Noise levels will increase as a result of construction
activities. The construction documents will require that
the contractor comply with applicable city noise
ordinances.
H. Temporary alteration of land uses will occur as a result of
construction activities. The land will be restored to
existing uses and conditions at the completion of the
construction period.
M.2. The construction activities will require use of areas now
used for parking. Accordingly, temporary relocation of
parking will occur on public streets as well as within
private parking areas over which easements will be acquired.
M. 3 . Construction of the sewer within public rights-of-way will
require traffic detours approved by the City Engineer.
M.4 . Construction within public rights-of-way used for travel
will result in traffic pattern changes.
M.6 . Construction activities within travel ways increase the
level of traffic hazards to motor vehicles, bicyclists and
pedestrians. The traffic detours will minimize the hazards.
N.5. The construction will disrupt public facilities including
utilities and roads, however, they will be restored to
their former condition upon completion.
P.4. The construction will result in improved sewer service.
S. An easement within a private golf course is required.
Construction within the private golf course will result in
disruption of normal golf play.
"Y-9" AGENDA ITEM #29(b) - DISTRICTS 6. 7 & 14 11Y-9"
I
P
RECLAMATION
PLANT 1 yp; J K F' Z
C.S.D.O.0 m
0 3
0' MAIN ST.
m i a PUMP STATION
n y
GISLER AVE. OIEGO
m �.
3 CINNAMON
AVE, Q�
N 'P AIRPORT LOOP
LID
DEODRA� BAKER ST P
AVE.
I 3P
CJ
P
- Q
(n
NORTH q9
v N.T.S.
po LEGEND!
F, EASEMENTS REQUIRED
t
INTERCEPTOR/FORCE MAINS
BAKER - GISLER INTERCEPTOR . CONTRACTS NOS. 14-1-1 (A a B)
AND BAKER FORCE MAINS , CONTRACT NO. 14- 1 -2
K
O
ENVIRONMENTAL IMPACT ASSESSMENT
Name of Project: Draft Supplement No. 1 to Environmental Impact Report for
Porposed Formation of County Sanitation District No. 14 and
Proposed Reorganization No. 79 Involving Reorganization of
Districts Nos. 7 and 13 re Baker-Gisler Interceptor,
Contracts Nos. 14-1-1A and 14-1-IB and Baker Force Mains,
Contract No. 14-1-2
Location: Proposed sewer lines between Main Street Pump Station
adjacent to the John Wayne Airport "Clear Zone" in the City
of Irvine and Reclamation Plant No. 1 adjacent to the Santa
Ana River between Ellis and Garfield Avenues in the City of
Fountain Valley
Entity or Person Undertaking Project:
A. District County Sanitation Districts 6, 7 and 14
B. Other
Staff Determination:
The Districts' staff, having undertaken and completed an Initial Study of
this project in accordance with Section 15063 of the Amendments to the
California Environmental Quality Act, for the purpose of ascertaining
whether the proposed project might have significant effect on the
environment, has reached the following conclusion:
1. The project will not have a significant long term effect on
the environment because of the mitigation measures
incorporated; therefore, a Negative Declaration can be
prepared.
X 2. The project could have a significant effect on the
environment; therefore, a Supplement to the EIR will be
required.
ii
Date' ' Thomas M. Dawes
Director of Engineering
"Z" AGENDA ITEM #29(b) - DISTRICTS 6, 7 & 14 "Z"
COUNTY SANITATION
DISTRICTS NOS. 19 29 3, 5, 69 79 119 13 AND 14
OF
ORANGE COUNTY, CALIFORNIA
MINUTES OF THE REGULAR MEETING
ON
SEPTEMBER 13, 1989
PNITAifON
J;o� ovolu.o o qJ`''Di
uy $ m
S/ees 1954
ORgNGE co
V
ADMINISTRATIVE OFFICES
10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA
ROLL CALL
A regular meeting of the Boards of Directors of County Sanitation Districts Nos. 1, 2, 3,
S. 6, 7, 11, 13 and 14 of Orange County, California, was held on September 13, 1989, at
7:30 p.m., in the Districts- Administrative Offices. Following the Pledge of Allegiance and
invocation the roll was called and the Secretary reported a Quorum present for Districts
Nos. 1, 2, 3, S. 6, 7, 11, 13 and 14 as follows:
`..� ACTIVE DIRECTORS ALTERNATE DIRECTORS
DISTRICT NO. 1: x Robert Hanson, Chairman _Ofma Crank
x Oan Griset, Chai roan pro tem _Dan Young
_x—Ronald B. Hoesterey Ursula Kennedy
a Roger Stanton _Don R. Roth
DISTRICT NO. 2: a William D. Mahoney, Chairman Beth Graham
—Ron Isles, Chairman pro tem =Carrey Nelson
' Boland E. Bigonger 7--Henry W. Medea
=A.B. "Buck' Catlin _Chris Norby
x Dan Griset Dan Young
—James Neal __George Scott
x Arthur G. Newton Carol Downey
xBob Perry Norman Culver
=Iry Pickler _Fred Hunter
x Mayne Silzel James T. Fasbender
=Don E. Smith —Fred Barrera
a Roger Stanton _Don R. Roth
DISTRICT NO. 3: x Richard Polls, Chairman Orbrey Duke
xCarrey Nelson, Chairman pro tem _Mayne Wedin
—a—Edward L. Allen _Paul Verellen
a Margaret M. Arnold _John Kanel
x Wes Bannister _Peter Green
=A.B. -Buck' Catlin Chris Norby
Norman Culver -7--Bob Perry
a Dan R. Griffin _Donna L. Chessen
x Dan Griset _ am
Dan Young
a William D. Mahoney _Beth Grah
x James Neal _George Scott
=Iry Pickler _Fred Hunter
x J.R. 'Bob' Siefen _Dewey Miles
a Roger Stanton _Don R. Roth
x Charles Sylvia _Robert Wahlstram
=Edna Wilson Victor Grgas
DISTRICT NO. 5: x John C. Cox, Jr., Chairman Evelyn Hart
Donald A. Strauss, Chairman pro tan =Evelyn Hart
a Don R. Roth _Roger Stanton
DISTRICT NO. 6: x James Wahner, Chairman James M. Ferryman
xRuthelyn PI canner, rm ner, Chai pro tem —Evelyn Hart
won R. Roth _Roger Stanton
DISTRICT NO. 7: x Don E. Smith, Chairman Fred Barrera
=Richard Edgar. Chai nnan pro tem Ursula Kennedy
=Dan Griset _Dan Young
a Don R. Roth _Roger Stanton
a Sally Anne Sheridan Larry Agran
Donald A. Strauss =John C. Cox, Jr..
-7—James Wahner —Harry Green
DISTRICT NO. 11: x Tom Mays, Chairman _Jim Silva
rm=Grace Winchell, Chai man pro tem Wes Bannister
a Roger Stanton —Don R. Roth
DISTRICT 00. 13: x Henry W. Wades. Chai nnan _Roland E. Bigonger
=Iry Pickler, Chairman pro tem —RogerFred Hunter
a Don R. Roth _ Stanton
x Don E. Smith Fred Barrera
=Wayne Wedin _Ron Isles
DISTRICT NO. 14: x Peer A. Swan, Chairman _Darryl Miller
x Ursula Kennedy, Chairman pro tan Richard B. Edgar
a Don R. Roth _Roger Stanton
a Sally Anne Sheridan Larry Agran -
=Don E. Smith —Fred Barrera
-2-
09/13/89
STAFF MEMBERS PRESENT: J. Wayne Sylvester, General Manager,
Rita J. Brown, Board Secretary, Blake P.
Anderson, Thomas M. Dawes, Gary G. Streed,
Penny Kyle, Ed Hodges, Doug Hauser, John
Linder, Bob Ooten, Rich von Lang en, Jack
Vincent, Chuck Winsor
OTHERS PRESENT: Thomas L. Woodruff, General Counsel , Clark
Ids, Bill Clarke, Jamel Demir, Conrad
Hohener, Jr., Walt Howard, Bob Finn, Jim
Costello, Doug Montague, Cathy
Pfeiffenberger, Tom Richardson, Phil Stone
.v
DISTRICT 2 In the absence of Chairman William A.
Appointment of Chairman pro tem Mahoney and Chairman pro tem Ron Isles,
Director Iry Pickler was appointed
Chairman pro tem of District No. 2.
ALL DISTRICTS The Joint Chairman reported on the
Report of the Joint Chairman August 28th meeting with the
Environmental Protection Agency (EPA)
Region 9 officials in San Francisco to present the Districts' 112020 VISION"
Action Plan for Wastewater Management and officially file the application for
renewal of the Districts' NPDES Ocean Discharge Permit, as authorized and
directed by the Boards on July 19, 1989.
The Joint Chairman observed that it was a very positive meeting. Staff will
remain at EPA's disposal for any and all questions or concerns which they may
have during the process of reviewing the Districts' application.
Mr. Hoesterey then reported on the California Association of Sanitation Agencies'
(CASA) Annual Work Conference in San Diego in August which he attended along with
Directors John Cox, Richard Edgar, Bob Hanson, Richard Polis and Jim Wahner, the
General Manager, Wayne Sylvester, and General Counsel , Tom Woodruff. The Joint
Chairman commented on several of the topics discussed at the conference.
Chairman Hoesterey also advised that the Districts were a winner in the Annual
CASA Safety Contest for their innovative safety program.
The Joint Chairman then called a meeting of the Executive Committee for
Wednesday, September 27th, at 5:30 p.m. , and invited Director Wayne Wedin to
attend and participate in the discussions.
ALL DISTRICTS The Joint Chairman announced that he had
Board Committee Appointments completed the Board Committee
assignments and that a revised listing
of the members of the various Committees would be mailed to the Directors in a
few days.
ALL DISTRICTS The General Manager commented on the
Report of the General Manager meeting with EPA Region 9 officials in
San Francisco on August 28th, and called
the Directors' attention to the briefing booklet included in their meeting
folders which had been used at the meeting. Also included for the Directors' \.✓
information was the newly-printed summary brochure on the "2020 VISION" Action
-3-
09/13/89
Plan. Mr. Sylvester noted that the Districts had submitted a five-volume
application for renewal of the NPDES Permit. The application included a
suggested schedule in order for EPA to issue the new permit in February 1990,
when the current permit expires. EPA has Indicated that they will be unable to
meet the suggested schedule, but added that they would administratively extend
the Districts' current permit until they had reached a decision regarding the
renewal.
Mr. Sylvester then expressed appreciation to Don Fox, the Districts' Safety
Consultant, and Ray Young, Safety Coordinator, for their contributions and
efforts in connection with the safety award presented to the Districts by the
California Association of Sanitation Agencies (CASA).
The General Manager reported on a meeting in Washington, D.C. with new EPA
Administrator, William Reilly, on August 14th which he attended along with other
members of the Board of Directors of the Association of Metropolitan Sewerage
Agencies (AMSA). It was Administrator Reilly's first meeting with the wastewater
management community. EPA was urged to follow a scientifically supportable,
pragmatic course in setting their regulations. Mr. Sylvester briefly reviewed
the five key subjects focused on at the meeting, which included sludge management
regulations, emerging effluent toxicity testing regulations, national coastal
marine policy, the combined sewer overflow issue, and formation of a policy board
with broad representation from POTW'S, regulatory agencies and groups with
environmental , academic and scientific interests to address policy issues as they
emerge.
ALL DISTRICTS The General Counsel reported on the
Report of the General Counsel ordinances to be introduced later in the
meeting increasing connection charges in
each District. He noted that a paragraph was inadvertently omitted from
District 13's Ordinance relative to the existing provision providing that local
governmental agencies pay established connection fees. The General Counsel noted
that the ordinances are uniform for each District with the exception of that
provision in District 13's ordinance.
Mr. Woodruff then briefly reviewed the status of the Beatrice/Hunt-Wesson
litigation filed following their appeal to the Board relative to Industrial Waste
Permit No. 3-1-143.
DISTRICT 1 The General Counsel reported on a major
Authorizingeneral Counsel to violation of District No. 1's industrial
file lea actions against waste discharge ordinance by Universal
universalcircuits, Inc. No. 1 Circuits, Inc. No. 1. He indicated that
for non-can Hance with conditions the firm has been dumping illegal
of industrial Waste Discharge concentrations of regulated wastes into the
Permit No. 1-1-34 sewer in excess of discharge permit
limitations imposed by the District.
Mr. Woodruff further advised that the District has the option of filing a
criminal action in conjunction with the District Attorney or filing for civil
penalties. He recommended that the District file suit against Universal Circuits
for civil penalties for violating the conditions set forth in their discharge
permit.
It was then moved, seconded and duly carried:
�..✓ That the General Counsel be, and is hereby, authorized to file legal actions
against Universal Circuits, Inc. No. 1 for non-compliance with conditions of
Industrial Waste Discharge Permit No. 1-1-346 issued to said firm.
-4-
09/13/89
DISTRICT 1 There being no corrections or amendments
Approval of Minutes to the minutes of the adjourned regular
meeting held July 19, 1989, nor the regular
meeting held August 9, 1989, the Chairman ordered that said minutes be deemed �.,✓
approved, as mailed.
DISTRICT 2 There being no corrections or amendments
Approval of Minutes to the minutes of the adjourned regular
meeting held July 19, 1989, nor the regular
meeting held August 9, 1989, the Chairman ordered that said minutes be deemed
approved, as mailed. _
DISTRICT 3 There being no corrections or amendments
Approval of Minutes to the minutes of the adjourned regular
meeting held July 19, 1989, nor the regular
meeting held August 9, 1989, the Chairman ordered that said minutes be deemed
approved, as mailed.
DISTRICT 5 There being no corrections or amendments
Approval of Minutes to the minutes of the adjourned regular
meeting held July 19, 1989, nor the regular
meeting held August 9, 1989, the Chairman ordered that said minutes be deemed
approved, as mailed.
DISTRICT 6 There being no corrections or amendments
Approval of Minutes to the minutes of the adjourned regular
meeting held July 19, 1989, nor the regular
meeting held August 9, 1989, the Chairman ordered that said minutes be deemed
approved, as mailed.
DISTRICT 7 There being no corrections or amendments
Approval of Minutes to the minutes of the adjourned regular
meeting held July 19, 1989, nor the regular
meeting held August 9, 1989, the Chairman ordered that said minutes be deemed
approved, as mailed.
DISTRICT 11 There being no corrections or amendments
Approval of Minutes to the minutes of the adjourned regular
meeting held July 19, 1989, nor the regular
meeting held August 9, 1989, the Chairman ordered that said minutes be deemed
approved, as mailed.
DISTRICT 13 There being no corrections or amendments
Approval of Minutes to the minutes of the adjourned regular
meeting held July 19, 1989, nor the regular
meeting held August 9, 1989, the Chairman ordered that said minutes be deemed
approved, as mailed.
DISTRICT 14 There being no corrections or amendments
pproval of minutes to the minutes of the adjourned regular
meeting held July 19, 1989, nor the regular
meeting held August 9, 1989, the Chairman ordered that said minutes be deemed
approved, as mailed.
dad
-5-
09/13/89
ALL DISTRICTS Moved, seconded and duly carried:
Ratification of a ent of Joint
and Individual District laims That payment of Joint and individual
1./ District claims set forth on pages "A", "B"
and "C" attached hereto and made a part of these minutes, and summarized below,
be, and are hereby, ratified by the respective Boards in the amounts so
indicated.
8/02/89 8/16/89 8/30/89
ALL DISTRICTS
Joint Operating Fund - $ 961,259.72 $ 570,219.53 $ 965,636.18
Capital Outlay Revolving Fund - 4,112,640.77 406,086.32 3,092,224.63
Joint Working Capital Fund - 398,771.57 157,734.08 186,806.97
Self-Funded Insurance Funds - -0- -0- 13,434.69
DISTRICT NO. 1 - 3.37 21,078.81 83.92
STRICT NO. 2 - 640,574.13 49,484.57 938,100.09
DISTRICT - 634,786.11 65,946.34 373,272.28
DISTRICT NO. 5 - 93,591.78 14,787.27 13,883.24
DISTRICT NO. 6 - 4,910.68 18,952.45 123.59
DIDI TR�.-5 - 57,214.95 15,789.26 10,467.62
DI TRI— C�1 - 5,461.67 93,176.69 19,803.52
DISTRICT NO. 13 - -0- 2,463.01 -0-
DISTRICT NO. 14 - 24,984.92 18.17 8,275.46
DISTRICTS & 6 JOINT - 7,373.55 4,918.78 11,091.12
DISTRICTS NOS. 6 & 7 JOINT - 35.35 3,057.36 35.88
DISTRICTS NOS. 7 & 14 J INT 3,797.29 1,757.69 3,508.47
$��J33-ZFM 1, ,4 5, ,747.6
ALL DISTRICTS Moved, seconded and duly carried:
Approving Change Order No. it o
the tans and s ecifications for That Change Order No. 11 to the plans
Job o. J-7-4 and specifications for Administration
Building Addition, Job No. J-7-4,
authorizing an addition of $26,454.00 to the contract with J. R. Roberts
Corporation for four items of additional work including installation of fire
protection equipment required by the City of Fountain Valley, the addition of a
chilled water expansion tank and piping, additional hot water heater wiring and
PVC liner at a manhole connection, and granting a time extension of three calendar
days for completion of said additional work, be, and is hereby, approved.
ALL DISTRICTS Moved, seconded and duly carried:
Approving Change Order No. 19 to
the plans and specifications far That Change Order No. 19 to the plans
Job No. J-15 and specifications for Ocean outfall
Booster Station "C" at Plant No. 2, Job
No. J-15, authorizing an addition of $6,966.00 to the contract with Advanco
Constructors, Inc. for four items of additional work including modifications to.
the elevator to comply with State Division of Industrial Safety requirements,
installation of condensate traps for roof-mounted heat pumps, modification of the
perimeter walls and the ceiling of the lunch/meeting room and installation of an
ultrasonic sensor device in the junction structure to enhance water level control
capabilities, be, and is hereby, approved.
-6-
09/13/89
ALL DISTRICTS Moved, seconded and duly carried:
pproyi ng hange rder No. to the
lansvan s ecifica ons for That Change Order No. 3 to the plans and
Job NO. J-ZU specifications for Warehouse and �..�
Maintenance Building, and Oil Storage
and Dispensing Improvements, Job No. J-20, authorizing an addition of $37,507.00
to the contract with J. R. Roberts Corporation for three items of additional work
including substitution of fluorescent light fixtures in Buildings 5 and 6,
rerouting water lines around and under Buildings 1, 4 and 8, and modifications to
the area fire protection water system; and granting a time extension of 14
calendar days for completion of said additional work, be, and is hereby, approved.ALL DISTRICTS Moved, seconded and duly carried:
Approving change order No. 21 to
the Tans and s eclficati ons for That Change Order No. 21 to the plans
Job os. PS- and P1-31 ana specifications for Headworks No. 2
at Plant No. 1, Job No. P1-20, and
Demolition of Digesters Nos. 1, 2 and 4; Replacement of Boiler; Piping Cleanouts;
and Grading and Paving at Plant No. 1, Job No. P1-31, authorizing an addition of
$51,591.98 to the contract with Kiewit Pacific Co. for seven items of additional
work including relocation of pH sensors, modifications to the bulk chlorine
facility, bubbler tubing modifications at the barscreens, additional pumps and
piping to increase capacity for temporary bypassing of peak flows in the
District 6 trunk junction box "A% modification of sluice gate supports, polymer
facility modifications and piping modifications in the foul air and chemical
handling facility, be, and is hereby, approved.
ALL DISTRICTS Moved, seconded and duly carried:
Aut ch
orizing the ene ral Manager to
issue a urase order to Sierra That the General Manager be, and is
Environmental En nee Ing, Inc. for hereby, authorized to issue a purchase
sampling and analytical services order to Sierra Environmental
required by SCAQMD in connection Engineering, Inc. in an amount not to
with construction permit for exceed $104,458.00 for sampling and
Jo No. P1-33 analytical services necessary to conduct
a scrubber pilot plant study for the VOC
reduction demonstration project to determine best available control technology
required by SCAQMD in connection with the Permit to Construct Primary Clarifiers
Nos. 6-15 and Related Facilities at Reclamation Plant No. 1, Job No. PI-33.
ALL DISTRICTS Moved, seconded and duly carried:
A rovin agreement with Orange -
aunty Water District to include That the Boards of Directors hereby
construction of a Water District adopt Resolution No. 89-124, approving
secondary effluent supply force agreement with the Orange County Water
main in Districts' project re District to include construction of a
So 0. P1-33 Water District secondary effluent supply
force main in Districts' project re
Primary Clarifiers Nos. 6-15 and Related Facilities at Reclamation Plant No. 1,
Job No. P1-33, to accommodate an anticipated increase in demand for reclaimed
water; and providing for reimbursement to the Districts for OCWD's share of the
costs for said work. A certified copy of this resolution is attached hereto and
made a part of these minutes. 1
gar/
-7-
09/13/89
ALL DISTRICTS Moved, seconded and duly carried:
Approving Addendum No. 1 to the
Professional Services Agreement That the Boards of Directors hereby
With Carol lo-Bo le A Joint Venture, adopt Resolution No. 89-125, approving
for preparation of he Collection, Addendum No. 1 to the Professional
Treatment and Disposal Facilites Services Agreement with Carollo-Boyle, a
Master Plan Joint Venture, for preparation of the
Collection, Treatment and Disposal
Facilities Master Plan, providing for a reallocation of the costs among
categories within said agreement, with no change in the maximum authorized
compensation of $2,099,162.00. A certified copy of this resolution is
attached hereto and made a part of these minutes.
ALL DISTRICTS Moved, seconded and duly carried:
A rovin ddendum o. 3 to the
rofessianal Services A reement That the Selection Committee
with Malcolm Pirnie, Inc. for certification of the final negotiated
design and construction services fee relative to Addendum No. 3 to the
re aired for Jab Nos. P1-25 P1-26 Professional Services Agreement with
P2-32, P - and P2- 4 Malcolm Pirnie, Inc. for design and
construction services required for
Covers for Primary Basins at Plant No. 1, Job No. P1-25; Foul Air Scrubber
System at Plant No. 1, Job No. P1-26; Covers for Primary Basins at Plant
No. 2, Jab No. P2-32; Foul Air Scrubber System at Plant No. 2, Job No. P2-33;
and Improvements to Grit Facility "811, Billings Tunnel and Distribution
Structure "A", Job No. P2-34, providing for additional operator training on
the scrubber systems, be, and is hereby, received, ordered filed and approved;
and,
FURTHER MOVED: That the Boards of Directors hereby adopt Resolution
No. 89-126, approving Addendum No. 3 to said Agreement with Malcolm Pirnie,
Inc. for said services, on an hourly-rate basis for labor plus overhead, plus
direct expenses, including profit, for an additional amount not to exceed
$24,500.00, increasing the total authorized compensation from $868,208.00 to
an amount not to exceed $892,708.00. A certified copy of this resolution is
attached hereto and made a part of these minutes.
ALL DISTRICTS Moved, seconded and duly carried:
Authorizin the Se ection omnit ee
to negotiate Atl e%um No. 5 o the That the Selection Committee be, and is
Profes�ervices A re nteme hereby, authorized to negotiate Addendum
with Brown and Caldwell ConsuIting No. 5 to the Professional Services
fnineers for design of Job No. - 9 Agreement with Brown and Caldwell
Consulting Engineers for design of
Central Power Generation Systems, Job No. J-19, to provide for design of
digester hot water loops for the systems at both plants; design modifications
to gas system at Digesters A and B; and design of backup cooling water source
for the new Ocean Outfall Booster Station at Plant No. 2.
ALL DISTRICTS
Actions re Job Nos. P1-
P -31, P - 3 and P2-34
Receive and file Staff Re lort re Moved, seconded and duly carried:
Safety Modifications to Circular
Clarifier walkways at Plant No. 2 That the Staff Report dated
August 28, 1989 re Safety
Modifications to Circular Clarifier Walkways at Plant No. 2, be, and is
hereby, received and ordered filed.
-8-
09/13/89
A rovin Chan a Order No. 18 to Following a report by the Director of
he ans and specifications for Engineering on the proposed change
J00 Nos. P1-25 1- 6 P2-31 P2-33 order to the plans and specifications
and P - 4 for Job Nos. P1-25, P1-26, P2-31, �✓
P2-33 and P2-34, it was moved,
seconded and duly carried:
That Change Order No. 18 to the plans and specifications for Covers for
Primary Basins at Plant No. 1, Job No. P1-25; Foul Air Scrubber System at
Plant No. 1, Job No. P1-26; Covers for Primary Basins at Plant No. 2, Job
No. P2-32; Foul Air Scrubber System at Plant No. 2, Job No. P2-33; and
Improvements to Grit Facility "B", Billings Tunnel and Distribution
Structure "A", Job No. P2-34, authorizing an addition of $441,048.79 to the
contract with Advanco Constructors, Inc. for modification of gunite
walkways and beams, handrail and elevated structural aluminum walkways at
Primary Clarifiers H, I, J, K, L, M, N, 0, P and Q at Plant No. 2 to comply
with OSHA requirements; and granting a time extension of 30 calendar days to
complete the additional work, be, and is hereby, approved.
ALL DISTRICTS Moved, seconded and duly carried:
v rRece e an e
es a shment of fees and That the Staff Report dated August 28,
miscellaneous char es re use of a 1989 re establishment of source control
District sewerage facil ties fees, administrative fees and
miscellaneous charges relating to the
use of the District sewerage facilities, be, and is hereby, approved.
ALL DISTRICTS Moved, seconded and duly carried:
Establishinq source control ees,
adman strative fees an That the Boards of Directors hereby
miscellaneous char es re use of t e adopt the following resolutions,
District sewerage facilit es establishing source control fees,
administrative fees and miscellaneous
charges relating to the use of the District sewerage facilities effective
September 9, 1989:
District Resolution No.
1 89-127-1
2 89-128-2
3 89-129-3
5 89-130-5 _
6 89-131-6
7 89-132-7
11 89-133-11
13 89-134-13
14 89-135-14
Certified copies of these resolutions are attached hereto and made a part of
these minutes.
�d
-9-
09/13/89
DISTRICTS 1 2, 3, 5 6 7, 11 8 13
Actions re introduction of propose
ordinances increasin sewer
connection charges
Receive and file Staff Report Moved, seconded and duly carried:
That the Staff Report dated August 28, 1989 re proposed ordinances
increasing sewer connection charges, be, and is hereby, received and
ordered filed.
DISTRICT 1
First reading oP Proposed Moved, seconded and duly carried:
Ordinance NO. 114
That proposed Ordinance No. 114,
An Ordinance of the Board of Directors of County Sanitation District
No. 1 of Orange County, California, Amending Ordinance No. 113
Establishing Wastewater Discharge Regulations for Use of District
Sewerage Facilities, be read by title only; and,
FURTHER MOVED: That reading of said ordinance in its entirety be, and
is hereby, waived.
Following the' reading of Ordinance No. 114 by title only, it was moved,
seconded and duly carried:
That Ordinance No. 114, An Ordinance of the Board of Directors of
County Sanitation District No. 1 of Orange County, California, Amending
Ordinance No. 113 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be introduced and passed to second
reading and public hearing on October 11, 1989, at 7:30 p.m. , at the
District's administrative office.
DISRICT 2
First E22%2 of Proposed Moved, seconded and duly carried:
rdinance 0. 20
That proposed Ordinance No. 209,
An Ordinance of the Board of Directors of County Sanitation District
No. 2 of Orange County, California, Amending Ordinance No. 208
Establishing Wastewater Discharge Regulations for Use of District
Sewerage Facilities, be read by title only; and,
FURTHER MOVED: That reading of said ordinance in its entirety be, and
is hereby, waived.
Following the reading of Ordinance No. 209 by title only, it was moved,
seconded and duly carried:
That Ordinance No. 209, An Ordinance of the Board of Directors of
County Sanitation District No. 2 of Orange County, California, Amending
Ordinance No. 208 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be introduced and passed to second
reading and public hearing on October 11, 1989, at 7:30 p.m. , at the
District's administrative office.
-10-
09/13/89
DISTRICT 3
First readin Of Pro osed Moved, seconded and duly carried:
rdinance No. 12
That proposed Ordinance No. 312,
An Ordinance of the Board of Directors of County Sanitation District
No. 3 of Orange County, California, Amending Ordinance No. 311
Establishing Wastewater Discharge Regulations for Use of District
Sewerage Facilities, be read by title only; and,
FURTHER MOVED: That reading of said ordinance in its entirety be, and
is hereby, waived.
Following the reading of Ordinance No. 312 by title only, it was moved,
seconded and duly carried:
That Ordinance No. 312, An Ordinance of the Board of Directors of
County Sanitation District No. 3 of Orange County, California, Amending
Ordinance No. 311 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be introduced and passed to second
reading and public hearing on October 11, 1989, at 7:30 p.m. , at the
District's administrative office.
DISTRICT 5
First reading of Proposed Moved, seconded and duly carried:
Ordinance No. bZ1
That proposed Ordinance No. 521,
An Ordinance of the Board of Directors of County Sanitation District
No. 5 of Orange County, California, Amending Ordinance No. 520
Establishing Wastewater Discharge Regulations for Use of District
Sewerage Facilities, be read by title only; and,
FURTHER MOVED: That reading of said ordinance in its entirety be, and
is hereby, waived.
Following the reading of Ordinance No. 521 by title only, it was moved,
seconded and duly carried:
That Ordinance No. 521, An Ordinance of the Board of Directors of
County Sanitation District No. 5 of Orange County, California, Amending
Ordinance No. 520 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be introduced and passed to second
reading and public hearing on October 11, 1989, at 7:30 p.m. , at the
District's administrative office.
DISTRICT 6
First readin? of Proposed Moved, seconded and duly carried:
Ordinance N0. 615
That proposed Ordinance No. 615,
An Ordinance of the Board of Directors of County Sanitation District
No. 6 of Orange County, California, Amending Ordinance No. 614
Establishing Wastewater Discharge Regulations for Use of District
Sewerage Facilities, be read by title only; and,
FURTHER MOVED: That reading of said ordinance in its entirety be, and
is hereby, waived.
-11-
09/13/89
Following the reading of Ordinance No. 615 by title only, it was moved,
seconded and duly carried:
..,/ That Ordinance No. 615, An Ordinance of the Board of Directors of
County Sanitation District No. 6 of Orange County, California, Amending
Ordinance No. 615 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be introduced and passed to second
reading and public hearing on October 11, 1989, at 7:30 p.m., at the
District's administrative office.
DISTRICT 7
irst readin
g o Proposed Moved, seconded and duly carried:
Ordinance No. 723
That proposed Ordinance No. 723,
An Ordinance of the Board of Directors of County Sanitation District
No. 7 of Orange County, California, Amending Ordinance No. 722
Establishing Wastewater Discharge Regulations for Use of District '
Sewerage Facilities, be read by title only; and,
FURTHER MOVED: That reading of said ordinance in its entirety be, and
is hereby, waived.
Following the reading of Ordinance No. 723 by title only, it was moved,
seconded and duly carried:
That Ordinance No. 723, An Ordinance of the Board of Directors of
County Sanitation District No. 7 of Orange County, California, Amending
Ordinance No. 722 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be introduced and passed to second
reading and public hearing on October 11, 1989, at 7:30 p.m. , at the
District's administrative office.
DISTRICT 11
First reading of Proposed Moved, seconded and duly carried:
Ordinance No. 1111
That proposed Ordinance No. 1111,
An Ordinance of the Board of Directors of County Sanitation District
No. 11 of Orange County, California, Amending Ordinance No. 1110
Establishing Wastewater Discharge Regulations for Use of District
Sewerage Facilities, be read by title only; and,
FURTHER MOVED: That reading of said ordinance in its entirety be, and
is hereby, waived.
Following the reading of Ordinance No. 1111 by title only, it was
moved, seconded and duly carried:
That Ordinance No. 1111, An Ordinance of the Board of Directors of
County Sanitation District No. 11 of Orange County, California,
Amending Ordinance No. 1110 Establishing Wastewater Discharge
Regulations for Use of District Sewerage Facilities, be introduced and
passed to second reading and public hearing on October 11, 1989, at
7:30 p.m. , at the District's administrative office.
-12-
09/13/89
DISTRICT 13
t ons re proposed ordinance
o. 130
Amendln ro osed Ordinance 1306 During the Directors' discussion
o inc u e rov s on Tor cnarging of the formula used in computing
connection fees to local connection fees, it was clarified
governmental agent es that the formula provides for the
recovery of the cost of facilities
and that replacement costs are deducted in calculating the fees.
Also discussed were reasons the Board previously those to make
connection fees applicable to local governmental agencies. In 1988
the Board included a provision in the District 13 ordinance to assess
local government agencies for connection fees in order to assure that
the cost of providing sewage service to large governmental
installations would be borne by those requiring sewage system
capacity and not the residents and businesses of District 13.
Federal and State installations pay connection fees in all Districts.
Directors discussed the possibility of exempting a particular type of
government facility and/or assessing connection fees only to
facilities exceeding a certain size. The General Counsel pointed out
that the connection fees must be equitable and that there must be
justification for different rates or applications.
Following further discussion, it was moved, seconded and duly
carried:
That proposed Ordinance No. 1306, An Ordinance of the Board of
Directors of County Sanitation District No. 13 of Orange County,
California, Amending Ordinance No. 1305 Establishing Wastewater
Discharge Regulations for Use of District Sewerage Facilities, be
amended to include the existing provision for charging connection
fees to local governmental agencies; and,
FURTHER MOVED: That staff and General Counsel be directed to prepare
a report on this matter for the Directors prior to the hearing and
second reading of the ordinance on October Ilth.
First rea of Pro osed Moved, seconded and duly carried:
Or nancdino.e , as amen ed
That proposed Ordinance No. 1306,
An Ordinance of the Board of Directors of County Sanitation District
No. 13 of Orange County, California, Amending Ordinance No. 1305
Establishing Wastewater Discharge Regulations for Use of District
Sewerage Facilities, as amended, be read by title only; and,
FURTHER MOVED: That reading of said ordinance in its entirety be,
and is hereby, waived.
Following the reading of Ordinance No. 1306 by title only, it was
moved, seconded and duly carried:
That Ordinance No. 1306, An Ordinance of the Board of Directors of
County Sanitation District No. 13 of Orange County, California,
Amending Ordinance No. 1305 Establishing Wastewater Discharge
Regulations for Use of District Sewerage Facilities, as amended, be
Introduced and passed to second reading and public hearing on
October 11, 1989, at 7:30 p.m. , at the District's administrative
office.
-13-
09/13/89
DISTRICT 1 Moved, seconded and duly carried:
d oournment
That this meeting of the Board of
�./ Directors of County Sanitation District No. I be adjourned. The Chairman then
declared the meeting so adjourned at 8:15 p.m. , September 13, 1989.
DISTRICT 2 Moved, seconded and duly carried:
zin he action committee
e oattASeum No. Z to the That the Selection Committee be, and is
Profess ono ery ces reement hereby, authorized to solicit a proposal
wit Willdan Associates for desi n and negotiate Addendum No. 2 to the
of Contract Nos. 2- -2 and 2-27 Professional Services Agreement with
Willdan Associates for design of Portion
of Euclid Interceptor Sewer, between Edinger Avenue and Lampson Avenue,
Contract No. 2-26-2, and South Anaheim Relief Sewer, Contract No. 2-27, to
provide for additional design services required due to changes in construction
sequencing, modifications to traffic control requirements of the City of Santa
Ana, and additional surveys to establish pavement elevations requested by the
City of Santa Ana.
DISTRICT 2 Moved, seconded and duly carried:
Aut or z n e Se ection Comm ttee
to negotiate Addendum No. 1 to the That the Selection Committee be, and is
Professional Services Agreement hereby, authorized to solicit a proposal
Wit Willdan Associates for des n and negotiate Addendum No. 1 to the
of Contract Nos. -2 -3 and - Professional Services Agreement for
design of Portion of Euclid Interceptor
Sewer, between Broadway and Orangethorpe Avenue, Contract No. 2-26-3, and
Katella Relief Sewer, between Euclid Street and Walnut Street, Contract
No. 2-28, to provide for additional design services required due to changes
requested by the City of Fullerton, and design services necessary in order to
provide for the abandonment of a section of the sewer in Euclid Street in the
City of Garden Grove known as the Euclid Purchase Sewer.
DISTRICT 2 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 2 be adjourned. The Chairman then
declared the meeting so adjourned at 8:15 p.m. , September 13, 1989.
DISTRICT 3 Moved, seconded and duly carried:
rov n ham a rder No. 7 to the
lams and s ecif ca ons Tor That Change Order No. 7 to the plans and
Contract No. - R-1 specifications for Miller-Holder Trunk
Sewer Manhole (Vault) Rehabilitation at
Various Locations, Contract No. 3-28R-1, authorizing an addition of $12,500.00 to
the contract with Mladen Buntich Construction Company for payment of
contract-specified bonus for early completion of a certain manhole to minimize
safety hazards and traffic disruption, be, and is hereby, approved.
DISTRICT 3 Moved, seconded and duly carried:
A_d ournment
That this meeting of the Board of
Directors of County Sanitation District No. 3 be adjourned. The Chairman then
declared the meeting so adjourned at 8:15 p.m. , September 13, 1989.
-14-
09/13/89
DISTRICT 5 Moved, seconded and duly carried:
ADorovinq Addendum No. I to the
Professional Services greement That the Selection Committee
wi�he Keith Companies for design certification of the final negotiated
and construction services required fee relative to Addendum No. 1 to the
for Contract NOS. 5-35 and 5-ib Professional Services Agreement with The
Keith Companies for design and
construction services required for the South Coast Trunk Sewer, Contract No. 5-35,
and the Crystal Cove Pump Station, Contract No. 5-36, providing for changes in the
scope of work initiated by The Irvine Company, City of Newport Beach and Laguna
Beach County Water District re project alignment in Pacific Coast Highway and the
construction schedules for said projects, be, and is hereby, received, ordered
filed and approved; and,
FURTHER MOVED: That the Board of Directors hereby adopts Resolution No. 89-136-5, approving Addendum No. 1 to said Agreement with The Keith Companies
for said services, on an hourly-rate basis for labor, including overhead and
fixed profit, plus subconsultant fees, for an additional amount not to exceed
$36,890.00, increasing the total authorized compensation from $124,360.00 to an
amount not to exceed $161,250.00. A certified copy of this resolution is
attached hereto and made a part of these minutes.
DISTRICT 5 Moved, seconded and duly carried:
Receive, file and deny claim of
Frans Weterrings That the claim of Frans Weterrings dated
August 7, 1989, in the amount of $277.90
for damage to his vehicle allegedly caused by an open manhole in the vicinity of
Pacific Coast Highway and Riverside Drive, be, and is hereby, received, ordered
filed and denied; and,
FURTHER MOVED: That said claim be, and is hereby, referred to the District's
General Counsel and liability claims administrator for appropriate action.
DISTRICT 5 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 5 be adjourned. The Chairman then
declared the meeting so adjourned at 8:15 p.m., September 13, 1989.
DISTRICT 6 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of '
Directors of County Sanitation District No. 5 be adjourned. The Chairman then
declared the meeting so adjourned at 8:15 p.m. , September 13, 1989.
DISTRICT 7 Moved, seconded and duly carried: '
Receive and file request for
annexation and authorizing That the petition from Penny Chartier,
initiation of roceedin s re et al . requesting annexation of 3.079
proposed Annexation o. 1 acres of territory to the District, in
Chartier Annexation the vicinity east of the intersection of
Orange Park Boulevard and Meads Avenue
in unincorporated County territory, be, and is hereby, received and ordered filed;
and,
FURTHER MOVED: That the Board of Directors hereby adopts Resolution
No. 89-137-7, authorizing initiation of proceedings to annex said territory to
the District, proposed Annexation No. 130 - Chartier Annexation to County
Sanitation District No. 7. A certified copy of this resolution is attached
hereto and made a part of these minutes.
-15-
09/13/89
DISTRICT 7 Moved, seconded and duly carried:
�../ Ad ournment
That this meeting of the Board of
Directors of County Sanitation District No. 7 be adjourned. The Chairman then
declared the meeting so adjourned at 8:15 p.m. , September 13, 1989.
DISTRICT 11 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 11 be adjourned. The Chairman then
declared the meeting so adjourned at 8:15 p.m. , September 13, 1989.
DISTRICT 13 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 13 be adjourned. The Chairman then
declared the meeting so adjourned at 8:15 p.m. , September 13, 1989.
DISTRICT 14 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 14 be adjourned. The Chairman then
declared the meeting so adjourned at 8:15 p.m. , September 13, 1989.
becretary of he Boards of Directors
of County Sanitation Districts
Nos. 1, 2, 3, 5, 6, 7, 11, 13 and 14
-16-
FUND MO 9149 - JT DIST WORKING CAPITAL PROCESSING DATE 7/26189 PAGE I
REPORT NUMBER AP43
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY
ANS--f A10 08 1.32/E9-P06FE N6-OATI. Do/a2;69-.__.
WARRANT NO. VENDOR AMOUNT DESCRIPTION
IOl00P ABC FAINT STRIPING SERVICE 15.220.3. ROAD RESTRIPING SERVICES
301f09 AT t T f929.7f LONG DISTANCE TELEPHONE
350.30.. CONFERENCE REGISTRATION --._-._ - -
- 101012 LINCOLP CF RESIDUALS INTERIORS
t$65.30 CARPET REP REGISTRATION
101012 ADVANCN CARPETS t INTER70R5 f66.50 CARPET REPAIR
1 __.AOVANCO CONSTRUCTORS,
-__ _-. ..__ _._H62.87 .__ __IONSTRUCTIONBPI-2 .-----_-_
101019 ADVANCO CONSTRUCTORS. INC. f9109381.60 CONSTRUCTION P1-25.26,P2-7],39
LPICIS AFRO TECH SURVEYS. INC. t3B1.60 MAPS
-10.2,17 __-_-AIR R-ACCESS"IES-W --F. - - 4G.8{._.._. -_ .---PU
101C17 AIR POLLUTION CONTROL ASSN. 195.80 PUBLICATION
- IOIC18 AIR PRODUCTS t CHEMICAL INC. f968.37 ACETYLHE TESTING
_-----101619----AL"ABOSCOFF-.--. -- -. -.540.47 ._ MECHANICAL
101020 AMERI INC. t/OP AMERICAN SEALS 12.090.69 MECHANICAL SUPPLIEb
- 101021 AMERITE CM f92.0G COPIeR LEASES
0102g____.SLAKE)P.RENDERSONSTJLOLI.ON $1,049.�1a4MEETVATA01i USES
101024 BLAME R. AWIRE LN 53.009.19 CABLING E%PENSES
101029 ANIXTER - WIRE t CABLE t1.SOS.77 CABLE
101326______ARATEV SERVICES.
_.-.-.--. _-519121.92- ._._..._,_-. _ ...UNIFORM
MVERT£G£llf,
101026 ARETEX INDUSTRIES
INC. $886.11 ONIPDPM RENTALS
103027 AREBS INDUSTRIES INC. f886.11 DRYCEH PARTS
x- -IGTHE AVl7E0-SOUS-ENOINEERiLS------f$2,524..00- - _ ...._... ..___.. MECHANICAL
STING
= 101089 THE AVEBUNY GROUP 32.S29.BS MECHANICAL PARTS
H-. 101030 AYAR DSt DEVELOPMENT
352.5B SERVICB pupRDS
E-_DISPOSAL SERVICE
_.._-.. __._ __.. _7S.694.09 _ ... .BIG-CANYON-ABPUN.7-13-^..�.,.�
1R1032 FALCON BLUE DISPOSAL SERVICE f$1,573.74 GRIT RENTING M.O.J-13-88
1 C1033 BANANA BLUE PRINT fLS73.H BLUEPRINTING
BARR DOOR OF
C $117.D0. -BUIUIUGFIOPAIRS G86-P2=�3. 4{v}--.__-._
101036 BARR ODOR Of T. INC.ANGE CTY♦INC $566.27 BUILDING REPAIRS
101936 BATTERIES WEST. I 068.59 LAB-SEIES
- -- --141C37�--.- -BA%TFR_SC TENT IF-IF RR000FT8 --- - -- 35.868.59 - -� - � - -- - LAB-6UPPL£ES ------_ - -
IC1030 BELL t NOWELL CO. 3179.CG PRINTER REPAIRS
101039 PEN2 ENGINEERING. INC. $272.64 MECHANICAL PARTS
--101G9�---.JO1SE-LASCAGE-0RFICS-FAOIYGib- _..__ 51�464.62 - -- - - -.--GFfiCE-SIWP6£PB ----- -
101091 BOLSA RADIATOR SERVICE t202.68 RADIATOR REPAIR
101092 BOYLE ENGINEERING CORP 528.730.59 ENGINEERING SERVICES 7-11
'L._... ___101015 _ - __._..BROWN-t CALDWELL-----. ._ .. .. - - .- _.. . .--f6P0.00 ._--LAB-SERVIG65-
101099 BROWN t CALDWELL CONSULTING 5390.30B.^.9 ENGINEERING SERVICES J-19
101045 BURKE ENGINEERING CO. 5218.69 ELECTRIC SUPPLIES
-- 444446 -0444-6.-$i EED-
101097 BY-FRODUCTS MANAGEMENT. INC. $40.034.69 FERROUS CHLORIDE N.O. 4-12-89
- 201048 C S A RECONDITIONING CO. $1,306A0 MECHANICAL PARTS
---- 101499- - -- - CAL-GLASS FOR- RESEARCH.-INC. -- - _. --5132.16 -LA9-SUPPLIEb-- --- ------ -
101050 CAL TYPE OFFICE KACMINES. INC. t1.64J.7} MAINTENANCE CONTRACT
I01051 JOHN A. CALAPRICE. POO f7Q10.00 CONSULTING SERVICES
_..... __40.1462---_. . _CA4.I1O44I4-80RESSI-ON SYSTEMS---....-.-, .._ _. -S6O0.OJ
101053 JOHN CAROLLO ENGINEERS S253r896.30 ENGINEERING SERVICES 11-17,PI-20
FUND NO 9191 - JT DIST WORUNG CAPITAL FROCESSING DATE 7/26/89 PAGE 2
REPORT NUMBER AP43
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY
___...___._..._._.._.__. .__. .-_ --CLAIN"A30-.B8102%B9--POSi-IN6..DATC-JR/6P/34._.-. _...
WARRANT NO. VENDOR AMOUNT DESCRIPTION
• 1O1054 CHCMWEST INDUSTRIES, INC. 372.794.0C FERRIC CHLORIDE M.O.LI-09-88
IP1C55 CHEVRON U.S.A.♦ INC. $8.272.13 UNLEADED GASOLINE
-COASSON_8-CEQUIPM 32,901.5P
2,901 - - -----FNGLNSBRINC-EBRIYC86 -
IVID57 COAST FIRE EQUIPMENT 52.$20.00 PIA¢ EQUIPMENT INSPECTION
IP1038 COASTAL VIDEO COMMUNICATION S20.00 VIDEOS
1SOR-COMPONENTS
OMPONENT COMPRESSOR,-PARTS -_..-__
191062 COMPRESSOR CDMPO NE NTS OF CALIF 32 d31.21 MECHANICAI, PARTS
193061 COMPUSF RVE $S1,21 COMPUTER SERVICES
__101062---.--CONSOLIDATE.-PARESRICAL D---_-__- TIC PA ._-...
101964 CONSOLIDATED REPROGRAPHICS
DIST. $6.086.95 BLEC7RIC PARES
101469 CONSOLIDATED REV R06P APNILS S13.588.17 BLUEPRINTING
!`--101065 ._.___CONESNCNIAMGRAPWyf-_.__.____.__-..__ti.i91.33 . . --. .- ..-PRINTINGNTLPAPRINTiNG-If.0.b-14-89---__._..
IOIC47 COSTA OLEO i91.35 INSTRUMENT PARTS
101 CE7 COSTA MESA AUTO SUPPLY 5135.39 TRUCE PARTS
_ —19106B-.__...__CAL WA-EN012SALf--[L ECTRI-0.—......__..�__.. _-_i$45.00 -. ... - .. ._-RENTALICQUOPPL88S-
191069 CAL WATER 301.79 RENTAL EQUIPMENT
301770 STATE OF CALIFORNIA t301.T9 DI¢S¢L USE TAR
INN---100110077i2 --DECO -1972..2381 ELECTRIC SUPPLIES
--_
m 171073 DE 6UELLE S SONS GLASS CO. 32,901.60 CLASS
X---ICID7A- DESIGN MODELS IRANSFOPSA.TJO/1------..-826i.06J.0C ___...CTONAGE TI(RYJ-22d
= 1C3076 DESIGN MODELS INC. ,352.42 VALVE
101076 OE2UPIN AND/OR CS CO. f352.92 VALVE
--1 P1-077----___ __.8/sift-.POIiNEP4___..__.-_.____-fil-H98.P9 - - -- --ANIONIC
-1 ICID78 DIFILIFPO ASSOCIATES t3C2.1C PRINTING
101079 DIGITAL EOUIPMENT CORP. S395.60 SERVICE AGREEMENT
Y 101-0BO--.--- -----C ORADO-EN7EPP p.15LS.-Wf - -----------33s678.38 --- VALV5-REPAIRS---- ._. . _
N
101D81 DUNN EDWARDS CORD, $11.322.50 PAINT SUPPLIES
101082 EIMCO PROCESS EOUI►. CO. t995.00 MECHANICAL PARTS
._-_...EA$TN AN,-INC..---.-_.____..._.-__...... _.__.__.._. ._8.1J9.94 _ .__._OPFiCE-SUPPLIES -. -_-
101089 V. H. EBERT CORP. $623,665.96 CONSTRUCTION 2-27
101005 EFFECTIVE VISUAL IMAGFPY 5580.6E TRAINING
.-.__.-..ENCHANT-ER,-INCr-_...__. .-.__ _._ _. __....__ _ 5 ,20Q.OP _..._ .__.--0CBAN-6ANPLINFlhOr
l Ol OB7 JAMES FALCONER $975.01 PROFESSIONAL SERVICES
101088 -JOHN S. FALNENSTEIN P.C. S3.360.00 CONSTRUCTION SERVICES J-20. J-7-4
1031089 - -__.FARE SALES- &.SERVICE- t8,112.31 - - - - --ELECTRIC-SUPPLIES- . ---- -
ID1090 FEDERAL EXPRESS CORE. $120.25 AIR FREIGHT
101092 FERPELL64S i19.50 PROPANE
S3y490.51 _ ._ _- _ _-CNLOR£NAT-lON-EQV£PMEm - . ..
101093 FISHER SCIENTIFIC CO. $207.76 LAB SUPPLIES
101094 FLO-SYSTEMS $632.76 PUMP PARTS
- ---101498-._._ _. FOUNTAIN-VALLEY-LAM6RA- --FILM---- --- ----- - --
221096 CITY OF FOUNTAIN VALLEY S6,567.4P WATER USEAGE
101097 THE FOXBORO CO. $537.14 ELECTRIC SUPPLIES
-- 10I896-- - - SATES FIBERGLASS- INSTALL-ZAS--- -------- -- --345,434.A0 - - - ------SCRUBBER RBPAIRrVALVE-REPAIR-----------
191099 GENERAL ELECTRIC CORPORATION $18,426.37 CONSTRUCTION J-15A
F
FUND NO 41.9 - JT DIST WORKING CAPITAL PROCESSING DATE 7/26/89 PAGE
REPORT NUMBER AP43
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY
66A02/S%-POSTING-DOTE- 06/02/49
WARRANT NO. VENDOR AMOUNT DESCRIPTION
101100 GENERAL TELEPHONE CO. 11.259.9; TELEPHONE
101301 SENICON CORPORATION f156.4! PRINTER
- 131103 GIERLICH-MITCMELL. INC. f36.486.90 MECHANICAL PARTS
101109 DON GREEK f ASSOCIATES f19r639.60 ENGINEERING SERVICES 3-33R
._-U aSO.26 .....-_VALVE__ _
SC1106 HACH COMPANY ,18.7E LAB SUPPLIES
101107 MATCH L KIRK. INC. $2,282.0 ENGINE PART
--301-103-- ft93.4O... _.._. -.. . •=^C2IO ....... _-.-..._
101109 HEKIM76N S ASSOC.. INC. $5,680.00 CONSTRUCTIOH R-027-I
101110 MELT STREAM 3576.00 RENTAL SERVICES
-�Iill —___HOER BIGGR.-C.Y.6.-GANF.-t-iMt.--. . __y3-y15.69. ._ __-._ MECHANICAL PARTS
I01112 R.S. HUGHES CO.. INC. f375.5E HARDWARE
1K1113 ICC INSTRUMENT f178.99 ELECTRIC REPAIRS
_ 102115 GRAM PAL-iNREA0C0.-0A _...$3.984.00... .. _...._._._... JAXNCCTOBJL
101116 INTERN PAPER f3r909.29 JANITORIAL SUPPLIES
101116 INTERNATIONAL BUSINESS MACHINE fIr373.46 C01@UTBR SOPTXARE
- 191118 THE IRVINE CO. 342.681.22 BIG CANYON REIMBURSEMENT AGREEMENT
m 10I119 J 3 N SCIENTIFIC ,15G.40 LAB SUPPLIES
-�1C332L-.__.,..TONES-3$SO KES_ASSOC..IIYC ..._._ `2AeG33.o5._ �NGIMBERING.SeRVSCBS-RES-88�: --_..__
S 161121 KAMAN BEARINGS L SUPPLY 518.32 FITTINGS
101122 KANER COMPANY 5101957.3C ELECTRIC PARTS
_...._301125 .. . ._ .._ ...XE[MAN�-ASSOCIAT.E4L- _____.- _. __--,__--S3yT62.50 ._ __.fpRKERB..CONY-AOMtNL9TRATLYEJBE---.__
101124 KEENAN SUPPLY $426.95 VALVE
ll!125 KELLEY BLUE BOOK 5122.00 PUBLICATIONS
RIENZI PACIFIC.._.__-._-.._._.__ .____...__SE5.00 .. . .._ . NST-OIL.NN PI-2 —.__..._...
W 101128 KIEYIT PACIFIC CO. f1rOT9$759.89 CONSTRUCTION PI-27
10L128 KiMMERLE BR OS., INC. 5759.89 CYLINOBR RBPAIR6
- --- 1011II9- -- ---MAIG-B[AOSN6r-INC.-- -- - . S$2,03.76 -- -CONSTRUCTION SEE-- __.-_..
- 10113O MARTIN NDSTROM. IN 16,716.66 CONSTRUCTION SERVICES HARTER 2-26-1
191131 K.P. LIND STPON. INC. f16.716.66 CONSULTING SERVICES - MASTER PLAN M.O.IO-I4-87
132-.____MSC-JwP.L1EP-EW66.06 .._..._ _ ._ __._._....PHOTO SERVICES C
101134 MPS 666.7E PHOTO SERVICES
101135 MAINTENANCE PRODUCTS, INC. i6-023.32 IffiCNANECAL PARTS
��NAFYAG ELECSP ONICS-�--1011S5._ _._ __ ._ ... . . ._. .. -S23.S2 _INSTRREPAT-SUPPLLE.L
101136 MASTER TOOLS SERVICES ,272.8E TOOL REPAIR
101137 MATT - CHLORr INC. i2.252.57 CHLORINATION PARTS
••••39 MICRO MOTION
S5,096.50
096
101139 MICRO NOTION 98,468.34 COMPUTER
REPAIR
1O1141 MITCHELL COMPUTER f-S$2.30 PUBLICAT HARDWARE/SOFTWARE
-.__.._.3012 A1��� -_-- --XITCNELL MANUALS,- INC. - --� -�- -- � �� �.-592.6P - -- PUBLICATION--- —.—
131142 MLADEN BUNTICH CONSTRUCTION CO 3613,665.26 CONSTRUCTION 3-28R-I
113141 MOORE PRODUCTS CO. $453.77 INSTRUMENT PART
-10 MOOR L-i._7 ABER-..--._-__.__ .... ..... -_.—._-.83..439.25
„; 101145 MORGAN/COLTON EQUIPMENT $1,311.43 TRUCK PARTS
FUND NO 91-9 - JT GIST WORKING CAFITAL PROCESSING DATE 7/2618% PAGE 4
REPORT NUMBER AP43
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY
_-CLAI44A3✓AID-O/A02"s -ROSTi NG..DATE-S6/02/.BW-- -
WARRANT NO. VENDOR AMOUNT DESCRIPTION
- -- 101146 -----MOTION INDUSTRIES, INC. ---- - ------ 5738.2E HARDWARE ---- -
201147 MOTOROLA, INC. $16,232.24 PAGERS/EQUIPMENT
-.--I41141-___.MOTOROL4_"LLULAS SENIVIX45
101249 NB PRODUCTS. INC. 3136.5E PLUG REPAIR
101190 NATIONAL FILTER MEDIA CORP. $23,120.93 MECHANICAL PARTS
_--5441.11 .. . - -_ HARDWARE-.-.- ----_ORTH CENTRAL E ..
101152 NORTH CENTRAL FNGF. $156.74 INSTRUMENT SUPPLIES
101135 O.M.S. $1.693,691.09 TWO REMOVAL
0113L--__CYNTHIA • "•LAC-C-0. -- -$49.80 EEXPE.10-i0-88 --
101195 OPERATION
O.NECH 348.80 SERVICE AGREEMENT
10114E OPERATION TECHNOLOGY INC. 3898.00 SERVICE AGREetLLNT
- 1Di-187 ORANGE-COAST--EAUTO98.04 . ._..._... ._..TRUCK PARTUPP1.BB6 ____
101159 ORANGE COUNTY D DOORPARTSCOMPANY
CO. $388.5E TRUCK PARTS
1011 .. ORANGE OVERHEAD DOOR LDMPANY $2.332.50 TRUCK REPAIRS
•01161 -COUNTY-OF ORAN ---.__.— .-.�433.96.-....- .--_. -__ __ _-SPSCIALT-Y-GAESFE -.
• 201162 COUNTY OF ORANGE $78.550.90 DISPOSAL LATE PEE
101162 PACIFIC PARTS 35,305.5C TRUCK PARTS
'-- .-101163- --PACIFIC BEFE7-Y-EOUERNDM7-LC. -_ ..�y4.93____-_ TELEPH-NFIPP6FN6 ---
101169 PACIFIC BELL $681.94 ENGINEONE
PA
F7l 101165 PARTS ENGINEERING COMPANY $].360.39 ENGINE PARTS
X—101167S-UNIISI -. '"1.2e-.. _ _-. BIG
_-._..
S 101168 J.M. PETERS CO.,CON INC. $
$3,113.44 BIG CANYON RSERVICESN2-1' ACR8P1�M7
301168 S4M Y. PETERS ON S ASSOC. 33,113.99 PNCIN86RING SERVICES 2-11-3
-`ODKF FNRS .-
.1 101176 PICKWICK PAPER $11.77 JANITORIAL SUPPLIES
1C1171 FINA 600 SYSTEMS,- INC. $44,786.15 SLUDGE REMOVAL M.0.5-11-88
D--..141142--.- RJ4MCY---&OWE4-_.___-___..
t 101173 POLYPURE• INC. 113,432.26 CATIONIC POLYMER M.0.3-8-89
101174 MAROLC PRIMROSE ICE S231.G0 ICE
__10I1A5- PROFESS TONAL-TRAINING-AS"t., ___636.00 - --PUBLICATION— ------
- 101176 THE PROJECTS SOLUTION CO. $4,550.40 INSTRUMENTATION INSPECTION M.0.8-10-88
- 101277 PYRAMID FENCE COMFANY S479.B3 FENCING
-- - _]O1-1T0---- --R.B.F. ASSOCIATE-S-- --- -- ----.. -- ..-. .-__ ...-;660.y0 - - - - INSPECTION-SERVICES— ------
101179 R.P.M. ELECTRIC MOTORS S1.623.97 ELECTRIC REPAIRS
301182 RANCHO TOMAS, INC. $37,700.00 EASEMENT 14-1-1A
301}81 - -R.D-SYSTENS.._INC.--._ ___ _._ __.._.___..__ . -_114M.75 _ _ ___-CAMERA,-REPAIRS
201182 RECVC, INC. S65,360.74 SLUDGE REMOVAL M.0.5-I1-88
- lolls! RED VALVE CO., INC. $53.65 FREIGHT
_.__--101384-.._ --.REMEDY-.TENR__ . .-______.._.-..---___ .-SB70.00
101195 THE REPUBLIC SUPPLY CO. $1,849.79 FITTINGS -
101186 REMOLD POWER TRANSMISSION $218.52 MECHANICAL SUPPLIES
--4 -JA.-ROBER IS CORP.-- — - _ _... ..._..... _. 3914,494.36 - - -- ------CONSTRUCPION�-20,-J-7 4
M ITS RICHARD ROLFE S734.32 METING EXPENSE
201189 RYDER TRUCK RENTAL, INC. $1,549.3, RENTAL VEHICLES
141-k90--- -SLI-C OAGT-6E5}6N5---------------- i"9.55--- - ----OFFICS-FURNITURE - -----
- 101191 SELCO PRODUCTS CO. $14.19 INSTRUMENT SUPPLIES
FUND NO 91" - JT GIST WORKING CAPITAL PROCESSIAG DRTE 7/26/8R PAGE 5
REPORT NUMBER AF43
CDLNTY SANITATION DISTRICTS OF GRANGE COUNTY
'- - - - - - -- CLAIMS -AID 18/.12/8Y- POSTING DATE 14/92/89
WARRANT $10. VENDOR AMOUNT DESCRIPTION
131192 SEMSORFV. INC. %49.14 ANALYZER PART
112193 SKYPARM WALK-It! MEDICAL CLILIC $1.426.55 PHYSICAL EXAMS - PRE-EMPLOYMENT
---101194---. SMI TM-EMER-V-CO. - -A1r 792.4} -SOIL TESTING- --- - -- -
101195 SNITN PIPE A SUPPLY. INC 954.57 PLUMBING SUPPLIES
102196 SOIL AND TESTING ENGINEERS S659.0C SOIL TESTING
101197 SOUTH COAST DODGE - 365.65 TRUCK PARTS
101198 SO. CALIF. COASTAL WATER 3214.600.00 SCCWRPA DEPOSIT US 89-20
101199 SOUTHERN CALIF. EDISON CO. S416.801.E6 POWER
- - - 1LLL200-- SO. CAL. 644 CO.. .. - -_ .__ $489.36 - - - NATURALGAS-__ _._ ._-..__.._.. .._ .
191201 $0. CALIF. WATER CO. $41.79 WATER USEAGE
101202 SOUTNERN COUNTIES OIL CO. 94,585.23 DIESEL SUED.
101203 - SPAPMLETTS 6RINKIN6 WATER - 51,401.69 -COOLER RENTALS A WATER- -- -
1R1204 SPEC TECH WESTERN $446.43 WELDING SUPPLIES
1.11205 SPEECO S574.60 SCALE MAINTENANCE
-- 101206-- - SPIRAL BINDING CO.. INC. S466.49 OFFICE SUPPLIES --- --
101207 STAR TOOL C SUFPLY CO. $555.31 TOOLS
191208 SUBIA. INC. 9265.90 PRESENTATION AIDS
- 101209 -SUMMIT STEEL --- S163.-54 STEEL- -- - ------ - -- -
101210 SUPILC9. INC. $904.89 LAB SUPPLIES
fTl 101211 THE SUPPLIERS $350.99 TOOLS
101212.-- - - TEHRAN COMPANY - A694.G4 LAB SUPPLIES
-- --- ----
X 101213 TEL-A-TPAIN S114.60 FILM RENTALS
181214 TILLINGHAST $625.11 PROFESSIONAL SERVICES
tZ 101215 - TOTAL PREVENTION SYSTEMS - S4r872.D0 CONSULTING SERVICES PI-27-1
10121E TRAVEL TRAVEL S672.3C TRAVEL SERVICES
L01217 T.S. TRIPP 5251.:9 WINDOW WASHING
D 101218- TRUCK L AUTO SUFPLY. INC. -$4.767.09 TRUCK PARTS- --
101219 UNISTRUT LGS ANGELES 152.22 METAL
101220 UNITED N07TINSMAN 1347.36 PORTABLE RESTS" RENTAL
1111221 UNITED PARCEL SERVICE - 5184.94- PARCEL SERVICES - - - --
iC1222 UNIVERSITY COPY SYSTEPS S99.q FAA MACHINE REPAIR
101223 UPMAN ALTERNATIVES S6.444.13 CONSULTING SERVICES RES 89-44
104224 VWR SCIENTIFIC 110.9E LAB SUPPLIES - - - -
101225 VALLEY CITIES SUPPLY CO. $4,455.32 HARDWARE
101226 VIKING INDUSTRIAL SUPPLY $189.29 PAINT SUPPLIES
IR1227 CARL WARREN A CO. - %NcC T INSURANCE CLAIMS ADMINISTRATOR
141228 WELLS FARGO GUARD SERVICE S1.I54.T3 SECURITY SERVICES
101229 WESUTES CAPR.ON, INC. $27.93 FREIGHT
101230- - WEST COAST ANALYTICAL SAW. 43.795.30 LAB SERVICES - " -
101231 WESTERN HUTS CHEMICAL SUPPLY S18072.59 CAUSTIC SODA M.0.8-10-88
IC1232 WEST-LITE SUPPLY CO. f1.316.00 ELECTRIC SUPPLIES
101233 CITY OF WESTMINSTER $119.10 ROAD REPAIRS
10123e W'ILLOAN ASSOCIATES 514.617.9E ENGINEERING SERVICES 2-26-3.2-28, 2-26-2.2-27
10L23E XEROX CORP. $4.991.S7 COPIER LEASES
141236 GEORGE YARDLEY ASSOCIATES - $712.74 VALVE - - - - --- ----
191237 RICHARD TOUTIG FRCD. $216.45 OFFICE SUPPLIES
FUND NO 9199 JT DIST WORKING CAPITAL PROCESSING DATE 7/26/89 PAGE 6
REPORT NUMBER AP43
COUNTY SANITATION DISTRICTS OF ORANGE COUNTY
-0l,A{MS-FA} 48,162I89--0 &*446 OAT-O 6/024-89 ---
WARRANT NO. VENDOR AMOUNT DESCRIPTION
301238 21EEARTN AND ILPEP 6280.]66.]0 CONStBUCTIOM P2-37
-----------------
TOTAL CLAIMS PAID 08/02/89 S6R945R366.62
SUMMAfl1L. ..___.___._---.__AMOUNT—_-
_ /1 OPER FUND $ 3.37
_12..OPES�Ull.— _. __ 13R IN . .
/2 ACO FUND 640,234.94
03 OPER PUMO 30,194.83
t—a-ACD.FUMII
95 OPER FORD 5.170.71 - - -_-� - -
M5 ACO FOND 80.421.07
2 06 ACO FUND 4.905.01
07 DIES I= 1,452.55
txj
52.853.81
!�.q Oil OPEAm ORNO 2.607.86
114 AGO FUND 2,607.86
_0566 AGO FUND3.994.95 _.__..
Cn P566 OPER POND 3,378.60
05A6 ACE FFOR --U.60
__ ..9667.OPER.PIOR. _.______.-_ ._._.. __ _..___. ___ __..____ .._-�75.35
29
67614 OPER FOND 1,259.72
JT EY¢R FUND 112,640.27
. .SOLE_._._ __. ___.._._ .__ __. 4,112,640.77
SELF FUNDED WORKERS COW IMSVRANCR POND 0
n:
JT ➢IST NORKINC CAPITAL POND 398,771.57
.__..--E 6,965,405.86
FUND NE 91" - JT DIST WORKING CAPITAL PCOC!SSING DATE 8/09/B9 PAGE 1
PFPORT NUMBEE 4942
. . . _ ...._._...._. _.. _.._._ __.... .. .--__COUNTY SANI UT10N..DI.StIL CI•tOF. ORANGE COUNTY
CLAIMS PAID CC/16/89 POSTING DATE EV/I6/F.9 -- --------
__Y20.RngLNQr_,.._.—._. VEND.OIL_____.___—_2tlD.UNL..._.... .. ..__._. ....DESCRIP_TIDN___--_.
1312" LINCOLN CARPETS C INTEPIORS f617.4E STAIR TREADS
_ . _ ._ IP126 R. ... _. ..A.CME AE LDIdE._.__.._____._.__ ._.._._....�2S"76 HECHANICAL PARTS__ __.. __ _.. ._ . .__...
1..1261 THE ADVANCE GROUP 364.7E PAINT SUPPLIES
101262 AIR PRODUCTS f CHEMICAL INC. f8R.R4 0%YGEN PARTS
1C1263 ALL ItoPLICATION ELECTRIC POTOR 111%.92
IC1264 LEASING ASSCCIATES/ALLSTIIE $1,290.34 AUTOMOBILE LEASES
IP1265 ALLLN ELECTRIC CO. 32,446.0! ELECTRIC REPAIRS
PESCEINSTALLATION
1CL267 ALTA SALES. INC. 9143.30 INSTRUMENT PARTS
LC126F AMERICAN CHAEV S GEAR CO. $3,588.55 CURB 6 CHAIR
BOSCO INC. S/OR ANEPICAw SEAIY 54.314-98 . __.._ __ _ ... ._.MECBANICAL SUET JFs
143..270 AMEN. SOCIETY FOR RICROBIOLGY 365.C9 SUBSCRIPTION
1C1271 AMEFITECH 992.10 COPIER LEASES
.IC127P.,__ANAJEIC�INC CQNSTRucrI OB_.—_. S323.A.G _ OIL SAMPLING
1C1273 ANALANCHO INC. 3216.5E OIL SAMPLING
•1l1274 A,IE ANCHOR PACKING CO. $142.57 ENGINE PARTS
2CI276 A, A., P. ANDFRSON .370SIt&.,5D .__-. -UNIFORM RENTAS
3C1277 ABATER SERVICES. INC. S5,E70.39 INSTRUMENT
RENTALS
fTl IC1277 AM120NA INSTRUMENT fi,774.Q0 INSTRUNSNS PART
ID1279...._..._...—ANS.I - CDNF. lt OFs COASTAL
AGENCYalm , _. 31.343.IE... __ _ . ._ MEMBERSOlLIESTING___.—_
2 IOIV79 ANSI CONF. OF COASTAL AGENCY f2$950.7C CONFERENCE
ASSESSMENT 78!
'—' 101280 AMSA 3250.9G CONFERENCE REGISTMTION
12pT_hA. _... . ._.. ._.__.. ._TOOL REPAIR___
1 171282 S t T HYDRAULICS $123.65 MECHANICAL PARTS
101283 FALCON DISPOSAL SERVICE S94.750.36 GRIT REMOVAL N.O. 7-13-86
..__.7.0.1289._.._BBCSAEEICL_SMPHIT _5153.11 _. . _ . ._.._.__.SAP= SUPPLIES___—..__.
I--' 201285 P.Y. BAROTTI AMC ASSOC. 35.16G.0a0 CONSTRUCTION SERVICES PI-25,26,P2-32,33.34,37
1J1206 BATTERIES WEST, INC. 1537.44 AUTO PARTS
.. ... __1P1287. ... _..___..84%716_HELLUILAELt.ORE.—_._ ._... . ._. _ _.—._�3131"E _._.. ... . ___-_LAB.SERVICES____._._ .__
101286 EATTER SCIENTIFIC PRODUCTS S4081.49 LAB SUPPLIES
101289 BEACH SUPPLY CO. $6.92 REFUND USSR FEE OVERPAYMENT
..__.101 299 EEACPA-RAY iMIEPEELSi.S.L.1Nt.._ SR.4'L.._.._.. ..__.CAB.WASHES_
101291 ROBERT BEIN.WILLIAM FROST f AS $4,622.31. ENGINEERING SERVICES US 88-144-5
171292 BOISE CASCADE 'OFFICE PRODUCTS $1,336.25 OFFICE SUPPLIES
10124d_. .P DLT RD.yULDlId1A1ClLE7U RILE. . _116D.r.Gi . ._... ._._ _.. __ _ .KAINTENANCLACREEMMT....
IC1294 EON-A-RUES 3242.-.r TRUCK PARTS
111295 MICHAEL BRANDMAN ASSOCIATES 3995.57 ENVIRONMENTAL SURVEY
._.._1C129�.___9E.Di!y_DALIIy,Eu rowsul nu,6_______s,V.2m.4-_--__—. ___�NGIHEERINGSERYICESSL-aa.v7-aR
101297 BUSH AND ASSOCIATES, INC. f3,496.19 SURVEYING SERVICES
1A129A GARY G. STREED $1,535.51 PETTY CASH REIMBURSEMENT
C.t R .RECOh DITIONIND_CD.. . .. ..y2,5l O.SC ..MECHANICAL PARTS__
10130 CPI CORPORATION s307.9 COMPUTER HARDWARE
101302 CS CONF ANY i2 rE38.93 VALVES
201.3DZ.._—._ _._CAL-CHEN $133.?7 .HARDWAICAL.PARTS..--__—_..__.
391303 CAL-GLEN SALES f133.P7 HARDWARE
101300 CAL-GLASS FOR RESEARCH, INC. 3233•P3 TAB REPAIRS
FUND NO 91-9 - JT DTST YORVIN6 CAPITAL FPCCESSING DATE Btl-/69 PAGE 2
RE-09T NUMBER Avq!
,..______ .._ COUNTY 54i1 TATION _QISTRICjet OF.ORANGE COUVTV
CLAIMS 41D CE/16/89 POSTING DATE 45/I6/69
VENDOR AMOUNT , ,, ,_ OES Lf IVY ION_.
121305 CARLETON ENGINEERS 51.575.2^ AIR EMISSION CREDIT AQUISITION
,_.._ IC130f CIROLLO-BOYLE.A JOINT VEATURE 636,666. , , _ENGINEERING-SERYICF�—RE3_B7-131
101JC1 CO— STL1`—CONTROLS• INC. 9634.32 VALVE
101308 CENTEL COMMUNICATIONS SYSTEM 94,158.43 PHONE SYSTEM MODIFICATION
_ 101309 __ CM CNWESTINDUSTR I E,_ INC. ,____ _ ____._._ fg9�1 Fy46.,9?, ..,._,_ _ FERRIC.CHLORIDE Md LIc09eSR
301310 HE
U.S.A.• INC. $4.628.86 OIL 6 GREASE
201311 CITY WIRE CLOTH. INC. 5967.37 MECRANCIAL SUPPLIES
10!312 CLAIRSON COMMERCIAL $64/LL 64 R8£UNIL OSER.JO!E�1fE8PAvwxT
.. _....-
gIS1S SS COT FIRE EQUIPMENT f258.76_ FIRE I EP RA TESTING
TESNC
I 1314 C.7.E.5. . CO. . INC. f1.779.66 BUILDING REPAIRS
3P1315 COOPPfiSSOR COMYONENT� OF_CALIF___ STgy9,}.QL_. PUMP-PARTS_
1^1316 CONNELL G.M. PARTS / DIV. 3416.9E TRUCK PARTS
101317 CONSOLIDATED ELECTRICAL DIST. f780.E8 ELECTRIC SUPPLIES
101118 _ CONSOLIDATED REPROGRAPHICS ._33.224.1.� _ALUE£RIMTIND___— _
1R1A9 CONTINENTAL GRAPHICS $1.630.83 BLUEPRINTING M.O.6-14-89
1C1320 CONTROLCO 1115.16 ENGINEERING CHARTS
AUTO BIIP_P LY _ __ 3.1-2 . . ._ _ _ —TRUCK-PARTS.
1CS322 CITY Of COSTA MESA S1.500.09 REFUND CONNECTION PEE
m 10132I COUNTY WHOLESALE ELECTRIC $3.058.2N ELECTRIC SUPPLIES
x.___1P.13.2♦___CBLIIJIS_S.CREEILiRS3_.__ _._ .__.._ 5479. 2 _ _.. OPEPATINGSUPPLIRS —
= 107325 CAL WATER 512C.03 EQUIPMENT RENTAL
i--. 191526 C.R.W.O.C.S. 52V.100.0! PERMIT FILING FEE, RIDES
37132 Z....__Q,•NNILMESiLB__—._._.__._____- - s533._52 . . .. MEETING EKPE.NSE6____.__._ .._..__._—
.--i 1C12P6 OIATF.0 POLYMERS 52.998.6E ANIONIC POLYMER M.0.8-10-88
1
101329 DIFILIPPO ASSOCIATES 92.379.63 PRINTING
N_.. ._.._IICQ11133SII3 ORO0.NAKO LBD.RO O6KD.R3EESN_G08 PP. 911,5507.46 INSTRUMANIS
13133
2 FRANK DRYDEN L ASSOC. 1 .00 ENGINEERING
I ENASRNVCE
ICS85 vPI-e2T0
S315_ ___PAINT SUPPLIES-
lei 134 TROLA DYNE 165.1 MECHANICAL PARTS
101313 ENS RESOURCES. INC. 11,299.21 v s
..
REGULATORY 6 LEGISWTIVB AFFAIRS CON6ULTING
EFFECTIVEVI __ A381.60.. PRESENTATION
AI.._._____—_
1C1337 EFFECTIVE VISUAL IMAGERY 3$35.11 PAWINTATIOH AIDS
131338 FERD INA ND EVA NGEL7STA 335.10 PAWING EXPENSE
_ OOHN , FALKEN --CDVSULTING_SERVICES_AUQQMn MKL
101340 JOMN B. FALMENSTE IN P.C. 53.572.3E CONSTRUCTION SERVICES J-7-4, 3-20
101341 FAIR SALES A SERVICE 9826.92 FILTER
. . . . . 3!13!Z_______...�RE�..LsS29.!rROPANE
IC1343 FILTER GAS 519.5E PROPANE
1C3344 FILTER SUPPLY CO. 3113.92 INSTRUMENT PARTS
29045 __ FISCHFP A PORTF.P COy f9B l.Ii __IHSTBUMENTmPPLIP.S_____—
IC1346 FLIT A VERTICAL CONCRETC 1217.25 CONCRETE CUTTING
131347 FLO-SYSTEMS 5462.92 PIPE
... . 161340 FOWNTAIN VAL1,EY_CAMf,R#_. ___.__ .__._.._J.AS•61.. . _. PLIA1. .—
'101349 CITY OE F66NTAIN VALLEY $606.11 ELECTRICAL PERMIT
1C1S50 FODUTAIN VALLEY PAINT S5.084.52 PAINT SUPPLIES
FUND NG S199 - JT DIST NORKING CAPITAL PROCESSING DATE 9/C9/19 FAGE
REP09T NUMBEP AP43
C094TT_SAN 1,TA]lOU..DJSTJt}S TS OF ORANGE COUNTY
CLAIMS eA[U 48/16 89 DUSTING RITE OE/1E/89
_ ___NRRRRMT NO. VENDOR ANOUNT _ _._ . _._. _. , , ____aES_CRIPULN
101351 THE FOKBORO CO. $91.14 ELECTRIC PARTS
FOYBORO CO. / MSG SYSTEMKE __ 51.26Rs}� ._.__ _ INSTRUMEU_
1 O135J FONBORO/JOROAN. INC 1503.46 INSTRUMENT REPAIR
101354 PMEDERICN PUMP L ENGINEEPING 4611.74 CHLORINATION PARTS
_.. __I9Ja25_ CITY OF F"LLCRTON
131356 FUSCOE, VILLLIAMS. L140GREN L f1.900.0C• CONSULTING SERVICES DIST 11
111357 GANAHL LUMEER CO. S2✓193.53 BUILDING MATERIALS
-Lm Sse GENERAL TFL FPHONE CO. s93A.90
IP1359 SERARDS PHOTO LAB $16.32 FILM PROCESSING
L01360 61ERLICH-MITCHELL. INC. S4.123.97 MECHANICAL SUPPIES
._ __ ..1.E1361-__DOi CREEK ASSOCIATES
5.bs4.B5
161363 00N GREEN 6 SUPPLY
CO. YES 55.683."1 SURVEYING SERVICES RES 88-]2
101363 NALpPlk SUPPLY CO. f59.94 OPBRATINC SUPPLIES
,&9 4_j_ HATCH A NIRN, INC. S0.549.2i _16MANGIAL-ASUIRS_
101361 HILTI. INC. 61.03A.25 1I77TINGS
10135E HOOPER CAMERA STORES $33.73 CAMERA REPAIR
MOUSE_PLNAJTCRILS __ - 19.1T _._... ..__.. BAT'TERIE3.__.-___.__ ..__ _
1C1368 P.S. HUGHES CO.. IkC. 5613.75 SAFETY SUPPLIES
m IP1369 HUNTINGTON BEACH RUBBER STAMP $260.47 RUBBER STAMPS
>�.___18L'7S__ Hj1N71NGTON VALLEY SCHNINN CVCL T212.P _JIC1(CLE_PARTS
2 101371 MURLCY ELECTRONICS, INC. 5985.01 ELECTRIC SUPPLIES
101372 ENERGY SERVICES GROUP f271.7E MBCHANICA}. PART
to___. 101313_,___IVA EN6INEEP.S ;2A153A3 S.. _ _._ ___ENGINEERING SERVICES EL-27-2 -__
1 191374 INDUSTRIAL THREADED PRODUCTS $625.32 CONNECTORS
1C1375 INGRAM PAPER $1r63-.39 JANITORIAL SUPPLIES
y ___-15137E _�NLANo EMOIR[ S9UIPNENLC9i_ sI.e22.Su _ JtRNTAL RQUIPMEn--.__.
W 101377 IRON OAKS 5192.76 REGULATOR
IC1379 IRVINE 6ECTECHRICAL CONSULTANT $492.5P CEOTECNNICAL SERVICES
.. 1C1.3TF. UNIJED_.CQNSULJANiS,______.--____ .anal. _. . __._INSTRUMENT PARTS- ___
IC2380 J K V SCIENTIFIC SBN.PS LAB SUPPLIES
1E1301 JADA SYSVEMS 941a.PC ELECTRIC PARTS
13}3@2_. - RIyIe,9 T F 1 -A-CE s I.112.T7_ _-.__ �IANNJTDBIAL�yEPylEB-__
IPI383 40HISTONE SUPPLY f260.67 ELECTRIC PARTS
292384 KALLEEN.S COMPUTER SUPPLIES $432.97 OFFICE SUPPLIES
AN @EARIN65 6 SUF Pyy_„ _ S49.12- _____._-------ZITIMS--._
111386 KAMER COMPANY $496.34 TOOLS
13139T KEENAN SUPPLY $411.93 VALVE PARTS
__.._ 19339.4 -_KSNS!S_ALLluC CLLP S 3_-__ REFUND USER_FEE-MUAYMEHT
191389 KING BEARING. INC. f7 M96.72 MECHANICAL PARTS
101390 KNAPFr MARS". JONES L DORAN f3.553.5P LECAL SERVICES - BEATRICE/HUNT MODS
_ 231391_ ,. MARj,1N KOROIQ SR _5;.331.tO ..,___ .__.__ _.CONSTRUCTION SERVICES_2-251
1S1s97 L.A. LIOU19 HANDLING SYSTEMS f91.Ea PUMP PARTS
101393 LAUNDERLAND $193.57 REIILND USER PEE OVERPAYMENT
CO4;_QLTIIL.LNG4y_______.__._f1Q.J�.73B
l91395 JUDY LEE $65.31 MILEAGE EXPENSE
101396 LIFECOM-SAFETY SERVICE SUPFLY f75.OG CYLINDER REPAIRS
FUND NO 9199 - JT DIST WDPKING CAPITOL PFOCESSING DATE 9/09/E9 PAGE 4
_ REPORT NUMBED AP43
,COUNTY,.
CLAIMS PAID 08/16/E9 POSTING DATE OR/1E/R9
YAPRAPT H0. VE ND OP _ _. . . _.__..._. .AM NALT . . _ DESCRIPTION_ _
1P1397 LIMITORQUE CORP. $3,846.47 VALVE PART
_... 17139P . LOR A IN PRODUCTS 31.191.54__ _. ,._ _.__.. RELIANCE_PQ4R_5IRYSFE AGREEMENT
101399 LOS ANGELES COUNTY SANITATION 31.114.69 COMPUTER SOPIMME
111400 MPS 337.10 PHOTOGRAPHIC SERVICES
__ _ 14140E NAG STSTER$/FORBOPO CO. SIA5_iU .... .... . .. ..... INSTRUMENT
101402 MALCOLM PIRNIE 9 INC. $1,473.72 ENGINEERING SERVICES - ODOR CONTROL
IDEALS MARVAC ELECTRONICS 145.25 INSTRUMENT SUPPLIES
.. _.__10PO4 __MATT - CNLOF. INC. $699.t_2_ __. _. CRLO9INATlON._MT3__,_._
101405 DON MAURER $39975.00 CONSULTING SERVICES - OCEAN MONITORING
101406 MCMAIN INSTRUMENTS 9330.0: LAB MAINTENACE ACREEMEST
IV24_407 MCNENNN ENGR. L EOU Ips f14.628.".v _ , . _ _ _ ____. eWl?_PARlS____.,______ , _
101408 -[MASTER-CARS SUPPLY CO. $1.022." TOOL
1M1459 MEDLIN CONROLS CO. S399.54 INSTRUMENT SUPPLIES
_.._--SOAP%&I[ _..__._._-..._}I�SAIILiQP _ QCEAM.HQNLTORIR&_RADEO_EQUIPNENT _
101411 MICROAGE COMPUTER $1.195.08 COMPUTER SOPTWARE/HARDWARE
101412 MICROSOFT CUSTOMER SERVICE S40.50 COMPUTER SOFTWARE
1¢J413 MINE SAFETY APPLIANCES CC. 59.472.16 ___„_ SAPB,TY SUPLLTES
1C1414 MITCMELL INSTRUMENT CO. $594.10 METER
1C1415 MONTGOMERY LABORATORIES 33.D15.CL LAB SERVICES
m 1014I4._.._......__.. nAljc_ 1NOU57RIE AJb a_. _ _ .. _�Al.@.6.9 .. .. . ..BEARINfl___
X 101417 MOTOROLA. INC. 3113.J4 COMMUNICATIONS SUPPLIES
101418 NEAL SUPPLY CO. S731.57 PIPE FITTINGS
W _101419 HE MERMES, INC. SVl.M±________�SIILDINS.316TEHIALS
101420 NEWPORT BUSINEES INTERIORS $629.24 PARTITIONS
132421 NEVARK ELECTRONICS $26.40 METER REPAIRS
W . . . 301114__. .__WAIE9ySRAG¢
I lj 423 CMARLES NICHOLS S58.93 MEETING EXPENSE
IP1424 NORTH CENTRAL ENGR. $95.49 INSTRUMENT SUPPLIES
30.I4_a...___NMa&gjIC PLAT NO _ i43.2q ---__-__-___E&PYdTUSAgFEBSDORPAYIIENT
10142E O•PRIEN MACHINERY CORP. 174.926.00 GENERATORS M.O. 10-15-88
112427 OCCUPATIONAL VISION SERVICES $390.69 SAFETY GLASSES
___. . AO1t25. ..-. _..-_ OPF.ISE�AE14.1BNLI1<IEPSLa.AC3s-__ ._A jjj U_f619 _. _.__ .-___-DEFT[E..PJIRNITURE(EARIITIONAM.D..6_-.8�8__
101429 OLYMPIC CHEMICAL CO. f469645.34 CHLORINE M.O. IO-12-88
101430 ONE DAY PAINT 3 BODY 9365.74 TRUCK PAINTING
__ }01031_,__ DR AN GE OAST ELECTRIC SUPPLY S371.9¢, _.__SLEQTILL9 S14PFLICS
101432 ORANGE COUNTY CHEMICAL CO. 37D6.25 MRATIC ACID
1C1433 ORANGE VALVE 6 FITTING CO. 3889.64 VALVES/FITTINGS
__101455 _Qu3LMAERYICE __ __. ._. str?A.°2_._ .__ __
121435 COUNTY OF ORANGE $29,533.86 USER FEE SYSTEM COSTS
101436 PACIFIC DATA CON SYSTEMS f1.392.66 COMMUNICATION SYSTEM SUPPLIES
.__. 14143j.___._...__._oACIFSC PPPTS ___,_ _. ..._SL11'`3Te20_-. ... _ .- _.. ELECTRIC_PARTS.__-.___.____
3.1438 PACIFIC SAFETY EQUIPMENT CC. $2,414.23 SAFETY SUPPLIES
1:1439 PACIFIC BELL 329.9E TELEPHONE
.....___1.914 __PA CTEk..CELll�1F __._..3A9621 . .___CELLgLAR SERVTOES.__._
101441 PARTS UNLIMITED $1.154.65 TRUCK PARTS
1C1442 PATTEN CORP./ TAILOR INSTR. 3212.E2 INSTRUMENT PARTS
FUND AD 91P9 - JT DIST WORKING CAFITAL PROCESSING DATE 8/09/89 PAGE
REPORT NUMBER AF43
SD.UIU_Y .S,ANILPTT.PNJLI ST1LtDI5_Of_ ORANGE-COUNTY
CLAIMS PAID 08/16/89 POSTING DATE 25/I6/89
-. Y\R,RANT NO.. __. . Y�4Qp__._._.__. . _ _._-- ._._ FMGUNT .__. _ - DESCPIPTIQN
101443 PEAT. MARWICK. MAIN S CO. S5.3000L AUDITING SERVICES
139wy _ ___ _ .__ __.CORE.DRILLIMC_.
101445 DR. EDVIN M. PERKINS $4,363.12 CONSULTING SERVICES - OCEAN MONITORING
101446 PHOTO R SOUND CO. $4,350.52 INSTRUMENT PARTS
_-_.-Plil fIA_Q_SXtUMai.INC. f11AA.1.Z�.9,5. . _ .... SLUDGE.REMOVAL.YA.3-11-RB—__.--._____
101448 ROBERT PLANTA S15.675.?E DEFERRED COMP PAYOFF
101449 POLYPURE. INC. $24,491.72 CATIONIC POLYMER M.O. 1-8-89
POWER E,Lf j"_S.0PPLY CC 323H.5.9 _INSTRUMT_pARIE.________
101451 POWER SYSTEMS S1.090.5P TECHNICAL SERVICES
101452 HAROLD PRIMROSE ICE S165.1r ICE
.. ......... 1?144g_....._.._-.IME. PRDAIL.Ci53➢LDI[R1L.GD_...._.__-....__--____._.-.31.12D.Sd'0 . _ INSTRUMENTATION.WSPECTICN.M.0. L-10-8A___._ -
101454 PROTOTYFE. INC. S3.000.9L COMPUTER PARTS
1E1455 PYRAMID FENCE COMPANY $9.109.66 FENCING
_—__.1413Ab___--__7V.:a4LjhuA-N_PN.ITDp SERVICE .__ .-__ _._ Si35.CG INSTRUMENT-.REPAIR_.
101457 R.A.M. ELECTRIC MOTORS 5841.21 ELECTRIC MOTOR
131450 RAINBOW DISPOSAL CO. S797.24 TRASH ReMOVAL
THE REGISTER _3.3Ei89D..79RA ADS
101461 THE REGISTER f596.79 TEMPORARY
6 ADS
301461 OENEOY TE MF f4.567.E3 POSTAGE SERVICES
=_—__1R 150.i_.....__..._._PS.^lETE1+FSF.B_9L3.EIII7L0_SYStfR ._-_.__ ..___....__3]-LD ..POsrAGE___—..—___
111463 THE REPUBLIC SUPPLY CO. S1.502.E0 INSTRUMENT PARTS/FITTINGS
i--i 101464 REVERE PRODUCTS S725.71 PAINT SUPPLIES
tZ.- _. .101465 _LEGAL_SERVICES____—._____
101466 ROBINSON FERTILIZER CO. S3.304.34 CROUNDSKEEPINC SUPPLIES
IC1467 ROSEMONT ANALYTICAL S1.477.21 INSTRUMENT PARTS
3.01,94R_.._...
__.RIIA.Lttltl-__
Ln 101469 RYAN+ ERCO 6591.6E METAL
101470 SANTA ANA ELECTRIC MOTORS $793.08 ELECTRIC MOTOR
_.. -101R,T1 _ .._._ ...... SEIEBCE.lPYLIC4LT1ON2INT!L _ _ .- __... -._ .. .AllmA13L 36 _ _ __ _ OCEAM_NONITORIMGI O_ 8=10-88-
IFI472 SEA COAST DESIGNS S212.4L OFFICE FURNITURE
201473 CITY OF SEAL BEACH S152.EL WATER USEAGE
_1014I9.. .__.._—SERA 3v50E6 Lc R._ANk Co. s45.,En _-___ _ TOOLJEPAiR _
101475 SE SALES. INC. $14.19 INSTRUMENT SUPPLIES
1P1476 SHAMROCK SUPPLY $257.9. SAFETY SUPPLIES
RT.PAGP INEENRR _
10!476 SLIDE MAKERS WEST 1841.11 PRESENTATION AIDS
101479 SM7TM PIPC S SUFPLY, INC S472.32 PLUMBING SUPPLIES
. .1014el SOUTHERN
CALIF. EDDY ___—_----- ---- ,523.2.^- -.POWER
101482 SOUTHERN CALIF. EDISON CO. f$3,164.16 ROVER
101482 S0. CAL. GAS CO. f3Y169.16 NATURAL CAS
. . 191493..._....__.._SDUTMERN.TS DRINKING W_C0.___.. _. ...- -. _---.__J9.P$33.75 __. __ ..._-.. DIESEL.PDEL_
101485 SPEC TCCTS WESTERN
WATER f33.T5 COOLER RSUTAIS/ WATER
101985 SPEC TCCN V[S TEop f6.21Y.6E WELDING SUPPLIBS
IC14AfzROBERT _387J..P7 ... UTLING SEANCE_____-__
10198i S76ERT SPIES S87O.6C TOOLS
FUND NO 9199 - JT GIST VORMING CAPITAL FFOEESSING DATE 8/D9/8x PAGE 6
_. REFORT NUPSER AP43
_........_.......___... -_.._.__.._-._- CR NIT. 301T.A t19k 7.757aIc73 DF„DPANCE EDUKTY_ _,
CLAIPS PAID 08/16/09 POSTING DATE C8/I6/89 - -
._ WAPPANT NO.,___ VEN22P ___.___-._AMOUNT__
1C1.89 SCOTT STEVENS 3630.40 MEETING EXPENSE
_10249C _. „S_TRIF SHOPPING CENTER f329d Q .. REFUND USER PEE.OVEBPAYtlUMI_....-_
1EU91� S1101A• iN C. f265.70 PHOTOGRAPHIC SERVICES
1C3492 SUMMIT STEEL f•51.1! STEEL
101494 SUR IVAIR ERS f6$111.41
IOL•9• SWEETLAND f•11.A1 SERVICES AGREEMENT
1P1.95 SVEETLAND CC. 1300.4• FITTINGS
.__._...i'vl•96___....._... TA SM�N.f N7LP.MP.I SE@ i..lt2'LLA07 ...... . . . .__AUUNI CONNECTION_FER
1C1497 TAK TAKANINE f4.283.1u CONTRACT GROUNDSKEEPING
101.9A TAYLOR-DUNN $336.23 CART PARTS
191SF9 CHARLES E. THOMAS 152A.9A„_. .__._._.._._._ TRW.. RRPA.
21156. THOMAS FISH COMPANY f238.90 LAB SUPPLIES
1015u1 THOKFSOA FUBLISMIR6 GROUP 1187.33 BOOKS
. _. . ..1013,02.._ G _ _ _ .__ '$461_13 . . .. .NAILING SERVICES.__
161503 TRAVEL TRAVEL $190.60 TRAVEL SERVICES
101504 TRIPLE M PICKING 61,473.25 REFUND USER FEE OVERPAYMENT
_..._...19nes TRUCN t
1:3406 J.G. TUCKER S SON, INC. 1613.12 CYLINDER TESTING
IT 3M1507 TWINING LAPORATCRIES OF 33.909.OP SOIL TESTING
M. __ I9/:04_._.._._ ..9313.fQJP.LA4iPJ6_..___ " t1.661.66.
._______......_-.._.. _ .. ..UNLEADED GASOL._..
= 101809 UNOCAL f327.•7 UNLEADED GASOLINE
'--� 101510 WHITED PARCEL SERVICE S317.63 PARCEL SERVICES
_ .J 9.1'1.11.. -__ W.3>._CG W1PrEflL4D.,,_Ixt•___..__.__..__._..�211.1°. __.. . .._. _ MECHANICAL_FARTE_--____--.
-1 301512 UNITED WESTERN ELEVATOR 1326.1? ELEVATOR REPAIRS
w 1C351! VUR SCIENTIFIC $1,817.69 LAB SUPPLIES
.1__..J101.R1'L_YdLI,EGS7n£S suv P,L]LED�. Wl18AA/._ ._.-_ PIITTxrs _-_-,__-
Cn 101535 VALVE SERVICES. INC. $223.31 VALVE
101526 VAREC DIVISION SS.193.96 MECNAMICAI. PARTS
..1013.17.... ... .Y.Aj,1AN_INS.SPUNEIlLGROWE. _... _.. __. ._ _..__.._ ..�.fi"...99 .. ..LAB SUPPLIES..
1C151R VERTEX SYSTEMS 11.517.50 COMPUTER DATA SUPPORT
1C1519 VIKING INDUSTRIAL SUPPLY $422.40 SAFETY SUPPLIES
_121 gZ.Q JOHN P. UAPLES _. _ f53R.9? pBDLCDNFROLCOMSULTN•L_ _
1C1521 WAP.RIN6TON $115.30 INSTRUMENT CALIBRATION
101522 VINCE4T WENTI FLOORS . INC. S87.9C BUILDING MATERIALS
..__ ID15;a _ UEST_cO�;i ANA4TT141J,III%..... .._ __._._f215sDT ..... . _...__ .... LAR.SEBVICES___.-...
101524 WESTERN METRO SUPPLY 3154.46 MECHANICAL PARTS
1C1525 WESTERN STATE CHEMICAL SUPPLY f28.1.9.5P CAUSTIC SODA M.0.8-10-88
166.53 __.. _..-.._._.._._ELECTRIC.SUPPLIES._____.
101597 WILCON IND. 1237.95 INSTRUMENT SUPPLIES
221529 WILLOAN ASSOCIATES $1.963.0..) ENGINEERING SERVICES RES 88-4
1D1529 _ .VENQN_CORi. _._ _ _ _ _. 1937)2..24 ._ COPIER LEASES..
101531 ARTHURT N. HORN C4. 651A.34 MECHANICAL PARTS
101131 ARTHUR YOUNG 3122.697.1? CONSULTING SERVICES M.O. 1-11-89
171E32 0.1CnaP0 YOUNG oP Os_ f1.026,f52_ ,__.____,__,_OFPICESUPPLIES........__.___._.._ ..
----------------
TO TA C A PS FA IC.. _ .-._- .._... . _-.._.... ... .k_ - --. ... ."E_ 6(189_ Sl N _�TO_!}23___•______====PPP
..._.........
POND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 08/09/89 PAGE ]
REPORT NUMBER AP43
- COUNTY SANIATION DISTRICTS OF ORADCE COUNTY
!I OPER FOND i 21,078.91'
J2.DYPR PIINII ___.. __4"M 11
02 ACO FUND Nf , 6.2
/3 OPER POND 60,63656.34
./]_ACE FUND..__ ._____. __.__._ _—12,127.10_.-._.. ..
OPE
15 AM FUND
12.660.27
00 -
IS AM POND 2,660.00
... .#6_OGO FUND
_14.61a 80
06 AGO FUND 5,789.26
oi OPER POND 15,789.26
ill AGO PUDD._. .._._______. _. .__—. . _._ 74,926.00 .__._.
!ll AGO FUND � —_--� 74,926.00
!13 OPER FUND 2.463.01 -
/546 ACO FUND __-- -�--- _- - 4,91818.]R
0667 OPER POND 3,057.36
07A14.0PU FUND......_ _. __ . _ _1,75769..__. .. .. ..
JP OPER FOND 570,219.53
X. CORF - 406,086.32
2... CPT FUNDED MIXERS COIF INSORANFP1+0N0_ _. .__ ______._._—O� .__ _. _ _..—._ __ - _._ __.__....— _
JT DIST WORKING CAPITAL FUND 157.734.08
to
tz
FUND 4P 9145 JT MST WGPKIRG CAPTI3L PPOLESSTVG DATE 9/23/P9 PAGE I
RFFC91 pUY 9ER AFa! '
-- -- - -- - -- - - COUNTY SANITATIOH DISTRICTS OF 0OA14SE COUNTY
CLAMS PAID CE/3./P9 VCSTILG DATE :S/3S/E9 _- --
-1JARPAM7 %G. VENDOR - - ArOUNT DESfF1PTION
ICIE£7 ABE SERVICE CO. 44P6.ff MECHANICAL PARTS
,.-_. lnlE9A IT K 1 - - "-'-- '- Sri 7.2E LONG DISTANCE TELEPHONE
1015PR ADVANCO CONSTRUCTORS. INC. 17GJ036.7E CONSTRUCTION PI-34-2, P2-34
101590 AIR COLO STIFFLY INC. 324R.23 ELECTRIC PARTS
lfl5" 41ROUAPD-INEUSTRIES4-IkC. 3373..E2 FILTER --
., 1415P2 AIRFAY CORP. CAMEP.IDGE DIV. 3367.!' CIRCUS BREAKER
1C1593 ALLE4614 PHARMACEUTICAL 35T3.4f REFUND USER FEE OVERPAYMENT
ACPHA 6A2-'--- --'-- 2709.34 SPECIALTY GASSES -- - - _- --
,. 101595 ALLOY DIE CASTING 157P.23 REFUND USER FEE OVERPAYMENT
101EAE T-E ALUNINUF ASSOCIATION 327.5: PUBLICATION
_ l R3.9] At h-COpYENTiOk-•Pyw- 3L4C.CC SEMINAR -
103596 POBCC INC. S/OP AFEVICAN SERI! 32.453.95 HARDWARE
10359- ANAPEIF SEWER CONSTRUCTION $12,36..73 SEWER REPAIRS DISf 11,7,6 2
ANCnD4-otCNI1tB-CO:-" 1279.2`. ENGINE PARTS - - -- - ---- - - - --
IP7643 ANIxTER - LIRE L CABLE 1270.3: ELECTRIC CABLE
IC!6.2 ANTMOkY•S CEC6. R MACHINE. INC 1259.5E MECHANICAL SUPPLIES
-_-- 2C16G3 APCO'-V,tV T'PPIMEP COPK 51,120..2 VALVE PARTS
IR.leC4 A-ALOS SYSTEFS $3.2-5.41 NOTICES 6 ADS
rn ILIAC% ASTPCIATEO SOILS FRSINEEPING. 16.264.A. SOIL TESTING
X---ICIff6" AWAPDS6TROFPICY--"'--_"-' 1149.6C SERVICE AWARDS
F .. . -. ..
i-. 10166E INLTI IRIAL I INC. 1976.4E HARDWARE
b.0 10166E FALCON DISPOSAL
T-SERVICE S761649..1 GRIT REMOVAL M.OJ-I3-BB
1C16C9 - BANK NA-9CUE-FRTYT--V"'-' _ fIS 3.A: BNEPRINTINC '- - -
� 151E10 BANK OF lxEP l[i-C.A.S.C. 3J7U.%' BOND G COUPoX PAYMENT
G6 HIGH BALK CV AKERICA NTLSA 3299.23 BANK CARDS
ICIG22 Pa.-BRROTTT-th"SSOG-" - 39.If D.c^ CONSTRUCTION'SERVICES'PI-25.26.-P2-32i33:36.3] --
F�; 161613 84PTO OIL CO. 3325. REFUND USER FEE OVERPAYMENT
101614 P. GATEMAN t575.. DEFERRED COMP DISTRIBUTION
1P1515 BAYTFR SCIENTIFIC PRCSUCTS SL lAA.22 LAB SUPPLIES -
111616 L'ILLIAM BELL 11K500.1P TREES
E• IP161? PEST BAP3ICADE 3122.1k BARRICADES
�'1 O161B -" -' -' PFST-WESTCRN->-SPtCF"OCF- fL'J18.05 REFUND USER'PEE OVERPAYMENT'-
m 1G1614 6ICCVCLE 1A4.P5 PUBLICATION
IOIEPC POI'A CASCACE OFFICE PRODUCTS 3547.29 OFFICE SUPPLIES
- ---161621 - 93LSA"RACTATO9-SrPVMF- - 192.64 RADIATOR REPAIR
]01622 POk-A-RUES 3111.53 TRUCK PARTS
lim! EPC! COMMUNITY nOEFITIC 31.2GI.A5 REFUND USER TEE OVERPAYMENT
PREIKTP-FTECCE-RRT-ASSOC.. IKr, 3T21.6H COMPRESSOR '-
IP1A25 PROCN L CALPWELL 1315.70 LAB SERVICES
_ 11162E PPCV6 ! CALLWELL CONSULTIN-r 31531921.61 ENGINEERING SERVICES J-23-I,P2-37
r" 1.3627 SUCH ARO AS"CTATCS. -Tr,C. t97R.': SURVEYING SERVICES -
., InI62E FA-Y G. STPEEC 3755.A9 FETTY CASH REIMBURSEMENT
IPIA29 PY-PFCOUCTS MANAGEMENT, INC. 145.S35.:4 FERROUS CHLORIDE M.0.4-12-89
-"-'ICI63I C A F RPORATITTONIN6 CC. $7,213.!1 SERVICE AL REPAIRS
101E32 CFT CORPORATION 57.211.5E SERVICE AGREEMENT
lAlE32 CS C4rP ANY 1321.14 OXYGEN SUPPLIES
FUND I:0 9100 JT LIST WOPNIJ19 CAFITAL FFOCESSING DATE 9/23/09 PAGE
PEFURT NUMBER AP43
�___.._ ..__._ .._._...-.. _..__..... ..___..._---_---.CCLLIY.SArJITATIDN DISTRICTS OF Oh ANGE CCUNTT
CLAIMS f>I[ -6/39/P9 POSTING DATE
_WARRANL NO. .....___. .. ..VEMDOP_ _.__ . AMOUNT EESCRIPTION ..__ ._ ._. . _._.. ..
1016!+ CAL-CLAS• FOP RESEARCH, INC. f679.97 LAB SUPPLIES
..-_13161• C40001. ,_16C.. 1L 993.TT OXYGEN PARTS
I SI 615 CAL TY-C CFFICE NACHIhLR. INC. 664.P! TYPEWRITER REPAIR
SDI IS6 CALIFORNIA SUPRESSION SYSTEMS 1269.21 MECHANICAL PARTS
101837 ..._GALS.CAYERR._. f1.046.E5 PHOTOGRAPHIC,SUPPLIES
ICIE3P CLO,IRICOE PLNUFACTUPINC 1357..`l REFUND USER FEE OVERPAYMENT
191639 CAFRO OIL CO. S4.!3 REFUND USER FEE OVERPAYMENT
1t-1N 4. .... . .CAKLCTCN_L1is"CERi—._._. . _ fL376.C9 AIR EMISSIONS CREDIT.COHSULTINC_..._--_ ._._.... .
ICIFel JOHN CAROLL0 ENGINEEF S 3A5r192.!2 ENGINEERING SERVICES 11-17.P1-20, J-15
161P41 CENTURY DATA SYSTEMS 11,461.5E REFUND USER FEE OVERPAYMENT
__.-1R1643 CENTURY-SAiEIY-1tiST..-1 HUFF., -1872.95 SAFETY SUPPLIES
_ 161644 CHEMWEET INOUSTkIES. P:C. 156,675.7- FERRIC CHLORIDE M.O.11-09-88
1C164! CME09Y TFYTO.CN $5,499.83 REFUND USER FEE OVERPAYMENT
'"1646 __ JEAN.G_.CNEVES---__ . . . 316u.41' _. _. . REFUND.USSR.PEE.OVERPAYMENT__
10164E CHEVRON U.S.O.. INC. $91413./C UNLEADED USER
OTGRPASH
10164E CIRCUIT.HOUSE
SE .. $363.72 REFUND USER FEE OVERPAYMENT
101649 CIRCUIT. _ - 3363.i1 REFUND USER FEE OVERPAYMENT
1CI651 CLAFN CONSULTANIS f6,$91.2 ENGINEERING SERVICES J-30
"fTl 101652 CLEMENT COMMUNICATIONS. INC. 647.91 SAFETY USER
--101652 SO66TALSOOMRUN331C5T-.... f4,647.91 REFUND VEER FEEOVERPAYMENE_.
1P169S COMPPESSOA fOM00 NCNTS OF CALIF 317r213.:9 MECHANICAL POT
S
.pD 101654 CONNECTOR TECH INOUSTPIES S2J5.12 REFUND USER FEE OVERPAYMENT
161655 CONNLLL -G.Mr04RT&-/-.DIV. - - 912S.40 TRUCK PARTS._.
11,106 CONSCLIDATEh ELECTRICAL DIST. $2,160.31 ELECTRIC PARTS
-� 141657 CGNSOLIDATED REFF.OSOAFHICS I!,d2S.!7 BLUEPRINTING
}--43165E--_ _.__. ._CORT-INCNSAL-GRAXMICS--- __ .. 31,7'9.9♦ BLUEPRINTING M.0..6-14-89 _ .... .
n1 ll']65^ CONTROL OSTR CORPORATION 1207.Sy TELEMETRY
REPAIRS
IeIP6C CONTPOLCO S143.IA TELEMETRY SUPPLIES
=.- . 10IS62 COSTA-MESA-AUTO-SUFPIY 3143.IM TRUCK PARTS
I016E2 CRA4TY WHOLESALE ORI ELECT0IC S834.35 ELECTRIC SUPPLIES
151E6! CAAOE VEY OP [OR[. 31,J6J.49 PIPE
..f119.AC RENTAL ft _
13166! RTE W&TEP RESOURCES CONTFGL f1,530.45 ADMINISTRATION FEE
301EEE CAML TORONTC . ._..
rF0 3$32.00 NOTICES
- ININC
-^ -10166E DAILY OF OlE ARMY —- - 2519.6G - ADMINIS 6 ADMINISTRATION
--�
301660 DEFT. OF TEE ARMY f519.CL ADMINISTRATION PEE
4016EF OREVPIN A,lC/CF CS CO. 61.211.P+ VALVE PARTS
mot
- - --DIATPE-006YMER9-ATES - - 12,R94.7C PRINTING
POLYMER M.0.8-10-M8...._._. _..-.. _... .___
101677 CISCO FAINT
ASSOCIATES 31,D64.E6 OFFICE
SJI67P DISCO FRINT COMPANY .659.4E CFF6E SUPPLIES
�- I01674 OOhADQ E9TERGCPS-. INC. 11$1,652.35 CONSFAINT ION
PI-05-1-1 .. .._. . ... . __
I01674 DU44 TECH
CPS-. f1,G51.19 PAINT SUPPLIES
I51675 OUOL TECH GROCESSIS,INC. 46 f51.1! REFUND USER FEE OVERPAYMENT
--301677 - -E A SERVICES, -CS6.OJ1.13 REFUND USER FEE OVERPAYMENT . . . _ _ .. .. _.
10167T CAA SERVICES, INC.. f26.952.OP ENGINEERING SERVICES J-13-2
- 10167k EA6TMAN, INC.INf. f1,6M1B.C: OFFICE SUPPLIES
FUND NL 91°F - JT Din WOkkil!G CiP17AL PIACESSING DATE S/2i/P9 "OF
AEFONT NUA'BF° AP41
-- ' - ' ---- -- ------ -- - ---' COUNTT" SANITATION 015TRICTi OF DFANGE COUNTY
CLR!KS PAID tF/311/89 ROSTI4T DATE :t/!1/P9
--F7RR ANT-40. - --VENDOR----- - AMOUNT DESCFI°710N - - -
lflf7° EDERHARP LCUIPPEAT 12.362.7° TRUCK PARTS
V: 'HP-[PCk Y--CORHr---"-- "' 1°15 aR6.17 CONSTRUCTION 2-26-2.2-27
1016F1 ECOANALYSTS. I4C. sa.222.56 CONSULTING SERVICES
rt IDIL92 EL PANCHO NORTH t31F.2. REFUND USER FEE OVERPAYMENT
-"-SPIER` ' ELECTRICAL-^YST"Sr-tTDA-- 51.215.:'P ELECTRICAL INSTALLATIONS - - - -- - --
IGI601 ENIRGY DIV• OF CIL 129P..IC REFUND USER FEE OVERPAYMENT
1C16FE EKGLLMAR[ INOUSTFIES f65G.L3 REFUND USER FEE OVERPAYMENT
Ir-1136P6"" "-EARSHALL FAICRr-- _' $11526.19 DEFUND ERREDUSER P¢DISTRIBUTIONT
:r. ST1A6F JOHNMF. FAIERES t313.+n DEFERRED COMP SERVICES
JION
1[1 AfF JOMN P. FALRENt-COP P.E. f3.560.'.: CONSTRUCTION SERVICES J-20. 3-7-4
FEDC RA L"E^°PC'Sfi'CORY:""' 3220.5f AIR FREIGHT
10149E FEPkELLNAS 19.7- PROPANE
101F61 FILTER SUPPLY CO. f2.376•?5 FILTER
n--101691 ' FfYCNC-690sif P"CPa- "' 339.923•66 CHLORINATION PAR'f8-'- ' -'-_"-'-'---'-' - ----'-
... 1016°3 GELBER PUXFS. INC. 2954.:2 PUMP PARTS
1CIf9A CLIFFORD A. FORREPT t1.56O•Pt ENGINEERING SERVICES PI-33
---1P1f^! FOVNTRI N-YRCCLT CAMERA- f]S.tC FILM
T 1D14°F DONALD L. FON A ASSCCIATES 21.815.H6 SAFETY CONSULTANT
X-_1C1697 FUSCOC. VILLLIAPS, LINISPEN A 1532.77 CONSULTING SERVICES - SEWER ABANDONMENT
_S
]P1S9P """- GSX"CHRPOR"IOM-'""""'" - S77L.PC VACUUM SERVICES
Self'! GATES FI CJEE CON V. TALLE IIR6.2L REFUND USER FEE OVERPAYMENT
l77 IPI771 GATES FIBS°CLASS ICC;ALLI 114.065.If TELLS
7^1 T21 G[N ERAC TCL(PNGY,E 'CC:- SP006.E' TELEPHONE '-
1P1742 GECPGE LEECH a ASSOCIATE.- SSE7.75 ELECTRIC SUPPLIES
( 1°1703 GERARDS 1-070 LA5 IS.`.? PHOTOGRAPHIC SERVICES
P-101701 " " "" - "'CON-GR EEK'F-ASSCCIFTES'---""' "' _ f7F165.75 SURVEYING SERVICES' _.... .__.. .._
Viic1 1E1705 CRINIIELL CLRPORATIOP, $22.12 FREIGHT
1677C6 CHANCES G. NARCY, INC. Il6E•PF BUILDING MATERIALS
IC17C7 FR[]' A. HAPo[R-' -' t1.950.CC DEFERRED COMP DISTRIBUTION
13174F. MATCH A MIPN• 111C• IIS3.N MECHANICAL PARTS
o 10114° S. A. HEALY CO. 9310N22.13 CONSTRUCTION PI-33-1
-TC17]" -"-P[PiR IA N-/"ASSOC:i-?NC: - S89E924.11 CONS1FOCttOX R-027-161
MISS HILTI. INC. 1521.3E MIXTURES
n. 101712 HOPSIT INTERNATIONAL 1363.11 TRAVEL SERVICES
- -- 1?173? . _._DON aLC"O TNOMOPICPC.. . . 737-+." DEPERR¢OCONP DIEIREBUTIOX_..
,. 291724 HOD-ER CAMERA STOPES I702.°.'. PHOTOGRAPHIC EQUIPMENT
I P17:E HOUSE IF BATTERIES s15P.•2 BATTERIES
L-----T777E'_______F:S:-NUGHET'"CO:.-INC:.-._ f2.356.55 SAFETY SUPPLIES ...._.. . . ._._.._. _.._.._.-..
111717 CITY OF MUN71NGION PEACH 515.51 WATER USEAGE
1C1 TIP HUNTINGTON 6EAfH CO. f191.92 REMO USER FEE OVERPAYMENT
s - 1C171° - MUST7NGTOq BEACH CO; f03.2? REFONO USER FEE OVERPAYMENT
• 1C.72:' 4U%YlkGT01( PEACP PU68ER SIAPF 99.:L RUBBER STAMPS
102721 HUNTINGTON PONCA tt.969.1E GENERATOR
`--'I 5177i '"- PYki T--0 iE T7^T-"-'--' - -' - f631.2F REFUND USER PER OVERPAYMENT
101723 ICT CDRPCP'TIOt 382.10 LAB SUPPLIES
u Spill. ITT CANNON LLCCTPIC I2.721.21 REFUND USER FEE OVERPAYMENT
FUND NC . - JT LIST WCFKINV CAP174L CA6L:S51NC CALL A123/89 FAGS 4
^EF'OCT NUMBEP AP43
_.. _.. .._.... .,__ _ _._.-_ . ...... . COUNTY NA%ITATION DISTRICTS OF OPANEL COUNTY
CLAIS5 PAIG IP/SC/84 POSTING CATS
_WARRANT. NO. ._. _. ._. ___.VENCOP_.___.._ . . AMOUVT DESCRIPTION
351725 INDUSTRIAL THOEADED FFCOUCTS 53.597.!' CONNECTORS
__-.101726 . .I GRAB PAF EE__ ._.. . .. . 31..93.47 JANITORIAL SUPPLIES
IP1727 INSIDE F C.t. YFEILY PE-CAT $22.00 PUBLICATION
101728 IPN COPPORAIION 33.997.26 COMPUTER EQUIPMENT
'_._122729 .. .._. . . IRVIME_RAXC_.9A7EA_UIS7RIC7 .. $18.41 WATER USEAGE .. ._._ _...
1117lL RIVIERA FINANCE 2712.14 JANITORIAL SUPPLIER - - -- - --- -
1-.1771 JOHNSON I MIGG14S s6.U020t. CONSULTING SERVICES - DISABILITY PLAN
_4 A.-732 . . . JOMSSTDWE_BURBLY_._..__.__.__. ... 322.CL ELECTRIC PARTS
I1 1773376 JONFB t STOKES ASSOC..INC. 45973.42 ENGINEERING
SERVICES PONT
B 88-27
3STt KAM SCIENTIFIC INBTPYEgT6 CO 3971.51. LAB SUPPLIES
KAMAN REARINL L-SUPFLY 541.7. FITTINGS
12273E
.. _
LNEP COMPANY f2r1760F INSTRUMENTOREP
171737 Ksv-PAY. INC. f225 AP INSTRUMENT REPAIR
-121736 T.L _KCIIM_CGNR6ClL6_.__. . .. 66.456.L1 .. ENGINEERING SERVICES 5-35.36..
151 T!S KIEWIT PACIFIC CO. $552.b6U.75 CONSTRUCTION PI-27
KITE- KIN-. BEARING, Ike. s1r824.F7 MACHINE SUPPLIES
1F.1741 DONALO. C. KINNEY _ $815.uC DEFERRED COMP DISTRIBUTION
'7 1017t2 KIRVHILL RURBEP 1391.E5 REFUND USER FEE OVERPAYMENT
.m IF174! MARTIN KONLICK. IF 31.539.CC CONSTRUCTION SERVICES 14-1. 5-34-3
- --00R744. L.i.-k_-UNJF-ORP_SUFPLY.CG 32.66D.F2 REFUND USER FEE OVERPAYMENT_. .... .......
-= IC1715 L.A. LIGUID HANCLING SYSTEPK f678.PF PUMP PARTS
,�bD 111746 LA-PELLE-MA-VIN 51,038.7E CORE DRILLING
l0174v7 LAF-SAFETY SUPPLY OD. 132A,1t. LAB SUPPLIES
-� ICl74R LACEY CUSTGF 575.16 REFUND USER FEE OVERPAYMENT
f") IC17A5 LIEFERT PSSEC167ZS OF 5592.6E ELECTRIC SUPPLIES
_._.LIKITZ"UE-COP" ----.. ___._.... _ 41,26A.36 CATE REPAIR
.L� 111751 LOTUS YEVEL. CALF. 1159.•.' COMPUTER LSOMME
SUPPLI
P 101752 A.J. LYNCH CO. }$32.t4 JANITORIAL SUPPLIES
- - 101753 FPS.-1 671.71 PHOTOCOMPUTER ACC SSORIESB.
I T1755 F-T•K. $I.E]A.Y] ENGINEER NG SERVICES
101 755 KALE OLM PIF niE INC. 114r085.5t ENGINEERING SERVICES PI-25.26. P2-12,33.74
Iof P1757 -MARVEL-{OOLSR04it5---------- - 3108.2E INSTRUMENT
AI PANS.. _._-_ .__.
P• 10I759 MASTS- TOOLS SEPVIC ES S35.65 TOOL REPAIR
10f IS- PLTT CMLOF. INC. $2,446.16 CHLORINATION PARTS
-- of IS- MCFAPLANCh6r.T IT IONS- 16,177.67 OFFICE IMPROVEMENTSC17 ._.
I SIM MCKENNA ENROL d EODIP. 36$495.14 INSTRUMENT
PARTS
UMENT
�+ 1O17A7 MCOLIN CONROLB CO. 5495.15 INSTRUMENT INPPLIE6
,.•----le2762 - MITCHELL-{INPUT$.-_INC. $6.397.65 OFFICE MACHINES
1P1764 NITCMFLL 471CP L}• STU S12o.64 COBLICATION
NSTRUCTION
101765 MLADEA EUNIICN CONSTRUE 7101. CO f3$1,165.36 CONSTRUCTION 3-28R-1
-- - - ITT 766 NOTION CNV LAHORSTOINC. i1.169..:. LAB SERVICES __ .. _. .. .
191 IF,7 M/TI01: IN pISTF1E5• INC. 31.162.1t MECHANICAL PARTS
19176] MOTPFOLA♦ INC.� f]. . BATTERIES 6 CHARGER
76i - - NOTIONAL {ELLUI AF SFFYICES $12.45 49 CELLULAR TELEPHONE SERVICES. -_. ..... _.� IC17E9 NATIONAL LOYB EA 1527521.42 LUMBER
� ICE T7: NATIONAL PLANT SERVICES, IFC. fL 123•CL VACUUM TRUCK SERVICES
i..
Nf�
-- FUND NC 51-- - JT GIST y04Nih[ CIFIUL FFOCESSILG 'ITS 4/23/0D FAGF
RFPCRT NUMB`-0 AP43
COUNTY SOMITOT10h DISTRICTS OF CRANGL COUNTY -
CLAIPS FAIC 'P/30/89 POSTING LATE l9/31/Fe
VAPRA4T-NO. ' -VEkCOR - AMOUNT DESCRIPTION -
101771 NEW LONAMEL 517.92 REFUND USER FEE OVERPAYMENT
-'_- " _-19177? NEU LONOMEY - ------ -- 19V.31 REFUND USER FEE OVERPAYMENT
102773 NEWARK ELECTRONICS S195.77 INSTRUMENT PARTS
101774 NEWPORT CTP. MEDICAL BLCG PI S52.SE REFUND USER FEE OVERPAYMENT
--"Ir3 775 kEV^OPT CENTEP-MECICAL`<2` S25P.ZP REFUND USER FEE OVERPAYMENT
11177F .IEyPORT NA0EOR ADOLESCENT f41.1P REFUND USER FEE OVERPAYMENT
ICI777 0. C. POWER 5495.`.? ELECTRIC PARTS
---7 C]77P C4ro7SR' . ...-._____..-._ --- ..S11716.:o TRASH REMOVAL -. .- . .--
11177S C•DONN<L 31L s118.1: REFUND USER FEE OVERPAYMENT
1017EC OCCUPATIONAL VISION SERVICES $224.41 SAFETY CLASSES
OCEAN SALT 'CC::-INC.-" S364.61 SALT -
IC17E2 OLYMPIC CPE-ICIL CC. 345.681.61 CHLORINE MO.0.10-12-88
1037E3 Ofif DAY Ptlla L EDDY SIS1.41 TRUCK REPAIRS
,T--7717Ptr Oft•LINE'-'E't CCTkORi'CS'-"' -- 3191.7.' ELECTRIC PARTS
i. 19176g ORSNRC COAST ELECTRIC SUPPLY 3256.52 ELECTRIC SUPPLIES
1C17ES ORANGE COUNTY AUTO PARTS CO. 9798.43 TRUCK PARTS
3C17P7 Of YSCN SERVICE - S1.263.61 SPECIALTY GASSES - -
10!7FP COUNTY OF GRANGE 55-1.E25.` DISPOSAL CATS FEE
IL17F^ COUNTY SANITATION D13TP1[7 113.9. DEFERRED COMP DISTRIBUTION
COUNTT-SRkITAT10k-C ISTR]C1 112.3a g.aE REIMBURSE WORKER'S COMP INSURANCE FOND
X
Z 101701 PACIFIC AMEFICIN OIL $263.71 REFUND USER FEE OVERPAYMENT
I"792 FACIFIC PARTS 3217.-S ELECTRIC PARTS -
7Ccl--'ILI793 PACIFIC
eFOCEBS-CFVIPPEMT:I•:C. f2.1l 3.31' MECHANICAL PARTS "--- - '_ "-
.: � IT 1795 PACIFIC SAFETY E4 UIEPEHT CC. SE.9L 3.Po SAFETY SUPPLIES
11179C PACIFIC BELL sE4f.71 TELEPHONE
='C1 "-70179E"' - PARTFT ENGINEERING PCOMPAN-'-- -_ S1B4.^6 REFUND USER FEE OVERPAYMENT'
u: l IC179F PARTS ENGINEERING COMPANY 1266.26 MECHANICAL PARTS
7� IC17" FAITS UkLIRITEO 5266.i6 TRUCK PARTS
SE
-- " ' ]M.1 tee oEeT4 M:Ry1CN: kA1N 8 CO. 151.4i.^1 DEFERRED SERVICES U
.. 1L1F^f RCY FENDEFGFAFI tagF.,: DEFERRED COMP DIStRIBUTION
101F51 PICKLICK FAFEP 1125.F1 OFFICE SUPPLIES
7 C1802 "P I P A-GR 0'ST eT FPS:'"IRC Z 544.A:9.6' SLUDGE REMOVAL M.0.5-11-88" " --'-
101263 POLYPUFE. 1'.C. 323.082.04 CATIONIC POLYMER M.0.3-8-89
m 1C1FC4 PORTER BOILED SERVICE. INC. 142.7- ELECTRIC METER
E'- Wets POLED PATTERT' CO.i-TNC:" 11,112.0E BATTERIES --
_ IQISL'S PPECIOL'S PETALS FLATIL2 520•12 REFUND USER FEE OVERPAYMENT
1i1P07 MAROLC PPIMFO6E ICE 5225.:F ICE
--I Ci 90 E' 74C"PROJECTS_SILUTTON CO. S3159O.;J INSTRUMENTATION INSPECTION M.O.'8-10-68 - -'
. 101F,- GUEST INTL. MON'ITGA SEPVICF S255.1^ MONITOR REPAIR
101L19 9.C.G.F. S92..7: INDEXES
.T ^IP11 REMFCV"TE 4: _ '- 43 d}<.rl TEMPORARY SERVICES
7
IM1P12 TMC REPUBLIC SUFFLY CO. SS.51LE1 FITTINGS
l Ol Pi' J. P. POP.ENIS CORP. 1331 CONSTRUCTION J-20, J-7-4
f.-••"- '101014 POSIF.SON FCPTTC]ZFP-CGS'- 119111,45 INSECTICIDE '-
IclelS ROYAL 14OLESl LL ELErTRIC /S.4T5.75 ELECTRIC SUPPLIES
r 1D1P16 4YrEP 74UCK PEI.IAL. INS. $2.2?7.4S SUMMER CREV TRANSPORTATION
FUND NO 919c - JT DIST WORMING CAFIIAL FROCESSING DATE 8/23/R9 PAGE
REPORT NUMBER AF13
[DUN IT_3 AH 11A710N 01ST81CTS_OF. ORANGE COUNTY___
x CLAIMS FAID CE/39109 POSTING DATE ut/3t/99
' uEppnR OVER___ ROVE ... .MOUNL. .. ..... OVER DLSCP.I?T10N.___-
'1 391917 JOSEPH T. RYERSON S SON. INC. $2,387.22 STEEL
0.•.. SANC03LENDINEERLUG_"&C.. . ROVE..512.301.1''. - -.ENGINEERING SERVICES-2-7
101P19 SANTA AMA RIVER FL000 S1.1OO.G9 ANNUAL DUES
101P2d SARGENT-WELCH SCIENTIFIC 1191.15 REFUND USER FEE OVERPAYMENT
35.2DO.00 _OVE R EMERGENCY.DEFESRE2_CONLWIIWOSAWAL._ -_
.i 101022 SCIENTIFIC SPRAY FINISHERS f212.51 REFUND USER FEE OVERPAYMENT
141P23 SEA COAST DESIGNS 61..22.29 OFFICE FURNITURE
O1P29_____SHAtl50[E.SDPELY_
1I1P25 SIMPSON STRONG-TIE CO $93.51 REFUND USER FEE OVERPATHIUM
IDIE2E SNYPARM PALM-111 MEDICAL CLINIC 53.798.0I PHYSICAL EXAMS
01$2L--.._ _..S O I L AIIC_SEP3INEEN6 INECR4__.- _ OVER ROVE.-.$435.06 _ SOIL TESTING__.
IOIP2R $0. COAST A1P OUALIT> $12,591.9. PERMIT APPLICATION FEES
131E25 SOUTH COAST AIR OUALITV 1115.RF PERMIT APPLICATION PEES
01Al0---- --- SO« P COAST DODGE $174.27 -- EERMILAEPLICATlnw wva
101 P 32 SOUTH COAST ODOGI 3171.21 TRUER PARTS
1O1P33 SOUTHERN CALIF._ EDISONCOUNTIES.
CO. s113.571.11 POWER
OIA33 - - _..._...SOUTHERN_CREGIONAL LA-CR......_.._. _ _ . .f1.937.L7 DIESEL FUEL
-! 101036 SOVTMYETT REGIONAL LW97ER TORY 3550.12 REFUND USER ER OVERPAYMENT
^' N' IO1F39 SPARx LE TTE CRINM ENO VA 1EP i1.550.3^ WELDING-
WATER
x
_ -ASK3F-------RREC-7ECH-YLSiCW ----ROVE.._ -. _. .591.6E --OVER SCALE G_SNTENANC-__
101937 SPEECO s$75.2P SCALE MAINTENANCE
„I 101036 SPEED[ SPEEDOMETER 375.7/ DRIVER TESTING
IOOLB
C .._C-1 ��� IIP90 SUNSETMMIT STEEL 33.517.R0 RCE
TRUCK
1^1061 SUMTCT FORA 33fi6.6P W.S PARTS
-0SY3 3URJ:'LO CUT --- - - -S$20J0 - -----LEWD USELt-.___
101E13 ?HE
CIRCUTS 739.12 REFUND USER PEE UVEVAYMBM'I
131E61 -TWE SUPPLIERS .iS9.95 FOOL REPAIR/TOOL6
-ICIFIR------ GWEDLOWNp-40.----- _... .___._ . _ 14,723.43 FI=IREFUNDGS_-_- --_
�! 101F66 SYSTEM $119723.53 REFUND USER PEE OVERPAYMENT
uI IOIR67 SYSTEM AUTO MASH 3505.5E REFUND USER PEE OVERPAYMENT
0iP16 TAM--IAMDUIM: -OVER ......-___,103.06__ ._ _..__--CONTRACT.CART
io3fi4g TAYLOR-DUNK f191U1.7V ELECTRIC CART PARTS
1 P1R50 TEL-A-TRPIN 3620.7D VIDCO RENTALS
f90S1-��----��-TILLINGHAST MSNAi------- _. -- _11.E65.36 ELECFILM RINTLREPAIRS-_
aI 101F52 TOWNE CENTS 5615.00 FILM RENTALS
191F53 TOWNS CENTER PLAZA .926.9N REFUND USER FEE OVERPAYMENT
OIE56 :RAVFbPERAVFb ----------. .. .. ....__-_.i19916.U0 ---- -- -INAV6LSERVICE6-
�� 101856 H.O. TPERITO CO. 5612.96 TRUCK
PARTS
10185fi TRUCK f AUTO SUPPLY. INC. SAS9.15 INSTR PARTS
i 01P57-------J.6.-TU6NF F-M-fON.-I NG.------ �- - - -� �� -- f6P3.V6 ....-.....INSTRUMENT SUPPL28S------ ------
��! lOIFS8 U.S. RENTALS 3132.DL RENTAL EQUIPMENT
11I059 POSTMASTER 116.I5 REFUND USER FEE OVERPAYMENT
0l4fiB- -515.44 ---- ---REFUND USER FES OVERPAYMENT- --
101061 UNION SIGN CO. $1N90.54 SAFETY SIGNS
103862 UNESTRUT LOS AADELES $36.76 METAL
s
i
FUND N6 91-- JT DIST YOPKING CSFIIAL PPCCEESING DATE b/23/29 FAST 1
PEPCPT NUMSC4 AFA!
- —MUk1V-SANITATION-019TRICTS-OF GRANGE COUNTY -- - - -• ---• -----------
.
.I -- CLAIM'S PAID J!/30/69 POSTING DATE 'f/39/9F
�•
„�YPRRIIHT-NO's"-•-.... ..-.. _. ___-Y•NOB►---.._... ... AMOUNT - CESGP IPT tON- _. .._. ....-.. .___.. _.__..._
,a IClff3 UNITEC PARCEL SERVICE 5276.2• PARCEL SERVICES
UR'DPN ALTERNATIVESONSTk--.__. .._._ . . - 15 . S .. _...._ _ ... _.. .
101P66 URBAN ALTERNATIVES S2M793.O0 LAB
SERVICES RE8 89-66
Ir' 1C1666 VYN SCIENTIFIC SI.746.B! LAB SUPPLIES
th�Y____.-Yp CtTT'ttTTCYPtlpKT<'OP-.__.. ._ .SSr/96./s .. PItTTNCB.....
lid 1Dim VAN WATER C ROGER$ 1362.76 CHEMICALS
1'IF" VACIAN INSTRUMENT GROUP 31.447.6% LAB SUPPLIES
3'O1PTC------VCKTTV- SV'S'TTMS------' - $BNIS.00 COMPUTER DATA-SUPPOR4------ - ------ -----
IDIP71 VIRING INDUSTRIAL SUFFLY 1798.47 SAFETY SUPPLIES
nr' ICIF72 VILLAGE NURSERIES S4702 CRDUNDCOVER
191'R73" ' - ' V;-;'EUtiUT------'- ' --- 912.15 REFUND USER FEE OVERPAYMENT -- --- --------- -
IDIe71 WALLACE S TIERNAN S2rMU3.4a FITTINGS
lu 101"S CARL YARPEN S CO. $363.66 INSURANCE CLAIMS ADMINISTRATOR
—297b76'-"'"" --" YEMrCPDTY�/--PURi'TiN�THfMCiI--' "' _"-'- 5173.13 REFUND USER-PEE-OVERPAYMENT '------
L.I 301M17 YESTCRk STATE CHEMICAL SUFFLY 951r18R.115 CAUSTIC SODA M.0.8-10-80
6" IC2076 WEST-LITE SUPFLY CO. $165.74 ELECTRIC SUPPLIES
Ll'ilm—'--'--'VMT7TTY'Fllt'S-YCRtlItK--'-""---" " ' SI0P919:21 - LEGAL SERVICES--------"'---- - -'
na 1e1 B99 YILLOAN ASSOCIATES 68.215.2/ ENGINEERING SERVICES J-26
m (Olen YILSOMrS EAUIPMENT RENTALS,INC $9,967.34 CONSTRUCTION SERVICES DIST 3
tun..---ROURNET 133495IV39' - LEGAI SERVICESW.0'.6-4�89-"-'---
M'o-... 1C1883 SEPnp CORP. $219SO.A2 COPIER LEASES
P-'TV 101fB4 YOPFA ORANGE 6ROYFp3 1359.31 REFUND USER HE OVERPAYMENT
ui ZO1FR3-'- -""""7i[T'BMN-ANLrFiPCR- ----"""" " " S41Gi738:10 CONSTRUCTION P2=37"""--------- "-_ -"-'-'
ue lolm RICHARD 8. EDGAR 1201.. DEFERRED CORD DISTRIBUTION
P
• f7 -----------------
�a•'V TOTAL CLAIM! PAID AP/3-1/pc $5.636r747.6P
La
M,
Rd
FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE OB/23/89 PACE 8
REPORT NUMBER AP63
_ CON" SANITATION DISTRICTS OF ORANGE COUNTY
' CLIMB PAID 08/30/69 POSTING DATE 08/30/89 - --
a
rI SIROIARY __--_--_ _—.--_ _ ... . AMOUNT. . .
•�• fl OPEN FUND f 63.92
/,.OPEN FUND__ . . .. _ 13,762_76 _
%2 ACO FOND 924.337.33 ---- -- --- --
u:
/3 OPER POND 21,058.37
'•l /5 890 PIRD
a•I IS OPEP POND - —�-6,092.34 -- -----
I f5 ACO FUND 7.790.90
" i60PER.F.Oxo ._._ _..__ .27.59
16 ACO FUND 96.00
R' f7 OPEN FUND 10.155.62
�1e' II J'90.FOND___ __._. .- --.__ .... _.312.90_. ._._.._._
'•1 III OPEN FUND 6.467.16 - - -------
['' III ACO FUND 13.336.36
.I8.41
Old ACO FUND B,257.05
6. X 1566 OPER FUND 4,076.10
1566_ACO FUNK __ 7,915.92_
I"T0667 OPER FUND 35.88
� tp 07614 OPER FUND 3,508.67
k.
�JT-CPER_FUNO—._. __ __—_..._. __ 965.636.18_..
COIF 3,092,224.63
N[ SELF FORDED WORKERS COMP INSURANCE FUND 13,434.69
N' 3T_DIS'LWORKIR0-AF1TAt __... _ I8j,A06.9Z_.
i 5,636,747.66
»
Ian. _••_ _ _ .. .
REPORT OF THE JOINT CHAIRMAN
i
OCTOBER 11, 1989
1 ) UPCOMING MEETINGS
A. EXECUTIVE COMMITTEE - THE EXECUTIVE COMMITTEE WILL
MEET ON WEDNESDAY, OCTOBER 18TH AT 5 : 30 P.M. , TO
HEAR AN INDUSTRIAL WASTE PERMIT APPEAL.
B. EXECUTIVE COMMITTEE - THE EXECUTIVE COMMITTEE WILL
MEET ON THURSDAY, OCTOBER 26TH AT 5: 30 P.M. THIS IS
A CHANGE FROM THE REGULAR OCTOBER MEETING DATE OF
OCTOBER 25TH DUE TO A CONFLICT WITH THE LEAGUE OF
CITIES CONFERENCE.
(INVITE TWO OF THE FOLLOWING DIRECTORS TO ATTEND: )
GRACE WINCHEL
AND
EDWARD ALLEN
_ OR -
(MARGARET ARNOLD)
C. CONSERVATION, RECLAMATION AND REUSE COMMITTEE - THE
CONSERVATION, RECLAMATION AND REUSE COMMITTEE WILL
MEET ON WEDNESDAY NOVEMBER 1ST AT 5: 30 P.M.
QG
-END OF REPORT-
-1-
MEEriNu DATe• October 11, 1989 TIME 7:30 P•H•DISTRICTS 1,2,3,5,6,7, 11 13 a 14
DISTRICT 1 '" JOINT BOARDS
(CRANK)........HANSON...... We Y (VERELLEN).........ALLEN.......
(YOUNG)........GRISET...... (KANEL)............ARNOLD......
(KENNEDY)......HOESTEREY..._ (GREEN)............BANNISTER...
(ROTH)........fB7RNECN....... x— _ (WEDAA)............BIGONGER....
(NORBY)............CATLIN...... _
DISTRICT 2 (HART).............COX.........
(PERRY)............CULVER...... _
(GRAHAM).......MAH ONEV.....✓ (KENNEDY)..........ED
GAR.......�_
(NELSON).......RBRS....... (CHESSENI..........GR IFFIN.....,C_WJwmr'A'i
(WEDAA)........SIGONGER.... (YOUNG)............GRISET...... ✓ _ 4 OA'/S3
(NORBY)........CATLIN...... V (CRANK)............HANSON......�C
(YOUNG)........GRISET......✓ Y (KENNEDY)..........HOESTEREY... v
(SCOTT)........NEAL........3G y (NELSON)...........!!llG.......
_
(DOWNEY).......NEWTON......yG (EDGAR)............KENNEDY..... I/
(CULVER).......PERRY....... (GRAHAM)...........MAHONEY.....�
(HUNTER).......PICKLER.....W_/ (SILVA)............MAYS........�C
(FASBENDER)....SILZEL...... (SCOTT)............NEAL........JC _
(BAR RE RA)......SMITH....... (WEDiN)............NELSON......JC
(ROTH).........STARYLN.....� _ (DOWNEY)...........NEWTON......��
(CULVER)...........PERRY....... ✓
DISTRICT 3 (HUNTER)...........PICKLER.....�/
(HART).............PLOWER..... ✓—
(DUKE).........POLIS ...... ✓ (DUKE).............POLIS.......—L;� _
(WEDIN)........NELSON......57 (STANTON)..........ROTH........ ✓
(VERELLEN).....ALLEN.......✓—`_ (ABRAM)............SHERIDAN....Z'
(KAHEL)........ARNOLD...... ✓ (MILES)............SIEFEN......J�_
(GREENI........BANNISTER...� (FASBENDER)........SILZEL.......
(NORBY)........CATLIN.......XG (BARRERA)..........SMITH........
(PERRY)........CULVER....... .........i•TiKiBM.....
(CHESSEN)......GRIFFIN.....JC y HART B )......•• ".....�—
(YOUNG)........GRISET......22 X_ OR)..........SWAN........?
(GRAHAM).......MAHONEY......L.,!: _Y-- _ (WAHLSTROM)........SYLVIA......JC_
(SCOTT)........NEAL........� (FERRYMAN/GREEN)...WAHNER.......
(HUNTER).......PICKLER..... (BIGONGER).........WEDAA.......�
(WILES)........SIEFEN...... (ISLES)............WEDIN....... ✓
(ROTH).........SIN""...... _)L — (GRGAS)...........IAFtBBNr.....
(WAHLSTROM)....SYLVIA......J,, Y (BANNISTER)........WINCHELL....�/_
(SAGAS)........Wik6BN.......aC-L .
DISTRICT 5 STAFF:
SYLVESTER... ✓
(HART).........COX......... ✓ y BROWN.......
(HART).........BigllN99*..... ANDERSON..,LJC
(STANTON)......ROTH........7 Z CLARKE......
CLAWSON.....
DISTRICT 6 DANES.......�
FILECCIA...._
(FERRYMAN).....WAHNER...... HODGES......
(HART).........PLUMMER.....� �
KYLE........JG
(SiRNTON).... ..ROTH. ....... V LINDER......
OOTEN.......
DISTRICT 7 STREED......J�
V 0 N
LANGEN JC
(BARRERA)......SMITH....... ✓ WINSOR...... \�
(KENNEDY)......EDGAR....... iw v vItw"wr
(YOUNG)........GRISET......IG V
(STANTON)......ROTH........L _Y
(AGRAN)........SHERIDAN...._Wl
(COX)..........9"WM......Adt. _
(GREEN)...... ..WAHNER...... OTHERS: WOODRUFF.... ✓ �yL(,.tiW.}.
DISTRICT 11 IDE.........?� y�yM
ANWAR.......
(BANNISTER)....MANS........ ✓ FLEMINGDEMIR .....J� `.
(ROTH).........WINCHEL....... FLEMING....._�C
(ROTH).........GiAMiBY.....JC HOUGH. .....
_
HOUGH.......
DISTRICT 13 HOWARD......
HUNT.......
NT........
( .....WEDAA....... KOPF ......
(HUNTER).......PICKLER.....✓ LINDST .....
_(STANTON LYNCH.......
A RA) O(BARE ......SMITH....... STNE.......A SON(ISLES)........MEDIN....... WYOUNG.. .. ..
DISTRICT 14
(EDGAR)........SWAKENN........JC
(MILLER........KENNEDY..... ✓ _
\ (STRNTBN)......SROTH ....HERIDAN iW-ag. �
(AGRRN)........SMITH. ....J�
(BANRERA)......SMITH.......JC_
r '
PUBLIC SIGN-IN SHEET
./ COUNTY SANITATION DISTRICTS OF ORANGE COUNTY
BOARD MEETING
NAME ORGANIZATION FIRM
Please Print Please Print
Al)PXA0 S AvEI a-4 f�LAT/N 6
131u r-v fvwvµ'--- Yawr,j k 4gvuwlol,w
h�
,46
QN-r N i4orm
aµL A/lE NztS sisGiv tip 6�.vif,
LAA =Df d MlaoDAI/ FF
LICK W So2. CSDOL
6 lZlcllx 21 ,i -oV O/vr6,^25 CKG
t( c U to 9_s.
me
Pmp . J ,Lvc -
T cL
F31
10-11-89 JOINT MEETING NOTES
N6(a) - Report of the Joint Chairman
(SEE ATTACHED REPORT)
N6(b) - Report of the General Manager
The General Manager reported that all of the Directors should have received
under separate cover a copy of his annual report (21 pages) summarizing the
Districts' accomplishments last year and outlining goals and objectives for next
year. He commented that it would give them a pretty good overview of some of
the things that are going on right now.
He then reported that President Bush had nominated Lujuna Wilcher to be EPA's
new Assistant Administrator for Water. Mr. Sylvester added that he happened to
be in Washington, D.C. last week and had the opportunity to meet with Lejuna.
For the past three years she has been in private law practice and represented
local public agencies in environmental matters. Thought that background would
serve her well and hopefully bring some balance and reason to the
administration. Quoted from press release.
Mr. Sylvester also reported that EPA Region 9 has advised us that we will be
receiving their award for excellence for the third year in a row. Read from
their letter. He added, as you know, our wastewater management program is based
on providing advanced primary treatment to all flow and secondary treatment to
half of the flow. We have been able to demonstrate that our program is very
effective in protecting the environment. Our operations were placed in
competition with the top full secondary treatment plants in the country by EPA,
and we have been informed by EPA Administrator Reilly that our partial treatment
program took second place when put up against the best full secondary plants in
the nation. We will be presented the award next week at the WPCF Meeting in
San Francisco.
With any luck, we will be conducting our first Board Meeting in the new facility
new month. Will let Directors know when mailing the agenda.
N6(c) - Report of the General Counsel
The General Counsel reported that there was a rather small article in the paper
last week regarding EPA's enforcement program. EPA announced that they were
undertaking a massive enforcement program. They announced last Spring that they
would be making the presentation the last of September. They named 61 agencies
of which 4 were major cities--Philadelphia, Detroit, E1 Paso and
Only three agencies were in Region 9. EPA has made it clear that they expect
all POTW's to engage in extensive pretreatment programs. Our enforcement and
Pretreatment program is considered to be one of the best.
With regard to Beatrice/Hunt-Wesson, the first court hearing is on October 25th
relative to the CEQA issue.
We have an appeal hearing for UCI next Wednesday evening which is different from
Beatrice. It is based on violations of the Districts' ordinances. It is an
..i appeal of the decision of the General Manager.
REQUEST TO ADDRESS THE BOARDS OF DIRECTORS
ALL PERSONS WISHING TO ADDRESS THE BOARDS ON SPECIFIC AGENDA ITEMS
OR MATTERS OF GENERAL INTEREST SHOULD COMPLETE AND SUBMIT THIS FORM
TO THE BOARD SECRETARY PRIOR TO COMMENCEMENT OF THE ARD� MEETING.
..i AS DETERMINED BY THE CHAIRMAN, SPEAKERS MAY BE DEFERRED UNTIL THE
SPECIFIC ITEM IS TAKEN FOR DISCUSSION AND REMARKS MAY E LIMITED TO
FIVE MINUTES.
DATE: /19 '/A 04, AGENDA ITEM NO. 2
x x x x x x x x x x x x x x x x x x x x x x x x x x x
NAME: (PLEASE PRINT)
HOME ADDRESS:
NUMBER STREET
p (CITY/ZIP CODE
TELEPHONE: a ��- /4 _7)
REPRESENTING:
ELF OR NAME OF ORGANIZATION
COCA
#11 - Award of Job No. P1-33
Tom Dawes reported that this project is for 60 mgd primary treatment. It is the
single largest construction project that has been awarded by the Board. These
facilities will be covered and used for parking and storage. Includes new roads
..� to Garfield Avenue, digester cleaning beds and outlet pipes 108 inches in
diameter. Goes down Garfield and joins the outfall system at Plant 2. Also
includes additional odor control scrubbers and polymer facilities. Seven bids
were received. We were very pleased to receive that number. The Engineer's
estimate was $46 million. Bids ranged from $39.7 million to $46.5 million. Gust
K. Newburg Construction was low bidder. They have not previously worked for us
but are a very large company and work all over the U.S. Have projects ranging
to $500 million. Referred to a brochure on the company. They do have a project
in the City of LA for $84 million to construct a new headworks. Their work is
pretty high quality. Recommended award to the low bidder.
#12 - JCE Agreement re Jobs P1-36 and P2-42
Tom Dawes reported that this project is for the first new major construction
design contract to come out of the recently-adopted 2020 Vision, 30-year Master
Plan. It is for the expansion of existing secondary treatment facilities at
each of the plants. 46 mgd. By construction of additional secondary clarifiers
and other facilities, we can increase the treatment to 80 mgd, and it is
relatively cost effective. At Huntington Beach will increase secondary
clarifiers and replace engines with motors. Increases 75 mgd to 90 mgd. The
total increase is 49 mgd. Estimated cost is $62 million. This is the most
cost-effective increase in secondary treatment that we will ever see. In the
future we will need to build additional new secondary treatment facilities. Can
expect the cost to be almost double that. When we met with EPA's Regional
Administrator in August, we told him we were proceeding immediately with this
and they were most pleased to hear we are going ahead with this project. He
added that the action before the Board was to award a contract to John Carollo
Engineers which includes preliminary design, support for permitting, and
contract support. Total agreement amount is approximately $5 million.
The General Manager added that the Master Plan that the Board adopted in July
called for continuation of the current program and treatment level which
provides for secondary treatment to one-half the flow. This project would be
needed regardless of the treatment level selected by EPA.
Items (12)(b)6(c) MOVED and SECONDED.
Director Hart asked how far along does this project take us? TMD replied that
this is the only project in the first five years of the Master Plan and during
the new 5-year permit. Would be the only project that we will need for 10 years
If Permit is renewed. If it is not renewed, we would have to proceed
immediately with new contracts for expansion.
Director Polis asked if we had considered building the whole thing at one time?
TMD explained that this contract with JCE was to improve facilities right now.
We have to wait to see what EPA says before we add additional facilities. Would
be a tremendous bullet to bite to build full secondary treatment facilities now.
Would cost between $2.5 and 3 million per one mgd of treatment. The Districts
couldn't afford that right now. The cost-effective way is to see if we need to
build more facilities.
-. i -2-
The General Manager added that our Master Plan calls for $2 billion of new
contracts over the next 30 years. Most of that money will be spent in 1990 and
early in the next century. If we expedite such a project at this point, it
would make major changes in our whole financial plan as we have considerable
amounts of other facilities that have to be built during this 10-year period.
VOICE VOTE on motion. Motion CARRIED.
Griffin asked if that action was for both items or just to receive and file.
Hanson replied, for both items.
#14 - Ordinances
(a) (3) - Oral public comments: (Taken before GC's report)
John Locke - Said he was in District 11. Prior to one year ago didn't know
s1Sf ETEs existed. I received a notice of user fees that went on my property
taxes which I was very much opposed to. Wrote to every Senator, etc. Amounts
to 55% increase, from $26/year to $40/year for me. This fee continues to go on.
I don't think it is right. I contacted Directors Winchell and Mays. Wrote to
everybody from Deukmejian on down. Thought it was going to stay at $26. I am
against having to collect this on the tax bill .
The Joint Chairman stated that neither of the fees mentioned by Mr. Locke were
part of this agenda item. The ordinances included in this agenda item have to
do with connection fees.
(a) (2) - Report of General Counsel
The General Counsel reported that this is the second reading of these
ordinances. No changes since introduction. They are a result of the study
presented to the Boards previously outlining increases in connection fees.
District 13 has a separate issue and that can be addressed as necessary. It has
been addressed by a separate staff report. Asked if there were any questions.
Director Sheridan asked re District 7, would it be appropriate to notify the
development community that will be planning new projects that these fees are
going up? There is a lot of new development going on. Think they should be
notified. Think we should put out a letter indicating what fees are and explain
the necessity of increasing them. Recommended it be sent to various Cities or
City Managers.
Director Siefen commented that all collection agencies get notified of this,
don't they? The General Manager replied yes, that is correct. The Districts
have agreements with all of the cities and sanitary districts and they collect
the fees for us at the time the building permit is issued. The cities keep 5%
for administrative costs and remit the balance to the Sanitation Districts. He
added that we would immediately send out notification to all cities advising
them of the changes. We will also follow up with Director Sheridan's request
that we notify builders in District 7.
Question was asked, if they apply for a building permit prior to the January 1st
deadline, will they have to pay new fees? Staff advised that if the permit is
issued prior to January 1, 1990, they will pay current fee.
-3-
Director Silzel stated that he thought we should emphasize communication more.
We receive these notices at cities but cities don't notify all parties. Think
we should emphasize more communication to the press. With regard to comment of
Mr. Locke that he didn't know we existed, when we impose fees on community, we
should make an effort to do a press release. If more people were informed,
..i there might be more people here. Don't think there is a problem with the
Districts. I know we operate well.
Called for the question. MOVED & SECONDED (14)(b). MOTION CARRIED.
EACH DISTRICT then MOVED, SECONDED & ADOPTED its respective Ordinance by roll
call vote.
#29 - DISTRICTS 6, 7 & 14 - Supplement to EIR
Tom Dawes reported that we are proposing to prepare a supplement to the EIR.
Three years ago when District 13 was farmed, this EIR was prepared for formation
and for certain wastewater conveyance facilities to serve this District. The
most important one is from airport area to Plant No. 1. 1n the EIR the actual
sewer ws shown in concept. The final route of the sewer was not determined. At
that time it was thought that the entire project would be within city streets.
After it was designed, it became apparent that certain easements would be needed
for the sewer along the Santa Ana River and within Mesa Verde Golf Course and
within a privately-owned parking lot. These easements were not identified
within the original EIR. Some property owners have indicated that they will not
sell and it will be necessary to condemn. We are proposing to do a supplement
to the EIR and get notices to those property owners. Southern California Edison
has a policy about putting sewers within their right of way. Also within
private parking lot in back of Harbor Blvd. , the landowner is willing to sell
but the tenant does not want the project to go forward. Know there will be
opposition.
MOVED & SECONDED items (b) & (c). Motion CARRIED.
-4-
REPORT OF THE JOINT CHAIRMAN
�../ OCTOBER 11, 1989
1) UPCOMING MEETINGS
A. EXECUTIVE COMMITTEE - THE EXECUTIVE COMMITTEE WILL
MEET ON WEDNESDAY, OCTOBER 18TH AT 5: 30 P.M. , TO
HEAR AN INDUSTRIAL WASTE PERMIT APPEAL.
B. EXECUTIVE COMMITTEE - THE EXECUTIVE COMMITTEE WILL
MEET ON THURSDAY, OCTOBER 26TH AT 5 : 30 P.M. THIS IS
A CHANGE FROM THE REGULAR OCTOBER MEETING DATE OF
OCTOBER 25TH DUE TO A CONFLICT WITH THE LEAGUE OF
CITIES CONFERENCE.
(INVITE TWO OF THE FOLLOWING DIRECTORS TO ATTEND: )
GRACE WINCHELL
AND
EDWARD ALLEN �
- OR -
(MARGARET ARNOLD)
C. CONSERVATION, RECLAMATION AND REUSE COMMITTEE - THE
CONSERVATION, RECLAMATION AND REUSE COMMITTEE WILL
�MEET ON WEDNESDAY, yN�OVEMBER 1ST AT 5: 30 P.M.
-END OF REPORT-
-1-
COUNTY SANITATION
DISTRICTS NOS. 11 2, 3, 5, 6, 7, 113 13 AND 14
OF
ORANGE COUNTY, CALIFORNIA
MINUTES OF THE REGULAR MEETING
ON
OCTOBER 11, 1939
olTAi/p , _
4S aa°e peO GIs'.
2&
U .
r •i
Sinoe l9ba y
pRq 'GE COONS
ADMINISTRATIVE OFFICES
10844 ELLIS AVENUE
FOUNTAIN VALLEY, CALIFORNIA
ROLL CALL
A regular meeting of the Boards of Directors of County Sanitation Districts Nos. 1, 2, 3,
S. 6, 7, 11. 13 and 14 of Orange County, California, was held on October 11, 1989, at
7:30 p.m., in the Districts- Administrative Offices. Following the Pledge of Allegiance and
invocation the roll was called and the Secretary reported a quorum present for Districts
Nos. 1, 2, 3, S. 6, 7, 11, 13 and 14 as follows:
'....W ACTIVE DIRECTORS ALTERNATE DIRECTORS
DISTRICT NO. 1: x Robert Hanson, Chairmen Dana Crank
=Dan Griset, Chairmen pro tan —Dan Young
=Ronald B. Hoesterey —Ursula Kennedy
_Roger Stanton x Don R. Roth
DISTRICT NO. 2: x William D. Mahoney, Chairman Beth Graham
Ron Isles, Chairman pro tan x Carrey Nelson
-7--Roland E. Btgonger Henry W. Wedaa
x A.B. -Buck- Catlin —Chris Herby
7—Dan Griset —Dan Young
x James Neal —_George Scott
x Arthur G. Newton _Carol Downey
=Bon Perry Norman Culver
=Iry Pickier —Fred Hunter
x Wayne Silzel —James T. Fasbender
=Dan E. Smith —Fred Barrera
_Roger Stanton x Don R. Roth
DISTRICT NO. 3: x Richard Polls, Chairman Orbrey Duke
=Carrey Nelson, Chalrman pro Can _Wayne Wedin
x Edward L. Allen Paul Verellen
x Margaret M. Arnold _John Kanel
a Wes Bannister —Peter Green
z A.B. -Suck- Catlin —_Chris Harty
rm=Noan Culver Bob Perry
=Dan R. Griffin —_Donna L. Chessen
=Dan Griset Dan Young
=William D. Mahoney —_Beth Graham
x James Neal George Scott
x Iry Pickier —_Fred Hunter
=J.R. -Bob- Siefen Dewey Wiles
_Roger Stanton .=Don R. Roth
-7--Charles Sylvia Robert Wahistrom
_Edna Wilson =Victor Grgas
DISTRICT NO. 5: x John C. Cox, Jr., Chairman Evelyn Hart
Donald A. Strauss, Chai man pro tan x Evelyn Hart
x Don R. Roth _Roger Stanton
DISTRICT NO. 6: x James Wanner, Chairman Jam
s M. Ferryman
x Ruthelyn Plummer, Chairman pro tan Evelyn Hart
x Don R. Roth =Roger Stanton
DISTRICT NO. 7: x Don E. Smith, Chairman _Fred Barrera
x Richard Edgar, Chai man pro in Ursula Kennedy
x Dan Griset —Dan Young
=Don R. Roth _Roger Stanton
=_Sally Anne Sheridan Larry Agran
Donald A. Strauss xJohn C. Cox, Jr.
-7--Jams Wanner _Harry Green
DISTRICT NO. 11: x Tan Mays, Chairman Jim Silva
=Grace Winchell, Chairman pro tem —Wes Bannister
_Roger Stanton =Don R. Roth
DISTRICT NO. 13: x Henry W. Wedaa, Chairman _Roland E. Btgonger
x Iry Pickier, Chai man pro ten Fred Hunter
=Don R. Roth =Roger Stanton
x Don E. Smith Fred Barrera
=Wayne wedin _Ron Isles
DISTRICT NO. 14: x Peer A. Swan, Chairman _Darryl Miller
x Ursula Kennedy, Chairman pro ten Richard B. Edgar
�..� =Don R. Roth =Roger Stanton
=Sally Anne Sheridan _Larry Agran-
x Don E. Smith Fred Barrera
_2_
10/11/89
STAFF MEMBERS PRESENT: J. Wayne Sylvester, General Manager,
Rita J. Brown, Board Secretary, Blake
P. Anderson, Thomas M. Dawes, Gary G. .
Streed, Penny Kyle, Ed Hodges, Rich
von Langan, Jack Vincent, Chuck Winsor
OTHERS PRESENT: Thomas L. Woodruff, General Counsel ,
Clark Ide, Jamel Demir, Bill Fleming,
Walt Howard, Harvey Hunt, Bill Knopf, -
Phil Stone, Sarwan Wason, Richard
Amezaga, Mr. & Mrs. John Locke, Doug .
Montague, Mark Nichols, Jerry D.
Porter, Tom Richardson, Adrian
Saavedra, Larry Simpson
* * * * * * * * * * * * *
ALL DISTRICTS Joint Chairman Hoesterey reported that
Report of the Joint Chairman the Executive Committee would hold a
special meeting on Wednesday,
October 18th, at 5:30 p.m., to hear an Industrial Waste Permit enforcement
action appeal .
He then called the regular meeting of the Executive Committee for Thursday,
October 26th, at 5:30 p.m., and invited Directors Grace Winchell and Edward
Allen to attend and participate in the discussions. The Joint Chairman
noted that this was a change from the regular meeting date of October 25th
due to a conflict with the League of Cities Conference.
Chairman Hoesterey advised that due to a scheduling conflict, the
Conservation, Reclamation and Reuse Committee, which was to meet on
November 1st at 5:30 p.m. , would be rescheduled to a date to be determined
after contacting the Committee members.
ALL DISTRICTS The General Manager briefly commented on
Report of the General Manager his annual report previously mailed to
Directors which summarized the
Districts' accomplishments in 1988-89 and outlined goals and objectives for
1989-90.
Mr. Sylvester reported that President Bush had nominated LaJuana Wilcher to
be EPA's new Assistant Administrator for Water. He observed that her past
experience at EPA and her more recent three years' experience in private law
practice representing local public agencies in environmental matters would
serve her well in her new capacity.
The General Manager then announced that EPA Region 9 had advised the
Districts that they were to be the recipients of an EPA Award of Excellence
for the third consecutive year. He further reported that the Districts were
placed in competition with the top full secondary treatment plants in the
country for the National Award of Excellence and that the Districts had
received second place. In announcing the awards EPA stated that the
Districts had scored outstanding in compliance, financial management,
personnel staffing, overall management practices and other key operational
factors. Mr. Sylvester added that this demonstrates that the Districts'
wastewater management program of advanced primary treatment to all flow and
secondary treatment to half of the flow is very effective in protecting the
environment. He said that the award would be presented at the Water
Pollution Control Federation meeting in San Francisco the following week.
-3-
10/11/89
ALL DISTRICTS The General Counsel reported on the
Report of the General counsel massive enforcement program currently
being undertaken by the Environmental
Protection Agency (EPA). They recently named 61 agencies found to be in
`✓ violation of federal industrial pretreatment program requirements. He noted
that EPA has clearly stated that they expect all POTW's to establish and
enforce pretreatment programs. Mr. Woodruff added that the Districts'
pretreatment and enforcement program is considered to be one of the best in
the nation.
The General Counsel then briefly reviewed the status of the
Beatrice/Hunt-Wesson litigation filed following their appeal to the Board
relative to Industrial Waste Permit No. 3-1-143.
Mr. Woodruff also commented on an upcoming hearing before the Executive
Committee on an appeal by Universal Circuits, Inc. relative to Industrial
Waste Permit No. 1-1-346.
DISTRICT 1 There being no corrections or
Approval of Minutes amendments to the minutes of the
regular meeting held September 13,
1989, the Chairman ordered that said minutes be deemed approved, as mailed.
DISTRICT 2 There being no corrections or
Approval of Minutes amendments to the minutes of the
regular meeting held September 13,
1989, the Chairman ordered that said minutes be deemed approved, as mailed.
DISTRICT 3 There being no corrections or
Approval of Minutes amendments to the minutes of the
regular meeting held September 13,
1989, the Chairman ordered that said minutes be deemed approved, as mailed.
DISTRICT 5 There being no corrections or
Approval of Minutes amendments to the minutes of the
regular meeting held September 13,
1989, the Chairman ordered that said minutes be deemed approved, as mailed.
DISTRICT 6 There being no corrections or
Approval of Minutes amendments to the minutes of the
regular meeting held September 13,
1989, the Chairman ordered that said minutes be deemed approved, as mailed.
DISTRICT 7 There being no corrections or
Approval of Minutes amendments to the minutes of the
regular meeting held September 13,
1989, the Chairman ordered that said minutes be deemed approved, as mailed.
DISTRICT 11 There being no corrections or
Approval of Minutes amendments to the minutes of the
regular meeting held September 13,
1989, the Chairman ordered that said minutes be deemed approved, as mailed.
DISTRICT 13 There being no corrections or
Approval of Minutes amendments to the minutes of the
regular meeting held September 13,
1989, the Chairman ordered that said minutes be deemed approved, as mailed.
-4-
10/11/89
DISTRICT 14 There being no corrections or
Aooroval of Minutes amendments to the minutes of the
regular meeting held September 13,
1989, the Chairman ordered that said minutes be deemed approved, as mailed.
ALL DISTRICTS Moved, seconded and duly carried:
Ratification of Rayment of Joint
and Individual District Claims That payment of Joint and individual
District claims set forth on pages "A"
and "B" attached hereto and made a part of these minutes, and summarized
below, be, and are hereby, ratified by the respective Boards in the amounts
so indicated.
9/13/89 9/27189
ALL DISTRICTS
JooinUp—
ating Fund - $ 460,788.90 $ 990,045.71
Capital Outlay Revolving Fund - 2,502,232.16 439,688.74
Joint Working Capital Fund - 155,213.48 146,529.26
Self-Funded Insurance Funds - -0- 11,268.85
DISTRICT NO. 1 - 61.68 2,903.71
DI I C� - 154,941.73 82,550.50
DI TR�N073 - 5,923.96 59,065.22
DISTRICT ON . 5 - 15,981.28 21,621.04
DI TRIICT_N U.6 - 62,814.13 1,511.94
DI R—I U.7 - 25,762.59 12,362.40
DI FTARI T N . 11 - 74.62 1,758.70
DISTR T N0. 1 - -0- 126.48
DISTR��14 - 43,101.19 1,614.19
DISTRICT N 97. 5 & 6 JOINT - 12.311.01 7,587.38
DISTRICTS N & 7 J NT - 2,886,48 36.28
DISTRICTS NOS. 7 & 1 JOINT - 170.14 3,394.38
1,7 .064.7
Director Don R. Griffin requested that his abstention from voting on Warrant
No. 102383 be made a matter of record.
ALL DISTRICTS Moved, seconded and duly carried:
Awarding Purchase of Chlorine in
Bulk, Specification No. C- That the Boards of Directors hereby
adopt Resolution No. 89-138, receiving
and filing bid tabulation and recommendation and awarding contract for
Purchase of Chlorine in Bulk, Specification No. C-025, to Olympic Chemical
Company for the price of $212.70 per tan plus sales tax, for a one-year
period beginning November 1, 1989, with provision for a one-year extension
(estimated annual cost $1,340,010.00 plus sales tax). A certified copy of
this resolution is attached hereto and made a part of these minutes.
ALL DISTRICTS Moved, seconded and duly carried: '
Awa rdin Purchase of hlonne in
ne- on 1 i nde rs ec ficat on That the Boards of Directors hereby
No. t;-UZb adopt Resolution No. 89-139, receiving
and filing bid tabulation and
recommendation and awarding contract for Purchase of Chlorine in One-Ton ,
Cylinders, Specification No. C-026, to Continental Chemical Company for the
price of $265.00 per tan plus sales tax, for a one-year period beginning
November 1, 1989, with provision for a one-year extension (estimated annual
cost $159,000.00 plus sales tax). A certified copy of this resolution is
attached hereto and made a part of these minutes.
-5-
10/11/89
ALL DISTRICTS Moved, seconded and duly carried:
A rov n on
sant o Assignment of
Real Pro ert ease at Plant No. 1 That the Consent to Assignment of Real
Specification No. L-013, to Village Property Lease at Plant No. 1,
Nurseries L.P. , a California Specification No. L-013, from Miya
Partnership Wholesale Nursery, Ltd. to Village
Nurseries L.P., a California Limited
Partnership, be, and is hereby, approved; and,
FURTHER MOVED: That the District 1 Chairman and Secretary be, and are
hereby, authorized to execute said Consent to Assignment of Real Property
Lease at Plant No. 1.
ALL DISTRICTS Moved, seconded and duly carried:
Approving Change Order No. 1 to
the plans and specifications far That Change Order No. 12 to the plans
Job No. J-7-4 and specifications for Administration
Building Addition, Job No. J-7-4,
authorizing an addition of $4,530.00 to the contract with J. R. Roberts
Corporation for three items of additional work including installation of a
low voltage lighting panel , 50 light switch box extensions for interior
partition office walls, additional ceramic tile in bathrooms around light
switch boxes and towel dispensers and various plumbing changes in several
locations in the new South Wing, be, and is hereby, approved.
ALL DISTRICTS Moved, seconded and duly carried:
Approving Change Order No. 20 to
the plans and specifications for That Change Order No. 20 to the plans
Job No. J-15 and specifications for Ocean Outfall
Booster Station "C" at Plant No. 2, Job
No. J-15, authorizing an addition of $17,165.82 to the contract with Advanco
Constructors, Inc. for seven items of additional work including moving two
120-inch diameter pipe sections to a remote yard to be sandblasted, painted
and then returned for final placement, installation of temporary electrical
power to heat building for protection of stored electrical equipment,
installation of a back-up power source for the wet well bubbler control
system in pumping station, installation of harmonic filters on two voltage
relays, placement of safety handrail equipment around four roof skylights,
placement of safety plate to close a 12-inch open space around electrical
cable trays and modification of the computer control system alarm for the
variable frequency drives, be, and is hereby, approved.
ALL DISTRICTS Moved, seconded and duly carried:
Approving Change Order No. 27 to
the Tans and specifications for That Change Order No. 22 to the plans
Job Nos. P1-20 and P1_jZ and specifications for Headworks No. 2
at Plant No. 1, Job No. P1-20, and
Demolition of Digesters Nos. 1, 2 and 4; Replacement of Boiler; Piping
Cleanouts; and Grading and Paving at Plant No. 1, Job No. P1-31, authorizing
an addition of $25,662.11 to the contract with Kiewit Pacific Co. for ten
items of additional work including installation of a digester gas flow meter
required by SCAQMD, installation of a concrete landing pad at existing
headworks, addition of new drain line at Sunflower Pump Station, rerouting
three chlorine solution lines at the splitter box, installation of an
aluminum ladder in lieu of stairway to access the belt conveyor catwalk,
modification of stile-type stairway, reinforcing covers at piping trench,
installation of a cover over an opening in discharge channel for odor
control , additional fiberglass grating and aluminum kick plates to various
locations for safety and chlorine gas leak detector support modifications,
be, and is hereby, approved.
-6-
10/11/89
ALL DISTRICTS Moved, seconded and duly carried:
Approving Change Order No. 19 to
he lans and s Per
for That Change Order No. 19 to the plans
Job Nos. PI- 5, P1-26, P -32 and specifications for Covers for
PZ-33 and P -34 Primary Basins at Plant No. 1, Job
No. P1-25; Foul Air Scrubber System at
Plant No. 1, Job No. P1-26; Covers for Primary Basins at Plant No. 2, Job
No. P2-32; Foul Air Scrubber System at Plant No. 2, Job No. P2-33; and
Improvements to Grit Facility "B", Billings Tunnel and Distribution
Structure "A", Job No. P2-34, authorizing an addition of $58,245.54 to the
contract with Advanco Constructors, Inc. for seven items of additional work
including electrical modifications at rectangular clarifiers, relocation of
existing light standards at Clarifiers D, E, F and G, substitution of
insulated copper grounding cable in lieu of bare copper cable at clarifier
basins, installation of Oritex wear surface at each foul air duct support
location, installation of a foul air connection on the underground primary
effluent line and a new underground effluent sampling line, repair of
42-inch RCP influent line to Clarifier I, and modification of tread-plate
hold-down anchors, be, and is hereby, approved.
ALL DISTRICTS Moved, seconded and duly carried:
Approving Change Order No. 5 to the
Tans and specifications for That Change Order No. 5 to the plans and
Job No. P1-27 specifications for Entrances, Site,
Security and Interior Road Improvements
at Plant No. 1, Job No. P1-27, authorizing an addition of $6,787.15 to the
contract with Kiewit Pacific Co. for five items of additional work including
additional transformer and electrical wiring at two gate card readers,
installation of District-furnished multiplexer, repair of landscaping,
replacement of 120-volt relays with 24-volt relays for gate control
circuitry, and traffic sign and striping modifications, be, and is hereby,
approved.
ALL DISTRICTS Moved, seconded and duly carried:
Approving hange Order No. 5 to the
Tans and s ecifications for That Change Order No. 5 to the plans and
,Job No. PZ-37 specifications for Miscellaneous
Modifications and Improvements to
Facilities at Plant No. 2, Job No. P2-37, authorizing an addition of
$77,047.00 to the contract with Ziebarth 8 Alper for placement of sloped
reinforced fill concrete in Digesters A and B to improve flow
characteristics of sludge recirculating system, and providing for payment of
contract-specified bonuses for early completion of certain major elements of
the project, be, and is hereby, approved.
ALL DISTRICTS Moved, seconded and duly carried: _
Accepting Job No. Pl- 5-1-1 as
complete That the Boards of Directors hereby
adopt Resolution No. 89-140, accepting
Cleaning of Digesters 7 and 8 at Plant No. 1, Job No. PI-35-1-1, as
complete, authorizing execution of a Notice of Completion and approving
Final Closeout Agreement. A certified copy of this resolution is attached
hereto and made a part of these minutes.
-7-
10/11/89
ALL DISTRICTS Moved, seconded and duly carried:
Authorizin the Selection omnittee
to negotiate Addendum No. to the That the Selection Committee be, and is
Professional Services Agreement hereby, authorized to negotiate Addendum
.� with John Carollo En ineers for No. 2 to the Professional Services
design of Jab No. P1- 4 Agreement with John Carollo Engineers
for design of Digesters Nos. 11-16,
Sludge and Gas Handling Facilities at Reclamation Plant No. 1, Job
No. P1-34, (subsequently divided into Job Nos. P1-34-1 and P1-34-2) to
provide for additional construction support services and for separation of
Job No. P1-34-1 into two separate construction projects, Gas Handling
Facilities at Reclamation Plant No. 1, Job No. P1-34-1, and Construction of
Digesters Nos. 11-16 at Reclamation Plant No. 1, Job No. PI-34-3.
ALL DISTRICTS Moved, seconded and duly carried:
Authorizing the Selection Committee
to ia negotte a Professional That the Selection Committee be, and is
Services A reement with EMA hereby, authorized to solicit a proposal
ervi[es Inc. for design of and negotiate a Professional Services
Job No. P -44 Agreement with EMA Services, Inc. for
design of Replacement of Computerized
Monitoring System at Plant No. 2, Job No. P2-44.
ALL DISTRICTS Moved, seconded and duly carried:
Authorizing the Selection Comnittee
to negotiate a Professional That the Selection Committee be, and is
Services Agreement to conduct a hereby, authorized to solicit proposals
study of user categories for and negotiate a Professional Services
establishing rates for Districts' Agreement to conduct a study of user
one-time connection fees and annual categories for establishing rates for
use fees Districts' one-time connection fees and
annual use fees.
DISTRICTS 1,2,3,5,6,7,11 & 13 Moved, seconded and duly carried:
Approving Addendum No. 1 to Agree-
ment with Arthur Young & Company re That the Boards of Directors hereby
function design and redevelopment adopt Resolution No. 89-141, approving
of the supplemental user fee data Addendum No. 1 to Agreement with Arthur
processing programs Young & Company for the functional
design and redevelopment of the
Districts' supplemental user fee data processing programs to interface with
the County Assessor's and County Auditor's data base management systems,
Including training services and oversight necessary to implement the new
programs, providing for an expanded scope of work to include additional
program modifications requested by the County Assessor to facilitate data
transfers, for an additional amount not to exceed $37,180.00, increasing the
total authorized compensation from $161,882.00 to an amount not to exceed
$199,062.00 (said increase to be deducted from County Assessor's charge to
- the Districts for data base information and processing). A certified copy
of this resolution is attached hereto and made a part of these minutes.
Director Don R. Griffin requested that his abstention from voting on this
motion be made a matter of record.
-8-
10/11/89
ALL DISTRICTS Moved, seconded and duly carried:
Authorizing staff to slue a
urchase order to Containerized That staff be, and is hereby, -
Chemical Disposal. Inc. for authorized to issue a purchase order
disposal of classified materials to Containerized Chemical Disposal ,
and wastes Inc. for disposal of classified
materials and wastes under the County
of Orange Cooperative Agreement, pursuant to the requirements of the
Resource Conservation and Recovery Act, for the period October 12, 1989 to
May 31, 1990, renewable for two years contingent upon negotiations with the
County of Orange (Cost through 5/31/90 estimated not to exceed $100,000.00).ALL DISTRICTS
Actions re Primary lar f ers
Nos. 6-15 and Related Facilities at
Reclamation Plant No. 1 Job
No. P -33
Verbal staff report The Director of Engineering
reported that construction of the
facilities included in Job No. P1-33 would result in an additional
60 mgd of primary treatment at Plant No. 1. This job is the single
largest construction project to ever be awarded by the Boards.
Mr. Dawes briefly reviewed some of the major elements of work included
in the project. He noted that the Districts were pleased to have
received seven bids ranging from $39.7 million to $46.5 million. Staff
recommended award of Job No. PS-33 to the low bidder, Gust K. Newberg
Construction Co.
A rovin Addendum
s No. 1 to the Moved, seconded and duly carried:
ons and specifications for
Job NO. F1-JJ That Addendum No. 1 to the plans
and specifications for said
project making miscellaneous technical clarifications, be, and is
hereby, approved.
A rovin Addendum No. 2 to the Moved, seconded and duly carried:
lans andd�s ecifica ions for
Job No. PI-33 That Addendum No. 2 to the plans
and specifications for said
project changing the date for receipt of bids from September 19, 1989
to September 26, 1989, revising insurance certificates and endorsements
required and making miscellaneous technical clarifications, be, and is
hereby, approved.
Approving Addendum No. 3 to the Moved, seconded and duly carried:
Ole and so
a I cations for
JODJob NO. That Addendum No. 3 to the plans
and specifications for said
project correcting the completion time for construction of said project
and making miscellaneous modifications relative to the electrical work
in Power Building 4, be, and is hereby, approved.
-9-
10/11/89
Awarding Job No. P1-33 to Gust K. Moved, seconded and duly carried:
Newberg Construction Co.
That the Boards of Directors
hereby adopt Resolution No. 89-142, receiving and filing bid tabulation
and recommendation and awarding contract for Primary Clarifiers
Nos. 6-15 and Related Facilities at Reclamation Plant No. 1, Job
No. P1-33, to Gust K. Newberg Construction Co. in the total amount of
$39,657,000.00. A certified copy of this resolution is attached hereto
and made a part of these minutes.
ALL DISTRICTS
Actions re Professional Services
A reement with ohm Ca rollo
En ineers for es n of Job
Nos. PI-36 and P -42
Verbal staff report The Director of Engineering
reported that the facilities to
be designed under Job Nos. P1-36 and P2-42 are the first of the major
projects to go forward from the Districts' recently-adopted "2020
VISION" 30-year Master Plan. These two projects include expansion of
existing secondary treatment facilities at Plants 1 and 2. Plant 1
will increase from 46 to 80 mgd and Plant 2 from 75 to 90 mgd. He
noted that because we are expanding existing facilities, it will be
much more cost-effective than any future additional secondary treatment
facilities that will be required to be built, which are expected to
cost about twice as much as this project.
He also pointed out that construction of Primary Clarifiers Nos. 6-15
and Related Facilities at Reclamation Plant No. 1, Job No. P1-33, would
be required regardless of the level of treatment ultimately required by
EPA for renewal of the Districts' NPDES ocean discharge permit, in
order to adhere to the overall wastewater management program approved
by the Boards in July, 1989.
Mr. Dawes further advised that this is the only project for additional
secondary treatment facilities that would be needed over the next 10
years if the Districts' 301(h) ocean discharge permit is renewed by
EPA. If it is not renewed, the Districts' would need to immediately
proceed with design work for additional secondary treatment facilities.
In response to a question relative to immediately building the
necessary facilities for full secondary treatment because of escalating
construction costs, staff advised that the most cost-effective
financial plan was to build additional facilities as they are needed.
If full secondary treatment facilities were built early, the ongoing
operating costs would exceed any construction cost savings. The
General Manager then pointed out that the Districts' new Master Plan
provides for $2 billion worth of new facilities to be built over the
next 30 years, with most of the money being spent in 1990 and early in
the next century, and that accelerated construction of major facilities
before they are needed would significantly impact the Districts'
financial requirements and the cost of service to the citizens.
-10-
10/11/89
A rovin Professional Services Moved, seconded and duly carried: -
Agreemen with John Carollo
Engineers That the Selection Committee -
certification of the final
negotiated fee relative to the Professional Services Agreement with
John Carollo Engineers for design and construction services,
preparation of operations and maintenance manuals, and training
services re Secondary Treatment Improvements at Plant No. 1, Job _
No. P1-36, and Secondary Treatment Expansion at Plant No. 2, Job
No. P2-42, be, and is hereby, received, ordered filed and approved;
and,
FURTHER MOVED: That the Boards of Directors hereby adopt Resolution
No. 89-143, approving said agreement with John Carollo Engineers for
said services, on an hourly-rate basis for labor plus overhead, direct
expenses, and fixed profit, for a total amount not to exceed
$4,997,841.00. A certified copy of this resolution is attached hereto
and made a part of these minutes.
ALL DISTRICTS Moved, seconded and duly carried:
Receive, file and a rove written
report of the xecutive Committee That the written report of the
Executive Committee's meeting on
September 27, 1989, be, and is hereby, received, ordered filed and approved.
ALL DISTRICTS Moved, seconded and duly carried:
Authorizing staff to negotiate
Amendment No. 2 to the electrical That staff be, and is hereby,
equipment purchase contract with authorized to negotiate Amendment
Cooper Industries, Energy Services No. 2 to the electrical equipment
Group, dba C-B Reciprocating re purchase contract with Cooper
Jab No. J-19A Industries, Energy Services Group,
dba C-B Reciprocating, for Purchase
of Spark-Ignited Engines for Use in Central Power Generation Systems, Job
No. J-19A, to provide for price escalation for the maintenance services
because of delays in receipt of the Permit to Construct and for extended
storage of equipment by the manufacturer.
ALL DISTRICTS Moved, seconded and duly carried:
Approving in concept the draft
guidelines re Procedures for That the draft guidelines re
Appeals of Wastewater Discharge Procedures for Appeals of Wastewater
Regulation Enforcement Actions Discharge Regulation Enforcement
Actions, as set forth in the General
Counsel/Staff Memorandum of September 20, 1989, be, and are hereby, approved _
in concept; and,
FURTHER MOVED: That the General Counsel and staff be, and are hereby,
directed to finalize said guidelines for appeals of enforcement actions
taken pursuant to the Districts' Ordinances Establishing Wastewater
Discharge Regulations for Use of District Sewerage Facilities, for
consideration by the Boards of Directors.
-11-
10/11/89
ALL DISTRICTS
Actions re appea of niversal
Ctrcuiis Inc. re nonrenewal of
Waste Disc arge Permit No. 1-1- 46
Ratifying action of Executive Moved, seconded and duly carried:
Committee in setting date and time
for appeal hearing That the Boards of Directors do
hereby ratify the action of the
Executive Committee in setting October 18, 1989 at 5:30 p.m. as the
date and time for hearing the appeal of Universal Circuits, Inc. re
nonrenewal of Waste Discharge Permit No. 1-1-346.
Ratif in action of Executive Moved, seconded and duly carried:
Committee in setting appeal hear ng
pursuant to Ordinance Section 619 That the Boards of Directors do
hereby ratify the action of the
Executive Committee in setting the appeal hearing for Universal
Circuits, Inc. pursuant to Ordinance Section 619, and,
FURTHER: That the Boards of Directors do hereby find that the Joint
Boards would have required hearing before the Joint Boards, as
authorized by the terms of the Joint Ownership, Operation and
Construction Agreement of July 1, 1985.
Affirm in the use of "Rules on Moved, seconded and duly carried:
A ea Pursuant to ection 19 0
the Dis ric sOrdinances That the Boards of Directors do
Es ab ish ng Wastewater Disc arge hereby affirm the use of "Rules
Regulations" for cc nducti ng hearing on Appeal Pursuant to Section. 619
of the Districts' Ordinances
Establishing Wastewater Discharge Regulations of the County Sanitation
Districts of Orange County, California" for conducting hearing on
appeal of Universal Circuits, Inc.
ALL DISTRICTS Moved, seconded and duly carried:
Establishn onsmm po
in the BoargMetn-g R cy
That the Boards of Directors do hereby
establish a non-smoking policy in the
Board Meeting Rooms.
ALL DISTRICTS Moved, seconded and duly carried:
mendin Classification and
mpen sation Resolution No. -20, That the Boards of Directors hereby
as amended revisin certain adopt Resolution No. 89-149, amending
Administrative lerical Classification and Compensation
Confidential , Laborator and Resolution No. 79-20, as amended,
omp ance position classifica ions revising certain
and salaries Administrative/Clerical , Confidential ,
Laboratory and Compliance position
classifications and salaries, as recommended by classification study. A
certified copy of this resolution is attached hereto and made a part of
these minutes.
-12-
10/11/89
DISTRICTS 1 1
2,3 5 6 7 11 8 13
Actions re ra osed rdinances
Amend In, Ordinances sta shin ,
astewater 2'schar a Regulations
or Use of D strict ewers e
ac f rrfFes
Public Hearing The Joint Chairman announced that
this was the time and place fixed
by the Boards for a public hearing on the following proposed Ordinances
of the Boards of Directors of County Sanitation Districts Nos. 1, 2, 3, _
5, 6, 7, 11 and 13 of Orange County; California, Amending Ordinances
Establishing Wastewater Discharge Regulations for Use of District
Sewerage Facilities:
Amending
District Ordinance No. Ordinance No.
1 114 113
2 209 208
3 312 311
5 521 520
6 615 614
7 723 722
11 1111 1110
13 1306 1305
Open Public Hearing The Chairman declared the
hearing open at 7:59 p.m.
Verbal report of General Counsel The General Counsel reported
that this was the second
reading of the ordinances of the respective Districts- which
amended their Ordinances Establishing Wastewater Discharge
Regulations for Use of District Sewerage Facilities to increase
the sewer connection fees, and that no changes had been made since
they were introduced at the September 13th Joint Board meeting.
He noted that the issues raised by District 13 at the September
Board meeting relative to exempting local governmental agencies
from payment of connection fees had been addressed by a separate
staff report mailed to District 13 Directors.
The Directors then discussed the procedures for notifying
developers of the proposed increases in connection fees, as well
as the various cities and sanitary districts that collect the fees
on behalf of the Districts, pursuant to agreements therefor.
Directors and staff agreed on the importance of keeping the public
Informed regarding the Districts' operations and financial
requirements. Staff advised that letters would be sent to all the
appropriate agencies and development companies notifying them of
the new fees to be effective January 1, 1990. It was pointed out
that the current connection fees would apply to all building
permits issued prior to January 1, 1990, after which the new fee
schedule would take effect.
-13-
10/11/89
Oral Public Comments John Locke, 6392 Sligo
Circle, Huntington Beach,
addressed the Board and expressed his displeasure with the
increase in District No. 11's sanitary sewer service charges. He
also stated he was opposed to collecting these charges on the
property tax bills.
The Joint Chairman pointed out that the fees Mr. Locke referred to
were not a part of the ordinances currently being considered by
the Directors under this agenda item. The user fees mentioned by
Mr. Locke are established by separate ordinances adopted by the
respective Boards.
Close hearing The Chairman declared the
hearing closed at 8:06 p.m.
Making findings that adoption of Moved, seconded and duly carried:
said Ordinances is categorically
exempt per CEQA Guidelines That the Boards of Directors
hereby find that adoption of said
Ordinances is categorically exempt from further environmental
assessment pursuant to California Environmental Quality Act ("CEQA")
[California Public Resources Code Section 21080(b) (8) (4)] and CEQA
Guidelines [California Code of Regulations Section 15273(a)(4)], in
that: (1) the Districts have adopted their comprehensive Master Plan
of capital facilities entitled "Collection, Treatment and Disposal
Facilities Master Plan - 1989", together with a Final Program
Environmental Impact Report relating thereto; and (2) the increased
revenues to be received by the connection charges will be used for
capital projects which are necessary to maintain service within the
existing defined service areas of the District, as set forth in the ,
comprehensive Master Plan.
DISTRICT 1 Moved, seconded and duly carried:
Second Reading of Proposed
Ordinance No. 114 That proposed Ordinance No. 114,
An Ordinance of the Board of
Directors of County Sanitation District No. 1 of Orange County,
California, Amending Ordinance No. 113 Establishing Wastewater
Discharge Regulations for Use of District Sewerage Facilities, be read
by title only; and,
FURTHER MOVED: That the second reading of said ordinance in its
entirety be, and is hereby, waived, whereupon the Secretary read
Ordinance No. 114 by title only.
DISTRICT 1 Moved, seconded and duly carried
Adopting Ordinance No. 114 by the following roll call vote:
AYES: Robert Hanson, Chairman, Dan Griset, Ronald B. Hoesterey,
Don R. Roth
NOES: None
ABSENT: None
That Ordinance No. 114, An Ordinance of the Board of Directors of
County Sanitation District No. 1 of Orange County, California, Amending
Ordinance No. 113 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be, and is hereby adopted'.
-14-
10/11/89
DISTRICT 2 Moved, seconded and duly carried:
econd Reading o Proposed
Ordinance No. 26 That proposed Ordinance No. 209,
An Ordinance of the Board of
Directors of County Sanitation District No. 2 of Orange County, ,
California, Amending Ordinance No. 208 Establishing Wastewater
Discharge Regulations for Use of District Sewerage Facilities, be read
by title only; and,
FURTHER MOVED: That the second reading of said ordinance in its
entirety be, and is hereby, waived, whereupon the Secretary read
Ordinance No. 209 by title only.
DISTRICT 2 Moved, seconded and duly carried
Adopting Ordinance No. ZO by the following roll call vote:
AYES: William D. Mahoney, Chairman, Roland E. Bigonger, A. B. "Buck"
Catlin, Dan Griset, James Neal , Carrey J. Nelson, Arthur G.
Newton, Bob Perry, Iry Pickler, Don R. Roth, Wayne Silzel ,
Don E. Smith
NOES: None
ABSENT: None
That Ordinance No. 209, An Ordinance of the Board of Directors of
County Sanitation District No. 2 of Orange County, California, Amending
Ordinance No. 208 Establishing Wastewater Discharge Regulations for,Use
of District Sewerage Facilities, be, and is hereby adopted.
DISTRICT 3 Moved, seconded and duly carried:
Second Readin of Proposed
rdinance Na. 1 That proposed Ordinance No. 312,
An Ordinance of the Board of
Directors of County Sanitation District No. 3 of Orange County,
California, Amending Ordinance No. 311 Establishing Wastewater
Discharge Regulations for Use of District Sewerage Facilities, be read
by title only; and,
FURTHER MOVED: That the second reading of said ordinance in its
entirety be, and is hereby, waived, whereupon the Secretary read
Ordinance No. 312 by title only.
DISTRICT 3 Moved, seconded and duly carried
Adopting Ordinance No. 312 by the fallowing roll call vote:
AYES: Richard T. Polls, Chairman, Edward L. Allen, Margaret M.
Arnold, A. B. "Buck" Catlin, Norman E. Culver, Victor Grgas,
Don R. Griffin, Dan Griset, William D. Mahoney, James Neal ,
Carrey J. Nelson, Iry Pickler, Don R. Roth, J. R. "Bob"
Siefen, Charles E. Sylvia
NOES: None
ABSENT: Wes Bannister
That Ordinance No. 312, An Ordinance of the Board of Directors of
County Sanitation District No. 3 of Orange County, California, Amending
Ordinance No. 311 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be, and is hereby adopted.
-15-
10/11/89
DISTRICT 5 Moved, seconded and duly carried:
Second Readin o Propose
rdinance Na. That proposed Ordinance No. 521,
An Ordinance of the Board of
Directors of County Sanitation District No. 5 of Orange County,
California, Amending Ordinance No. 520 Establishing Wastewater
Discharge Regulations for Use of District Sewerage Facilities, be read
by title only; and,
FURTHER MOVED: That the second reading of said ordinance in its
entirety be, and is hereby, waived, whereupon the Secretary read
Ordinance No. 521 by title only.
DISTRICT 5 Moved, seconded and duly carried
Adopting Ordinance No. 521 by the following roll call vote:
AYES: John C. Cox, Jr. , Chairman, Evelyn Hart, Don R. Roth
NOES: None
ABSENT: None
That Ordinance No. 521, An Ordinance of the Board of Directors of
County Sanitation District No. 5 of Orange County, California, Amending
Ordinance No. 520 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be, and is hereby adopted.
DISTRICT 6 Moved, seconded and duly carried:
Second Reading of Proposed
Ordinance No. 615 That proposed Ordinance No. 615,
An Ordinance of the Board of
Directors of County Sanitation District No. 6 of Orange County,
California, Amending Ordinance No. 614 Establishing Wastewater
Discharge Regulations for Use of District Sewerage Facilities, be read
by title only; and,
FURTHER MOVED: That the second reading of said ordinance in its
entirety be, and is hereby, waived, whereupon the Secretary read
Ordinance No. 615 by title only.
DISTRICT 6 Moved, seconded and duly carried
Adopting Ordinance No. 615 by the following roll call vote:
AYES: James A. Wahner, Chairman, Ruthelyn Plummer, Don R. Roth
NOES: None
ABSENT: None
That Ordinance No. 615, An Ordinance of the Board of Directors of
County Sanitation District No. 6 of Orange County, California, Amending
Ordinance No. 614 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be, and is hereby adopted.
-16-
10/11/89
DISTRICT 7 Moved, seconded and duly carried:
econd Reading of roposed
Ordinance No. M That proposed Ordinance No. 723,
An Ordinance of the Board of
Directors of County Sanitation District No. 7 of Orange County, `.✓
California, Amending Ordinance No. 722 Establishing Wastewater
Discharge Regulations for Use of District Sewerage Facilities, be read
by title only; and,
FURTHER MOVED: That the second reading of said ordinance to its
entirety be, and is hereby, waived, whereupon the Secretary read
Ordinance No. 723 by title only.
DISTRICT 7 Moved, seconded and duly carried
Adopting ordinance No. 7ZJ by the following roll call vote:
AYES: Don E. Smith, Chairman, John C. Cox, Jr. , Richard B. Edgar,
Dan Griset, Don R. Roth, Sally Anne Sheridan, James A. Wahner
NOES: None
ABSENT: None
That Ordinance No. 723, An Ordinance of the Board of Directors of
County Sanitation District No. 7 of Orange County, California, Amending
Ordinance No. 722 Establishing Wastewater Discharge Regulations for Use
of District Sewerage Facilities, be, and is hereby adopted.
DISTRICT 11 Moved, seconded and duly carried:
econd Reading of Proposed
rdinance No. 1111 That proposed Ordinance No. 1111,
An Ordinance of the Board of
Directors of County Sanitation District No. 11 of Orange County,
California, Amending Ordinance No. 1110 Establishing Wastewater
Discharge Regulations for Use of District Sewerage Facilities, be read
by title only; and,
FURTHER MOVED: That the second reading of said ordinance in its
entirety be, and is hereby, waived, whereupon the Secretary read
Ordinance No. 1111 by title only.
DISTRICT 11 Moved, seconded and duly carried
Adopting Ordinance No. 1111 by the following roll call vote:
AYES: Tom Mays, Chairman, Don R. Roth, Grace Winchell
NOES: None
ABSENT: None
That Ordinance No. 1111, An Ordinance of the Board of Directors of
County Sanitation District No. 11 of Orange County, California,
Amending Ordinance No. 1110 Establishing Wastewater Discharge
Regulations for Use of District Sewerage Facilities, be, and is hereby
adopted.
-17-
10/11/89
DISTRICT 13 Moved, seconded and duly carried:
Second Readin of Proposed
Ordinance Na
1 That proposed Ordinance No. 1306,
An Ordinance of the Board of
Directors of County Sanitation District No. 13 of Orange County,
California, Amending Ordinance No. 1305 Establishing Wastewater
Discharge Regulations for Use of District Sewerage Facilities, be read
by title only; and,
FURTHER MOVED: That the second reading of said ordinance in its
entirety be, and is hereby, waived, whereupon the Secretary read
Ordinance No. 1306 by title only.
DISTRICT 13 Moved, seconded and duly carried
Adopting Ordinance No. 1306 by the following roll call vote:
AYES: Henry W. Wedaa, Chairman, Iry Pickler, Don R. Roth, Don E.
Smith, Wayne D. Wedin
NOES: None
ABSENT: None
That Ordinance No. 1306, An Ordinance of the Board of Directors of
County Sanitation District No. 13 of Orange County, California,
Amending Ordinance No. 1305 Establishing Wastewater Discharge
Regulations for Use of District Sewerage Facilities, be, and is hereby
adopted.
DISTRICT 1 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 1 be adjourned. The Chairman
then declared the meeting so adjourned at 8:12 p.m. , October 11, 1989.
DISTRICT 2 Moved, seconded and duly carried:
Approving Change Order No. 1 to the
plans and specifications for That Change Order No. 1 to the plans
Contract Nos. 2-26-2 and 2-27 and specifications for Portion of
Euclid Interceptor Sewer, between
Edinger Avenue and Lampson Avenue, Contract No. 2-26-2, and South Anaheim
Relief Sewer, on Ball Road between Euclid Street and Walnut Street, Contract
No. 2-27, authorizing an addition of $98,532.00 to the contract with
W. H. Ebert Corp. for an additional 1,610 tons of asphalt paving on Ball
Road, be, and is hereby, approved.
DISTRICT 2 Moved, seconded and duly carried:
Authorizing staff and General
Counsel to negotiate an agreement That staff and General Counsel be,
With the City of Anaheim to include and are hereby, authorized to
ity's Euclid Street Maintenance negotiate and prepare an agreement
Project in District's contract with the City of Anaheim relative to
No. Z-26-3 a cooperative project in connection
with construction of Portion of Euclid
Interceptor Sewer, between Broadway and Orangethorpe Avenue, Contract
No. 2-26-3, and the City of Anaheim Euclid Street Maintenance Project
between La Palma Avenue and the 91 Freeway, providing for City costs to be
reimbursed to the District.
-18-
10/11/89
DISTRICT 2 Moved, seconded and duly carried:
Receive and file re uest or
annexation an au horiz n That the petition from Gene Wilson, ,
initiation of proceedings re at al. requesting annexation of 2.102
ra osed Annexation No. 7 - son acres of territory to the District in
Annexa ion the vicinity of Country Hill Road and
Vista Del Sol in the City of Anaheim,
be, and is hereby, received and ordered filed; and,
FURTHER MOVED: That the Board of Directors hereby adopts Resolution
No. 89-144-2, authorizing initiation of proceedings to annex said territory
to the District, proposed Annexation No. 70 - Wilson Annexation to County
Sanitation District No. 2.
DISTRICT 2 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 2 be adjourned. The Chairman
then declared the meeting so adjourned at 8:12 p.m. , October 11, 1989.
DISTRICT 3 Moved, seconded and duly carried:
Authorizing the Selection omnit ee
to negotiate a Professional That the Selection Committee be, and
Services Agreement with NBS Lowry is hereby, authorized to solicit a
for design and construction proposal and negotiate a Professional
services re uired re Contract Services Agreement with NBS/Lowry for
Nos. 3- Na3- 5-2 design and construction services
required re Lampson Interceptor Sewer,
Contract No. 3-24-2, and Orange-Western Subtrunk Relief Sewer, Contract
No. 3-25.
DISTRICT 3 Moved, seconded and duly carried:
Acce tin Contract No. 3-34R
as comple a That the Board of Directors hereby
adopts Resolution No. 89-145-3,
accepting Manhole Adjustments and Street Repairs on Knott Interceptor Sewer,
Contract No. 3-34R, as complete, authorizing execution of a Notice of
Completion and approving Final Closeout Agreement. A certified copy of this
resolution is attached hereto and made a part of these minutes.
DISTRICT 3 Moved, seconded and duly carried:
Receive and file Summons an
omplaint from Westminster School That the Summons and Complaint to
District of Orange County re Determine Validity of Proceedings;
Amendment No. Three to the for Declaratory and Injunctive
Redevelo ment Plan for the Relief, Westminster School District
es tminster Commercial Redevelop- of Orange County, California vs. All
ment Project No. 1, Case No. 599324 Persons Interested in the Matter of
Amendment No. Three to the
Redevelopment Plan for the Westminster Commercial Redevelopment Project
No. 1 in the City of Westminster, et al . , Case No. 599324, be, and are
hereby, received and ordered filed; and,
FURTHER MOVED: That the District's General Counsel be, and is hereby, ,
authorized to represent the District' s interests in this matter, as
necessary.
-19-
10/11/89
DISTRICT 3 Moved, seconded and duly carried:
d Tournmen
That this meeting of the Board of
Directors of County Sanitation District No. 1 be adjourned. The Chairman
then declared the meeting so adjourned at 8:12 p.m. , October 11, 1989.
DISTRICTS 5 8 6 Moved, seconded and duly carried:
Award n ontrac Nos. - 7-1
and 5- 7- to Ni onal Plant That the Boards of Directors hereby
Services, Inc. adopt Resolution No. 89-146, receiving
and filing bid tabulation and
recommendation and awarding contract for Rehabilitation of Balboa Trunk
Sewer, Between 32nd Street and Coronado Street, Contract No. 5-27-1
(District 5 only) , and Investigation of Pacific Coast Highway Gravity Sewer,
Contract No. 5-37-2 (Districts 5 and 6), to National Plant Services, Inc. in
the total amount of $108,321.40 (Total amount for Contract No. 5-27-1 is
$30,800.00; total amount for Contract No. 5-37-2 is $77,521.40). A
certified copy of this resolution is attached hereto and made a part of
these minutes.
DISTRICT 5 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 5 be adjourned. The Chairman
then declared the meeting so adjourned at 8:12 p.m. , October 11, 1989.
DISTRICT 11 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 11 be adjourned. The Chairman
then declared the meeting so adjourned at 8:12 p.m., October 11, 1989.
DISTRICT 13 Moved, seconded and duly carried:
Ad ournment
That this meeting of the Board of
Directors of County Sanitation District No. 13 be adjourned. The Chairman
then declared the meeting so adjourned at 8:12 p.m., October 11, 1989.
DISTRICTS 6 7 8 14
Actions re Su cement No. 1 to E R
for Pro osetl Formation of District
No. 4 and Proposed Reorganization
No. 79 Involvin Rear anization of
Districts Nos. 7 and ii re impacts
resultin from final design align-
ment of ontract Nos. 14-1-1A
14-1-1B and 1 - -
Verbal Staff Report The Director of Engineering
reported that the reason for
preparing a supplement to the Environmental Impact Report for Proposed
Formation of County Sanitation District No. 14 and Proposed
Reorganization No. 79 Involving Reorganization of Districts Nos. 7 and
13 was to address possible impacts relative to changes in the final
design alignment of the major conveyance facilities included in the
-20-
10/11/89
original EIR--the Baker-Gisler Interceptor, Contracts Nos. 14-1-1A and
14-1-1B, and Baker Force Mains, Contract No. 14-1-2. It was originally
planned that the route of these sewers would be fully within city
streets. However, after the projects were designed, it became apparent
that to most effectively carry out the construction projects certain
public and private easements would be needed along the Santa Ana River
and within the Mesa Verde Golf Course as well as within a
privately-owned parking lot west of Harbor Boulevard. He also noted
that because some property owners have indicated their unwillingness to
negotiate easements with the Districts, it may be necessary to initiate
condemnation proceedings for certain properties. _
Mr. Dawes stated that the CEQA procedures to be followed in connection
with Supplement No. 1 to the EIR will provide for proper notification
to all property owners relative to the proposed final alignment of
these sewers.
He also advised that the supplement would address an increase in pipe
size from 72 inches to 90 inches.
Receive and file Initial Study and Moved, seconded and duly carried:
Environmental Impact Assessment
That the Initial Study and
Environmental Impact Assessment, which assess the impacts of the
changed alignment of the Baker-Gisler Interceptor, Contract
Nos. 14-1-1A and 14-1-1B, and Baker Force Mains, Contract No. 14-1-2,
necessitating the use of public and private easements and increasing
the size of pipe from 72 inches to 90 inches, finding that additional
documentation and preparation of Supplement No. 1 to said EIR is
necessary to satisfy CEQA requirements, be, and are hereby, received
and ordered filed.
Declarin intent -to re are Notice Moved, seconded and duly carried:
of Preparation of Supplement NO. 1
to EIR That the Boards of Directors do
hereby declare their intent to
prepare and circulate for public review a Notice of Preparation of
Supplement No. 1 to said EIR, in compliance with CEQA regulations.
DISTRICT 6 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 1 be adjourned. The Chairman
then declared the meeting so adjourned at 8:17 p.m. , October 11, 1989.
DISTRICT 7 Moved, seconded and duly carried:
A8,proying plans and specifications
for
�05tract Nos. 7-11-1 and That the Board of Directors hereby
7-11-3 adopts Resolution No. 89-147-7,
approving plans and specifications
for Abandonment of Lane Road Pump Station, Contract No. 7-11-1, and
Abandonment of Castlerock and Dow Avenue Pump Stations and Modifications to
MacArthur Pump Station, Contract No. 7-11-3, and authorizing the General
Manager to establish the date for receipt of bids. A certified copy of this
resolution is attached hereto and made a part of these minutes. fir/
-21-
10/11/89
DISTRICT 7 Moved, seconded and duly carried:
Acce tin ran s o asemen rom
Allen D. Gage re uontraCt No. 7--11---S That the Board of Directors hereby
adopts Resolution No. 89-148-7,
�..d approving and accepting Grants of Easement from Allen D. Gage for temporary
construction and perpetual right of way required in connection with
Abandonment of Castlerock and Dow Avenue Pump Stations and Modifications to
MacArthur Pump Station, Contract No. 7-11-3, and authorizing payment of
$3,000.00 for said right of way. A certified copy of this resolution is
attached hereto and made a part of these minutes.
DISTRICT 7 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 7 be adjourned. The Chairman
then declared the meeting so adjourned at 8:17 p.m. , October 11, 1989.
DISTRICT 14 Moved, seconded and duly carried:
Adjournment
That this meeting of the Board of
Directors of County Sanitation District No. 14 be adjourned. The Chairman
then declared the meeting so adjourned at 8:17 p.m. , October 11, 1989.
Secretary of tile Boards of Directors
of County Sanitation Districts
Nos. 1, 2, 3, 5, 6, 7, 11, 13 and 14
-22-
- FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/06/89 PAGE I
L.j REPORT NUMBER AP43
CLAIMS PAID 09/13/89 POSTING DATE 09//3/89
YARR ANT Nn. YUNnn. ARn uT __ _ OE8I8J�A1a—
�I 101905 ABC FAINT STRIPING SERVICE 1250.01 PAINT SUPPLIES
1019B6 L1N[DIN reRP Rf A INT[R IORc iilT_5p RHT1 ni9c ypyeT RC
101907 ADVANCED OFFICE SERVICES 575.77 OFFICE MACHINE REPAIR
• 101906 AIR COLD SUPPLY INC. $196.13 ELECTRIC PARTS
_. 101909 AIPHA4A7 -1A1 Cl mfac
101910 AMERICAN DISTRICT TELEGRAPH S69.00 SERVICES AGREEMENT
101911 ROPCO INC. S/OR AMERICAN SEALS S3.638.07 HARDWARE
+0+9+P eMFR VAu Trruuvu c omv <I nea_IP PnN
P•I 111913 ANINTEP - WIRE 6 CABLE S109.19 CLEANERS
i"1 141934
ARATER SERVICES. INC. $4,695.10 UNIFORM RENTALS
�•I 9 DD-� THSTRIn.1RRT PARTS
�j I 101916 ASPHALT INSTITUTE $721.50 ASPALT PAVING'� 1I1917 BC INDUSTRIAL SUPPLY, INC. $374.56 BUILDING SUPPLIES
101919 MIL ARY SANER $670.90 CONSULTING SERVICES - ANNUAL REPORT
X 111920 P.Y. BAROTTI AND ASSOC. S3.720.00 CONSTRUCTION SERVICES PI-25626. P2-33.34,37
t3 f0]921 RARTLf uF _ NA9TPR MAN
101922 DONERIC14 BASSO. INC. $9,371.69 AUTOMOBILE
�_ 101923 BANTER SCIENTIFIC PRODUCTS 32026.87 LAB SUPPLIES
WI 1.192
• Yf1111M RE, I l\CI R54_E4 I.AN11Cf1pi CIIP11 TPC
101925 BENZ ENGINEERING, INC. S889.64 COMPRESSOR PARTS
"n 101926 BOISE CASCADE OFFICE PRODUCTS $3.44 OFFICE SUPPLIES
M 1,Iq,7 Rnvlr rYc.urrPTur. rn.o T111 179 --
"^ 101928 BROOKS INSTRUMENT DIV. $414.96 METER
101929 BROWN S CALGVELL CONSULTING $6,139.53 ENGINEERING SERVICES PI-35,P2-39
m! VT W�U— CTTUVT TUC
a' 101931 SE GAPY G. STREEO - $432.65 PETTY CASH REIMBURSEMENT
"I 101932 C L R RECONDITIONING CO. $210.J0 MECHANICAL PARTS
q
MAINTENANCE CONTRACT M.0.2-nA_a9
101934 CS COMPANY S9,175.08 VALVE PAIRS
'ql 10IT35 CAL-FAC CHEMICAL CO.. INC. 215J.47 CHEMICALS
�• e
101937 JOHN R. CALAPRICE9 PMO SS40.00 CONSULTING SERVICES
101938 CALIF. ASSOC. OF SANITATION $685.04 REGISTRATION PEE
IIIIe{e _C .1-111
101940 JOMN CAROLLO ENGINEERS $3,931.29 ENGINEERING SERVICES
101941 CMIEMWEST INDUSTRIES, INC. S66.384.51 FERRIC CHLORIDE M.O.11-09-88
101943 CHEVRON U.S.A.• INC. $241.95 FAINT TRIMMER
101944 CLDSSON S CLDSSON $1.896.50 ENGINEERING SERVICES - LANDSCAPING
I 019A9 TECHNICAL JOURHeTs
103946 C.I.E.S. • CO. , INC. $23,854.75 PUMPS
'I 19191
7 COMPRESSOR COKFONENTS OF CALIF 2381.60 MECHANICAL PARTS
` 111949 CONSOLIDATED ELECTRICAL DIST. 15,311.81 ELECTRIC SUPPLIES
101950 CONSOLIDATED REPROGRAPHICS $1,847.40 BLUEPRINTING
FUND NO 9199 JT DIST WORKING CAPITAL PROCESSING DATE 9/06/89 PAGE 2
V REPORT NUMBER AP43
CLAIMS PAID 09/13189 POSTING DATE P9/13/09
DESCRIPTION
al
• 101951 CONTINENTAL GRAPHICS $27.249.51 BLUEPRINTING M.O.7-12-89
a ERP -
• 101953 COUNT YN OLES ALE ELECTRIC iJfS36.0T ELECTRIC SUPPLL IES
• 101959 DRANE VEYOR CORP. $344.58 PIPE
1O 301956 CAL WATER 3272.44 RENTAL EQUIPMENT
101957 LARRY CURTI TRUCK 3 EQUIPMENT $22,800.00 SLUDGE REMOVAL M.0.4-13-38
'• ]01959 DANIELS TIRE SERVICE $430.4•' I TIRES
• 101960 DANNYrS CUSTOM WAXING $920.00 TECHNICAL
REPAIRS: ER OVSPRAY REMOVAL
TECHNICAL NSES
10� 101962 TON DOVES S102.36 MEETING EXPENSES
a 101163 DEL MAR ANALYTICAL i8.320.10 EMISSIONS ANALYSIS
1°I CONSTRUCTION J-22 H.0.4-13-SA
101965 DEZURIK AND/OR CS CO. $1,325.43 VALVE PARTS
.�m 102966 DIATEC POLYMERS 35,793.17 ANIONIC POLYMER M.0.8-10-88
12 101968 DUNN EDWARDS CORP. 2584.70 PAINT SUPPLIES
••a�^' 301969 RIVALS SALES 3339.7E CONNECTORS
i•°I� CONSULTING - RECULATOR9-6-688I81d4P98-MPAPRB
!::i 101971 EASTMANr INC. 32r864.21 OFFICE SUPPLIES
1_aID 101972 EBERHARD EQUIPMENT $65.64 AUTOMOTIVE PARTS
YY 038T3 S'O'N6L YG78 pG i8 647 q7 COMPUTER CONSULTING 8ERVIGE9
0197/ EFFECTIVE VISUAL IMAGERY 3271. PRESENTATION AIDS
hj 201975 EDWARD L. ELLIOTr JP. $1 r355.00 ENGINBERINC SERVICES
' 101977 ENCHANTER, INC. $4,200.40 OCEAN MONITORING M.0.6-10-87
111978 ENGINEERS SALES-SERVICE CO. $452.62 PUMP PARTS
CONSULTING - PERSONNEL-STU8'2
101980 JEFF ESSER 3152.40 MILEAGE EXPENSES
j 1C1981 ESPRIT SYSTEMS. INC. $61.74 INSTRUMENT
101963 FARR SALES i SERVICE $2,396.96 ELECTNIC PARTS
ul 101964 FEDERAL EXPRESS CORP. $261.25 AIR FREIGHT
°0 101986 FIRST AMERICAN TITLE INSURANCE $6,430.06 TITLE REPORTS
Y•i 101967 FISCHER 9 PORTER CO. $174.37 CHLORINATION PARTS
103989 FOXBORO/JOROAN. INC $365.00 INSTRUMENT PARTS
102990 TRUCK 3 BUS GROUP/GH $23,662.64 VANS
30 PARRS
201992 GENERAL TELEPHONE CO. 32G1.69 TELEPHONE
101993 GIERLICH-MITCHELL. INC. $48,987.21 MECHANICAL SUPPLIES
ue .11 ea° nnu ner ry e . v° - ENGINEEREHG SBRNEGE9 RES 88 72
102995 HARRINGTON INDUSTRIAL PLASTICS 24.764.33 INSTRUMENT SUPPLIES
' 201996 HATCH i KIRK. INC. $51412,10 MECMAICAL REPAIRS
ni
ei
R.'
Pe
FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/06/89 PAGE 3
L✓ - REPORT NUMBER AP43
•I CLAIMS PAID 09/13/89 POSTING DATE C-9/13/89
'ARRANT NO_ VIHI111Y
ICI 101997 S. A. HEALY CO. $102 r015.63 CONSTRUCTION PI-35-1
11199A HniNPIGfR f-V_f_ fll li_ lYf_ Svvv.Lt
71 101999 HOUSE OF BATTERIES iS0O66 RATTERIeS
` 102000 R.S. HU ONES CO.. INC. f701..12 PAINT SUPPLIES
1020G2 HUNTINGTON BEACH RUBBER STAPP $172.25 RUBBER STAIR'S
302003 HUNTINGTON VALLEY SCHWINN CYCL $445.69 BICYCLE PARTS
110: 162005 ING INDUSTRIES 1398.61 ELECTRIC SUPPLIES
102006 ISCO COMPANY $770.87 LAB SUPPLIES
lnfn., ,u. ,^
eun• - BdIGIN88RiNC-SRRYICGG.^•T-���-.
"`i In 2101 INCON SYSTEMS, INC. $763.20 MECHANICAL PARTS
'�� 102009 INDUSTRIAL THREADED PRODUCTS i1.060.64 FITTINGS
102011 iR ON OAKSIrp Is1605.115 VALVE PARTS
1°ITl 102012 J f W SCIENTIFIC f1.068.95 LAB SUPPLIES
=..X 1n.n13 SURPbEBs
` r=. 302G14 JENSEN TOOLS R ALLOYS f111.92 TOOLS
102015 JOHNSTONE SUPPLY $199.54 ELECTRIC PARTS
1n", ouoYnu u .:nur{y . n eAy.041.01 CON
102017 KALLEEN-S COMPUTER SUPPLIESf1.296.01 OFFICE SUPPLIES
1°n 142018 KAMAN BEARINGS A SUPPLY $1,775.74 FITTINGS
r+' I In 2BIG uur. ........ fi 764 84
y.CA le 2020 KEEN-KUT ABRASIVE CO. $198.75 TOOLS
202121 KEN•S OIL, INC. $25.00 WASTE OIL DISPOSAL
1C2023 MARTIN KORDICK. SR 12,866.10 CONSTRUCTION SERVICES 14-1.5-34
102024 LRB SAFETY SUPPLY CO. $1.168.89 LAB SUPPLIES
" PbieS
1 102026 LEE G RO CONSULTING ENGR. $26.505.00 ENGINEERING SERVICES PI-33
102027 LIFECON-SAFETY SERVICE SUPPLY $216.55 CYLINDER REPAIRS
102029 LOTUS REVEL. COPR. f159.00 SOFTWARE
102030 LUSTRE-CAL $491.50 PRINTING
ses
IC2032 "PS $24.84 PHOTOGRAPHIC SERVICES
IC2333 HACONCO f442.80 MAINTENANCE CONTRACT
In F-GERYEGRF - MASTER PiAN
102035 MARVAC ELECTRONICS $49.86 INSTRUMENT SUPPLIES
102036 MASTER TOOLS SERVICES $47.91 TOOL REPAIR
102038 DON MAURER $4,375.00 CONSULTING SERVICES - OCEAN MONITORING
202539 MCKENNA ENGR. B EQUIP. S6,164.2P PUMP PARTS
WTI.. MONITOR
102041 MICROAGE COMPUTER $1,993.76 COMPUTER SOFTWARE/HARDWARE
,a�i 102042 MOBILE HOSE AND HYDRAULIC SUPP S145.74 HOSE
FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/06/89 PAGE 4
L REPORT NUMBER AP43
CLAIMS PAID 09/13/89 POSTING DATE 09/13/89
el 102043 MONITEK, INC. S3.333.57 INSTRUMENT PARTS
' 102045 MOTION INDUSTRIES. INC. $20.72 HARDWARE
102046 NEWARK ELECTRONICS S392.66 INSTRUMENT
10204E NOPCAL CONTROLS. INC. 5763.07 MECHANICAL PARTS
lial 102049 NORTH SUFPLY S283.45 TOOLS
•^'^'• * '42 ..' 32 QU ORSNR N 0 30 32—AR
1OI 202051 ORANGE'COAST ELECTRIC SUPPLY S136.27 ELECTRIC SUPPLIES
Ise' f12052 ORANGE COUNTY CHEMICAL CO. $1.613.85 HYDROCHLORIC ACID
1G2654 c� OSCARNS LOCK S SAFE 320.A7 KEYS 102655 OXYGEN SERVICE S1.184.18 SPECIALTY GASES
IM 102057 PSSI 92,521.00 TV SEWER SERVICES
P°I>G 212059 PACIFIC DATA COM SYSTEMS 33,556.78 MONITOR
= APSTiLSUR"""H
102060 PACIFIC SEWER MAINTEKANCE CORP S1.300.0G WE,
INSPECTION
102061 PACIFIC BELL $29.87 TELEPHONE
TERH
1206 PATE CELLULAR $126.47 CELLULAR TELEPHONEONE
SERVICES
�.DI 3D2064 FATTTENN CORP./ TAYLOR INSTR. 32.889.66 STRIP CHARTS
-ADITTNaSRR IICR6
262066 POLYPURE. INC, b15.759.56 CATIONIC CATIONIC POLYMER M.O. 3-8-89
112:67 POWER ELECTRO SUPPLY CO. S30.79 ELECTRIC SUPPLIES
�a 202069 HAROLD PRIMROSE ICE a106.00 ICE
102070 THE PROJECTS SOLUTION CO. $2.000.00 INSTRUMENTATION INSPECTION M.0.8-10-68
I'r'I 102072 RECYC. INC. 3399520.GL• SLUDGE REMOVAL M.O.5-1/-88
IaWc 202073 RED WING SHOES S96.63 SAFETY SHOES
^� 3R
N' ]02075 REMEDY TEMP $1.243.20 TEMPORARY SERVICES
h° 3020T6 THE REPUBLIC SUPPLY CO. $1.086.06 PIPE/FITTINGS
112178 REMOLD POWER TRANSMISSION S621.22 MECHANICAL PARTS
1��� 102079 RICHARDS. WATSON S GERSHON $7.862.P2 LEGAL SERVICES
162081 RONAN ENGINEERING CO. $65.07 INSTRUMENT PARTS
Iw' 102082 ROSEMONT ANALYTICAL $240.47 INSTRUMENT PARTS
IN-TRW MR
102G84 JOSEPH T. RYERSON S SON. INC. $2.423.16 STEEL
102CB5 SAFETY-KLEEN CORP. $796.93 PARTS CLEANER
102087 SCIENCE APPLICATIONS INT'L $114,662.29 OCEAN MONITORING M.O.6-14-89
102088 SEA COAST DESIGNS $5,212.81 OFFICE EQUIPMENT
P:.
FUND NO 9199 - JT DIST WORKING CAPITAL FROCESSING DATE 9/06/89 PAGE 5
REPORT NUMBER AP43
CLAIMS PAID 09/13/89 POSTING DATE 09/13/89
WARRANT NA, Amni'MT
OESC0.iPTi ON
°I L02089 SEA DYN, INC. S4T860.lC CONSULTING — SEDIMENT MODELING
102C91 SECURITY SPECIALISTS $2,963.44 SECURITY SYSTEM
102092 SHAMROCK SUPPLY 447.90 TDOLS
102094 SMITH-EXERT CO. S20B.00 SOIL TESTING
� eI 102095 SOFTWARE WAREHOUSE $455.44 SOFTWARE
'13 102N97 SOUTHERN CALIF. EDISON CO. 111.127.32 POWER
e 10209TO SO. CAL. GAS CO. R3.950.9G NATURAL GAS
0T
�"I 102100 SPEC TECH WESTERN 155823 WELDING SUPPLIES
102101 SPEEDE SPEEDOMETER $287:19 DRIVER TESTING
109100 cTeR TOOI A VIG PI I rnl _ (eGl_Tc
" frl I0I I0I STERLING APT 5180.84 GRAPHICS SERVICES
aix 102204
SUBIA, INC 5265.00 PRESENTATION AIDS.
1C2106 SUPELCO. INC. $151.58 LAB SERVICES
a fir. 102107 CONTINENTAL AIR TOOL, INC. 351J99.74 TOOLS/HARDWARE
APINr
102169 TEKMAR COMPANY S478.93 LAB SERVICES
102110 3T EQUIPMENT COMPANY 5981.03 FITTINGS
102112 TRUCK L AUTO SUPPLY. INC. $4,048.61 TRUCK PARTS
102113 J.G. TUCKER S SON. INC. $4,406.96 INSTRUMENT PARTS
SOIL TESTING
102115 UNOCAL 3229.63 UNLEADED GASOLINE
102116 UNITED NOTTINGHAM S}47.36 PORTABLE TOILETS
102118 DATAVAULT U.S.SAFE DEPOSIT CO. $1.124.00 COMPUTER PACK STORAGE
102119 UNIVERSAL MACK $410.60 TRUCK PARTS
ut
use 102121 VALLEY C7 TIES SUPPLY CO. $3,476.73 FITTINGS
102122 VAREC DIVISION $256.46 MECHANICAL PARTS
102124 VERTEX SYSTEMS $780.00 COMPUTER SERVICES
102125 VIKING INDUSTRIAL SUPPLY 3924.94 SAFETY SUPPLIES
1C2227 JOHN R. NAPLES 5546.35 ODOR CONTROL CONSULTANT
102128 WELLS FARGO GUARD SERVICE 51.20C.60 GAURD SERVICES
T AM
102130 WESTERN STATE CHEMICAL SUPFLI 532.359.46 CAUSTIC SODA H.0.8-10-88
102131 WEST-LITE SUPPLY CO. S335.28 ELECTRIC SUPPLIES
102133 XEROX CORP. 12.77U.P9 COPIER LEASES
ee -----------------
TOTAL CLAIMS PAID G9/1)/89 $3.442,263.35
FOND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 09/06/89 PACE 6
REPORT NUMBER AP43
L COUNTY SANITATION DISTRICTS OF ORANGE COUNTY
CLAIMS PAID 09/13/89 POSTING DATE 09/13/89
•I SUMNARY AMOUNT
a
•� R2 OPER FUND 5,523.58
o• P2 ACO FOND I49,4I8.15
,i /5 OPSE FUND 15,707.18
nl 95 ACO FUND 274.10
15.12
96 Am FUND 62,795.41
inl 97 OPER POND 9,132.18
e;
/Il OPER FUND 74.62
,e! 914 ACO FUND 43,101.19
FT1 �� 9566 AM FUND 280.00
F667 OPEN FUND 2,866.46
JT OPER FOND 460.788.9
CORF 2,502.2720 CC
0
JT DIST WORKING CAPITAL FUND 255,213.48
Y'i
� r3.942;M0.15
61
!
�1
N<
i+ol
of
�I
_ Mr
r,!
FUND I( )199 - APT GIST WORKING CAPITAL PROCESSING DATE 9/49/89'FAGE l(
REPORT NUMBER AP 93
CLAIMS PAID DS/27/89 POSTING DATE 09/27/89
102249 ABC VIDEO, INC. S119.50 INSTRUMENT REPAIR
n
v 102151 AIRPAX CORP. CAMBRIDGE DIV. S495.72 CIRCUIT BREAKER
a 102252 LEASING ASSOCIATES/ALLSTATE $1,290.34 AUTOMOBILE LEASES
•,� 1t 2154 R09CO INC. 5/OR AMERICAN SEALS 54.267.4- HARDNARE
162155 AMERITECH $97.52 COPIER LEASES
a
1 C2157 ANIXTER - WIRE S CABLE $743.98 ELECTRONIC SUPPLIES
sEIT.102158 ABATE% SERVICES♦ INC. $328.69 UNIFORM RENTALS
10216J ATLAS CHRYSLER PLvMOUTH $3,688.61 TRUCK PARTS
102161 AUTO SHOP EQUIPMENT CO. S260.UG TRUCK PARTS
102163 FALCON DISPOSAL SERVICE $63.922.45 GRIT REHOVAL M.0.7-13-88
102164 BANK OF ANERTCA-C.A.S.C. S6.486.13 ADMINISTRATION FEE - CERTIP. OP PARTICIPATION
1n,,A4 01MY ni eYP PTN tO ATI_aY
ul 102166 P.Y. BAROTTI ALD ASSOC. $5.520.06 CONSTRUCTION SERVICES P1-25.26.P2-32.33,36.37
102167 P. GATEMAN 5575.:0 DEFERRED COMP DISTRIBUTION
+1.9110 Ll. ai TYnrT oAll
sl X 102169 BAXTER SCIENTIFIC PRODUCTS $2,962.54 LAB SUPPLIES
r = 102270 ROBERT BEIN.WILLIAM FROST 6 AS S41939.55 ENGINEERING SERVICES 5-31
enTer reerenr Arr Trr Cenm:r Te ♦on..2o n T1. enV I.
102172 SOLTRONIX CATA MAINTENANCE $275.00 MAINTENANCE CONTRACT
--1 102173 BROOKLYN THERMOMETER CO.. INC. 899.6P LAN SUPPLIES
Tnmt]. R.... . fu nun : to .T_Y
ul� 102175 BROWN S CALDWELL CONSULTING $1.928.1E ENGINEERING SERVICES PI-35, P2-39
i—' 102276 GARY G. STREED 5805.91 P= CASH REIMBURSEMENT
10217E CPT CORPORATION S84.76 OFFICE SUPPLIES
102179 CRC PRESS . INC. 31O2.50 CHEMICALS
tnoton ri rON euv a ttA-•2 veT tr-S
102181 CAL-6L AS8 FCR RESEARCH. INC. 8662.% LAB REPIARS
102182 CALTROL . INC. S3.260.73 REGULATOR PARTS
202184 CASE POWER A EQUIPPE'NT $346:67 TRUCK PARTS
262165 CENTURY PAINT 917214 PAINT
0. 302187 CMEMWEST INDUSTRIES. INC. $68,943.35 FERRIC CHLORIDE M.0.11-09-88
102188 CHEVRON U.S.A.. INC. $979.44 CREASE 6 OIL
102190 CONPRESSOk COMPONENTS OF CALIF $1,179.00 BEARINGS
2,2191 COMPUTER OATACOK 51.413.6E OFFICE SUPPLIES
P'Ol.1 rnYw:tr
102193 HUNG CONG S45.60 EMPLOYEE MILEAGE
102191 CONNELL S.M. PARTS / DIV. S155.5C TRUCK PARTS
r
FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9120/69 PAGE 2
REPORT NUPBER AP43
CLAIMS PAID 59/27/89 POSTING DATE T9/27/89
a
1C2195 CON-WAY WESTERN EMPRESS 379.25 FREIGHT
r 162197 CONTINENTAL GRAPHICS $7,346.97 BLUEPRINTING
• 102198 CORNIER SUZUKI Sb36.49 SALES TAE
ID2200 COUNTY WHOLESALE ELECTRIC $1.177.49 ELECTRIC SUPPLIES
102201 CAL WATER $15.46 RENTAL EQUIPMENT
102203 ONE, INC. SB15.9L FITTINGS
102204 DAILY PILOT 16A.00 NOTICES 6 ADS
TEST EQUIPMENT
302206 CE2URIN AND/OR CS CO. S1.688.O9 VALVE
1C2207 DIATEC POLYMERS $2,611.24 ANIONIC POLYMER M.0.8-10-88
PRIRTL C
m 102289 DOR ADO ENTERPRISES,IS ES. INC. $29960.11 PLANT MAINTENANCE 6 REPAIR
X 102211 FRANK DRYOEh S ASSOC. S34O.00 SCRUBBER INSPECTION
.no 91. r_. _ _ .u9rxuurx rS_ .v_ u.1g�IT 5{IR2L125
1.2212 EASTMAN. INC. C317.66 OFFICE SUPPLIES
192213 ECCANALYSIS. INC. $2.737:7: OCEAN MONITORING
� .nam.• re•erT.ur u. u. u.rr•u .ar ca PRSSRMTAT1011 AIDS
182215 ENCHANTER. INC. S2.380.00 OUTFALL VIDEO
1 302216 ERNST L WHINNEY $9,900.30 CONSULTING SERVICES - CLASSIFICATION STUDY
102211
IP2218 FBI SAND AND GPAVFL. INC. $3.0.29 ROAD BASE ROCKS
102219 MARSHALL FAIRRES SS•J.00. DEFERRED COMP DISTRIBUTION
.nAs•n .nuu c si rr •e •^0 ^0 ^^"S'"^"^TiOM SSRVICBS J 20 fy "
102221 FARR SALES S SERVICE �a$177.02 FILTERS
102222 FCOERAL EMPRESS CORP. $536.50 AIR FREIGHT
p' 102224 FISCHER-S PCRTER CO. S1a929.06 CHLORINATION PARTS
102225 FLAT S VERTICAL CONCRETE S395.1J CONCRETE CUTTING
I» 102227 FOUNTAIN VALLEY CAMERA S551.30 FILM
102220 FOR ENTERPPISES 31.825.94 SAFETY CONSULTING
102230 FROST ENGINEERING SEPVICEF CO. $76.77 VALVE PARTS
1321^31 CITY OF FULLERTON $137.86 WATER USEAGE
102233 GATES FIBERGLASS INSTALLERS 51.689.0E REPAIR MANIFOLD
102234 GENERAL TELEPHONE CO. S6.746.29 TELEPHONE
102236 GIERLICH-MIICMELL. INC. S5.9J2.33 ELECTRIC PARTS
1.2237 GOLOE& COAST 810HASS EI:EiGY CD $3,816.00 SAWDUST
iP 1C2239 HALFRIN SUPPLY CO. $7.39 OPERATING SUPPLIES
Iwo 10224L FRED A. MAPPER $1.454.00 DEFERRED COMP DISTRIBUTION
�a7
FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/2G/84 PAGE 3
L REPORT NUMBER AP43
a
CLAIMS PAID 09/27/89 POSTING DATE 09/27/89
s
102241 HARRINGTON INDUSTRIAL PLASTICS it♦311.!3 INSTRUMEN'T PART
le '102243 S. A. MEALY CO. 1327♦723.87 CONSTRUCTION PI-35-1
Y
132244 MOERPIGER C.V.S. CALIF. ♦ INC. i3♦382.E6 MECHANICAL PARTS
102246 DONALD 0 NONOMICNL SSOL.CO DEFERRED COMP DISTRIBUTION
142247 R.S. HIES CO.. INC. 51.145.2E SAFETY SUPPLIES
102249 HUNTINGTON VALLEY SCMWINN CTCL 554.23 BICYCLE PARTS
102250 INDUSTRIAL THREADED PRODUCTS $578.05 CONNECTORS
102252 INLAND EMPIRE EQUIPMENT CO. SI♦.22.90 EQUIPMENT RENTAL
1C2253 IRVINE RANCH WATER DISTRICT s17.35 WATER USEAGE
° m 102255 RIVIERA FINANCE $526.02 JANITORIAL SUPPLIES
X 111151 DAVID JENKINS B ASSOC.. INC. $2.905.35 SOURCE CONTROL CONSULTING
102258 KALLEEN♦S CCMPUTER SUPPLIES 3159.49 OFFICE SUPPLIES
102259 KAMAN BEARIKGS t SUPFLT $784.28 FITTINGS
102261 KEENAN t ASSOCIATES SOCIATES $3.162.50 WORKERS COMP ADMINISTRATION
102262 KEENAN SUPPLY S190.16 VALVE
I C2264 KING BEARINE♦ INC. $9.162.57 MACHINE SUPPLIES
102265 DONALD E. KINNEY $815.3W DEFERRED CORP DISTRIBUTION
r
102267 MARTIN KORDICK. SR $2.972.10 CONSTRUCTION SERVICES 14-1.2-26
102266 LAB SAFETY SUPPLY CO. $614.34 MUSIC PARTS
102270 LIMITORQUE CORP. $21.376.81 VALVE
102271 MPS $191.86 PHOTOGRAPHIC SERVICES
r
102273 MARVAC ELECTRONICS $1♦952.75 INSTRUMENT SUPPLIES
102274 MASTER TOOLS SERVICES 5331.57 TOOL REPAIR
PH'
102276 MCKENNA ENGP. C EQUIP. S2.198.90 PUMP PARTS
1 P2277 NCMASTEP-CAPP SUPPLY CO. $1_♦811*45 NAIIDNARE
e
102279 METER CRAFT INC. $79.21 METER
102.80 MICRO MOTIOA 53.J57.69 INSTRUMENT REPAIR
1622P2 SEPPENTIK AND/ ' $4,757.42 MECHANICAL PARTS
102283 AL AD EN RU NTT[M CONSTRUCTIOK CO $38,213.92 CONSTRUCTION 3-34R
111IPAY MllQ llr NOCr •V1 GYM1YI ♦r e..CTIC eiY-V9 Va o
102285 MORDIGAN TREES '' $583.32 LANDSCAPING SUPPLIES
. I 192286 MOTION INDUSTRIES, INC. 5222.6E MECHANICAL PARTS
♦
FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/20/89 PAGE 4
[: REPORT NUMBER AP43
CLAIMS PAID 09/27/69 POSTING DATE 09/27/89
�aARRANT Q.
Ie 102287 NA PRODUCTS. INC. 5139.34 PIPE SUPPLIES
Iv 102289 NEUTRON 5950.JU RENTAL EQUIPMENT
° 162290 NEWARK ELECTRONICS 5273.75 ELECTRIC SUPPLIES
10 102292 OFFICIAL AIRLINE GUIDES f335.AO PUBLICATION
102293 OSU/SMEAC. $51.14 PUBLICATION
u °
102295 ORANGE COUNTY AUTO PARTS CO. f1.J29.87 TRUCE PARTS
ne
10229E ORANGE COUNTY FARM SUPPLY CO. f1.J76.11 LANDSCAPING SUPPLIES
I42258 JRRNGE VALVE 6 FITTING CO. $299.79 PITTINCS
I^ 102299 05C AR°S LOCK S SAFC $47.45 KEYS
u ero4vr •;2.y.^c 5P^^T^T" CASES
102301 COUNTY SANITATION DISTRICT $83.92 DEFERRED COMP DISTRIBUTION
MITI 102302 COUNTY SANITATION DISTRICT 13.J24.35 REIMBURSE WOREBRS COMP INSURANCE
X
(" 1C2304 PACIFIC PARTS $6,259.19 INSTRUMENT PARTS
102305 PACIFIC PKCCESS EGUIPPENT.INC. f438.P4 PUMP PARTS
.nv anR oAr1PTP veer.. en .corn* r vT ID7 33 o..ve
121
102307 PACIFIC BELL $664.48 TELEPHONE
CZ 102308 PAINE S ASSOCIATES $8,271.25 COMMUNITY RELATIONS CONSULTING
-u0 102310 PARTS UNLIMITED� $1.762.2A AUTOMOTIVE PARTS
IAA 102311 FEAT, MARWICK, MAIN f CO. 54.628.0? AUDITING SERVICES
..e..e on. egypT orvAry 5-0O8 • , nvnevevn pOMm ^•q•g38112I0R
r' 102313 PHOTO f SOUND CO. $6,656.44 COMPUTER EQUIPMENT
ual 102119 PIMA 600 SYSTEMS, INC. $09.602.45 SLUDGE REMOVAL M.O.5-I1-88
0
102316 PLAN-SAK 1122:75 MAILING SUPPLIES
°O 102N 7 POL Y PURE. INC. $20.468U3 CATIONIC POLYMER M.O.3-8-89
102319 HAROLD PRIMROSE ICE 5180.00 ICE
102320 THE PROJECTS SOLUTION CO. $4,240.00 INSTRUMENTATION INSPECTION M.O. 8-10-88
IN ENGINEERING PLANS REVISIONS
1 � 102322 PAINBOW DISFOSAL CO. $404-1! TRASH REMOVAL
1 '2323 R.0 SYSTEMS. INC. $389.2C INSTRUMENT REPAIfl
102325 REDI EMPRESS $3 J.CC MESSENGER SERVICES
IC2326 THE REGISTER S9GO.37 NOTICES 6 ADS
162328 PENOTC METER RESETTING SYSTEM 53.479.O[ POSTAGE
I02329 THE REPUBLIC SUFFLY CO. 5185.71 HARDWARE
M
102331 JOSEPH 1. RYERSON L SON. INC. $1 .780.45 METAL
h102332 SANCON ENGINEERING . INC. 58.950.20 SEWER REPAIRS
1e
FUND NO 9199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/20/R9 PAGE 5
REPORT NUMBER AP43
CLAIMS PAID 09/27/89 POSTING DATE 09/27/89
la
162333 SEA COAST DESIGNS 6354.12 OFFICE FURNITURE
102335 SHAMROCK SUPPLY S62.n6 SAFETY SUPPLIES
102336 SIERRA EVIRON.ENGP..TNC. 39.800.00 ENGINEERING SERVICES - VOC TESTING
al 102338 SMITH PIPE 3 SUPPLY. INC $336.71 PLUMBING SUPPLIES
102339 SOIL AND TESTING ENGINEERS S348.00 SOIL TESTING
II' 102341 SOUTHERN CALIF. EDISON CO. $444.022.84 POWER
11
2342 S0. CAL. CO. 5287.53 NATURAL GAS
1R P14• CO. CAI ,,!Al. YSTFR f0. A.R_E4 WAERR URRAG8
1al 102344 SOUTHERN COUNTIES OIL CO. $4,156.21 DIESEL FUEL
102345 SPARKLETTS OPINNING WATER $2,183.62 DRINKING WATER/CDOLER RENTALS
a
102347 STAR TOOL s SUPPLY CO. $1,483.96 TOOLS
IAK X 102348 STERLING APT $32.30 OFFICE SUPPLIES
'A IRIA49 ¢IIYNTT ¢Tffl [a feT-M1e M87A6
102350 SUPELCO. INC. $1,034.60 LAB SUPPLIES
A 102351 CONTINENTAL AIR TOOL. INC. $1,217.04 TOOLS
6p 302353 TAN TAKAMINE 3360.00 LANSCAPING SUPPLIES
102354 TAYLOR-DUNN $438.94 TRUCK PARTS
a I anf 14G oTnY... Tf Ue
11RACR SERVICES
ICWIRNGB
102357 CHARLE ANALYTICAL. INC./NOR CPL $335.09 LAB SERVICES
302351 CM4RLE5 E. TH OM45 $632.99 TRUCK PARTS
• . v
302359 TOTAL PREVENTION SYSTEMS 66.174.9C ENGINEERING SERVICES PI-27-1
I 10236D TRAFFIC CONTROL SERVICE, INC. 37.150.0E TRAFFIC CONTROL SERVICES DIST 2
tnP.a. ¢RANG TRA.F1 - T 93 SBRViGBG
w 112362 T.S. TP IPP $1.94J•CO WINDOW WASHING
102363 TRUCK S AUTO SUPPLY. INC. $164.94 TRUCK PARTS
102365 U•S• YATE P kEVS S39.00 SUBSCRIPTION
- � 102366 UND EP GP OUND SERVICE ALERT s154.00 MEMBERSHIP FEES
102!58 UNITED WESTERN ELEVATOR $326.15 SERVICE AGREEMENT
102369 UPJOHN HEALTHCARE SERVICES $400.9.3 CPR TRAINING
R
102571 VALLEY CITIES SUPPLY CO. S8076.43 FITTINGS
Ga 102372 VARIAN INSTRUMENT DIVISION $632.42 LAB REPAIRS
'A 102374 VEPTEK SYSTEMS $5.235.00 COMPUTER SUPPORT
Y 102375 VIKING INDUSTRIAL SUPPLY 311.36 FREIGHT
1G2377 WELLS FARGO GUARD SERVICE $2.359.85 GUARD SERVICES
102378 WEST COAST ANALYTICAL SAY. $20.00 LAB SERVICES
ptl
FUND NO ^199 - JT DIST WORKING CAPITAL PROCESSING DATE 9/20/89 PAGE E
REFORI NUMBER AP43
CLAIMS PAID 09/27/89 POSTING DATE 09/27/89
I•
!° 102379 WE.STEPN METRO SUPPLY $13.19 FREIGHT
CA
' 102381 WEST!LITE SUPPLT CO. .933.5, ELECTRIC SUPPLIES
1° 162382 ROURKE A WOGDRUFF $36.919.97 LEGAL SERVICES M.0.6-04-89
I° CONSULTING SERVICES M.0.1-11-89
1O 102384 RICHARD YOUNG PROD. - 1342.10 OFFICE SUPPLIES
I» IO23E5 RICMARD S. E06 AS S2G0.CO DEFERRED COMP DISTRIBUTION
u
n•
TOTAL CLAIMS PAID D9/27/89 $1.782,064.78
_________________
luSUMIURY AMOUNT
/1 OPER FUND 3 1,111.77
01 CONST FUND 1,791.94
02 AGO FUNDFUNU 63:187:62
02 CONST FUND 3.213.88
iu 03 AM FUND 228.00
v> I 03 CONST FUND 3.482.31
u 65 AGO POND 15,565.92
06 DIES FUND 1,325.18
u I] OPER FUND 10.915.40
» 17 ACO FUND 1.447.00
All AGO FUND 3.30
013 OPER FUND 126.48
>• 014 AZ FUND 1,596:84
v. 0566 OPER FUND 3,870.45
aq 1617 DPER PUND 36.28
I•v 07614 OPER FORD 3.394.38
N° CORP 439,688.74
SELF FUNDED WORKERS COMP INSURANCE FUND 11,268.85
•M'I 6 529.26
i•' F 1.782.064.78
�•0i
I•°I
�w
EXCERPT FROM THE MINUTES OF THE REGULAR
JOINT MEETING OF THE BOARDS OF DIRECTORS OF COUNTY
.�' SANITATION DISTRICTS NOS. 1, 2, 3, 5, 6, 7, 11, 13 AND 14
OF ORANGE COUNTY, CALIFORNIA
A regular joint meeting of the Boards of Directors of County Sanitation Districts
Nos. 1, 2, 3, 5, 6, 7, 11, 13 and 14 of Orange County, California, was held at the
hour of 7:30 p.m. , October 11, 1989, at 10844 Ellis Avenue, Fountain Valley,
California.
The Chairman of the Joint Administrative Organization called the meeting to order
at 7:30 p.m.
The roll was called and the Secretary reported a quorum present.
DISTRICT 7 Moved, seconded and duly carried:
Accepting Grants of Easement from
Allen D. Gage for temporary That the Board of Directors hereby adopts
construction and perpetual right of Resolution No. 89-148-7, approving and
way required in connection with accepting Grants of Easement from Allen
Contract No. 7-11-3 D. Gage for temporary construction and
perpetual right of way required in
connection with Abandonment of Castlerock and Dow Avenue Pump Stations and
Modifications to MacArthur Pump Station, Contract No. 7-11-3; and,
FURTHER MOVED: That payment of $3,000.00 for said right of way be, and is
hereby, authorized.
A certified copy of this resolution is attached hereto and made a part of these
minutes.
STATE OF CALIFORNIA)
) SS.
COUNTY OF ORANGE )
I, RITA J. BROWN, Secretary of each of the Boards of Directors of County
Sanitation Districts Nos. 1, 2, 3, 5, 6, 7, 11, 13 and 14 of Orange County,
California, do hereby certify that the above and foregoing to be a full , true and
correct copy of minute entries of the meeting of said Boards of Directors on the
11th day of October, 1989.
IN WITNESS WHEREOF, I have hereunto set my hand this 11th day of October, 1989.
Secretary of the Boars of Directors
...i of County Sanitation Districts
Nos. 1, 2, 3, 5, 6, 7, 11, 13 and 14
STATE OF CALIFORNIA)
) SS.
COUNTY OF ORANGE )
Pursuant to California Government Code Section 54954.2,
I hereby certify that the Agenda for the Regular Board Meeting
on Ok%AA.k� , 19941 was duly posted for public
�� inspection
at the main lobby of the Districts ' offices on attAko, S
19�.
IN WITNESS WHEREOF, I have hereunto set my hand this $�
day of 19-U.
Rita J. Brown, Secretary o
each of the Boards of Directors
of County Sanitation Districts
Nos. 1, 2, 3, 5, 6, 7, 11, 13 6
14 of Orange County, California